K&K Industries, Inc. ( 2019 )

ARMED SERVICES BOARD OF CONTRACT APPEALS
Application Under the Equal Access )
to Justice Act of~ )
)
K&K Industries, Inc. ) ASBCA No. 61189)
Under Contract No. W912HY-l l-C-0009 )
APPEARANCES FOR THE APPELLANT: Terrence L. Brennan, Esq.
Brian S. Schaps, Esq.
Deutsch Kerrigan, L.L.P.
New Orleans, LA
APPEARANCES FOR THE GOVERNMENT: Michael P. Goodman, Esq.
Engineer Chief Trial Attorney
Clark Bartee, Esq.
James Purcell, Esq.
P. Alex Petty, Esq.
Engineer Trial Attorneys
U.S. Army Engineer District, Galveston
OPINION BY ADMINISTRATIVE JUDGE PROUTY
ON APPELLANT'S EQUAL ACCESS TO JUSTICE ACT APPLICATION
Pending before the Board is an application for fees and other expenses pursuant
to the Equal Access to Justice Act (EAJA), 5 U.S.C. § 504, submitted by appellant,
K&K Industries, Inc. (K&K). The underlying appeal was taken pursuant to the ·
Contract Disputes Act, 41 U.S.C. §§ 7101-7109. See K&K Industries, Inc., ASBCA
No. 61189, 18-1 BCA ,-i 37,134 at 180,720. Familiarity with that decision is
presumed. Because we find that K&K is an eligible, prevailing party, and that the
government's position was not substantially justified, we grant K&K's application but
reduce the requested recovery to that which is allowed by the EAJA.
BACKGROUND
This appeal involves the above-captioned contract for the rehabilitation of four
floodgates on the Brazos River in the Gui f Intracoastal Waterway, Texas. K&K, 18-1
BCA ,-i 37,134 at 180,720. During contract performance, K&K discovered that one of
the large hinge castings, to which the floodgates were attached, was cracked. This
necessitated the installation of a spare casting, which required substantial time and
effort. As a consequence of the work installing the spare casting, on January 13, 2016,
K&K submitted a certified claim to the contracting officer (CO) seeking additional
compensation and an extension of time on the contract. K&K submitted a revised
claim to the CO on September 12. 2016. Id. at 180.722. On March 6, 2017, the CO
approved a portion of the sought-for additional compensation and contract extension,
denying the balance. Id. at 180. 723. K&K then appealed to the Board. In our
September 5, 2018 decision on the merits, we found that K&K was entitled to recover
$61,092 plus interest for additional costs associated with the contract. Id. at 180,724.
On November 15, 2018, K&K filed its application for fees and costs under the EAJA.
DISCUSSION
As a partial waiver of sovereign immunity. the EAJA is to be strictly construed
in favorofthe United States. Ardestaniv. I.NS.. 502 lJ.S. 129,137 (1991). To
recover under the EAJA. an applicant must timely file its application, establish that it
is an eligible party as defined by the EAJA, and prove that it was a prevailing party in
the underlying action. Rex Systems, Inc .. ASBCA No. 52247, 02-1 BCA 131,760at 156,854. Even if an applicant is otherwise qualified, an award may be denied if the
government's position is determined to have been substantially justified, or if special
circumstances make an award unjust. 5 U.S.C. § 504(a)(l).
The government does not contest K&K's status as a prevailing party or the
timeliness of the application, and we find that K&K meets these prerequisites. Instead,
the government argues that K&K failed to provide sufficient evidence that it is an
eligible party; that the government's position was substantially justified; that the
attorneys' fees requested should be capped at the statutory $125 hourly rate; and that
travel costs for lay witnesses are not recoverable expenses. (Gov't opp'n at 2-5) In its
reply, K&K submitted additional evidence supporting its position that it is an eligible
party and argued that the government failed to meet its burden to show that its position
in the underlying appeal was substantially justified (app. reply br. at 1-3). K&K did
not respond to the government's arguments regarding the fee cap or the
appropriateness of paying lay witness travel costs.
Eligibility
A party is generally eligible for consideration of an award of costs under the
EAJA if it is ai:i entity having a net worth of no more than $7,000,000 and no more
than 500 employees at the time the adversary adjudication was initiated. 5 U.S.C.
§ 504(b)(l)(B)(ii). "Net worth is determined by subtracting an applicant's total
liabilities from its total assets." Kostmayer Construction, LLC, ASBCA No. 55053,
09-2 BCA 134,302 at 169,440 (citing Broaddus v. United States Corps of Engineers,
380 F.3d 162, 167 (4th Cir. 2004)). K&K asserts that it is eligible to receive fees and
expenses under the EAJA because it meets these criteria. The government questions
the proof submitted by K&K.
2
To support its position that it is an eligible party, K&K submitted a financial
statement with balance sheets as of December 31, 2015, and December 31, 2016, as
part of its application. These showed a net worth of $6,156,323 and $6,145,576, as of
those dates respectively. (App. br., ex. 3 at 3-5) Given how close these amounts were
to the $7 million threshold, the government responded that appellant failed to meet the
burden of presenting sufficient evidence of a net worth under $7 million and fewer
than 500 employees as of May 31, 2017 (gov't opp'n at 4). The government allowed,
however, that K&K could prove its eligibility by submitting a supplemental balance
sheet better demonstrating its value at the time this appeal was initiated (id. at 5 (citing
Kostmayer Constr., 09-2 BCA, 34.302 at 169,440)). K&K's response included a
financial statement for the year ending on December 31, 2017, reflecting a net worth
of$6,184,096, and an employee earnings summary dated May 2017, showing 48
employees as of May 2017 (app. reply, ex. 9 at 4-5, ex. 10). In light of K&K's
additional financial statement, which is consistent with its earlier-filed statements, we
are satisfied that K&K has proved that it is an eligible party.
Substantial Justification
The law regarding "substantial justification" and the EAJA is well established.
The government bears the burden to show that its position was substantially justified.
Amaratek, ASBCA Nos. 59149, 59395, 15-1 BCA, 35,866 at 175,348 (citing
Lucia E. Naranjo, ASBCA No. 52084, 00-2 BCA, 30,937 at 152,707). To prevail on
a substantial justification defense, the government is not required to prove that it had a
substantial likelihood of success in the litigation; rather that "a reasonable person
could think [the government's position is] correct, that is [that] it has a reasonable
basis in law and fact." Pro-Built Construction Firm, ASBCA No. 59278, 18-1 BCA
, 36,975 at 180,116 (citing Pierce v. Underwood, 487 U.S. 552, 566 n.2 (1988);
Rex Sys., 02-I BCA, 31,760 at 156,854). Put another way, the government's position
is more likely to be substantially justified when greater "legal uncertainty" is
presented. SST(Supply and Service Team) GmbH, ASBCA No. 59630, 18-1 BCA
, 36,932 at 179,932 (citing Rex Sys., 02-1 BCA, 31,760 at 156,855).
Substantial justification applies to the entirety of the litigation position and not
just the posture on individual issues. Thus, the Supreme Court has held that, "[w ]hile
the parties' postures on individual matters may be more or less justified, the EAJA-
like other fee-shifting statutes - favors treating a case as an inclusive whole, rather
than as atomized line-items." Commissioner, INSv. Jean, 496 U.S. 154, 161-62
(1990) (citations omitted); cf Texas State Teachers Association v. Garland
Independent School Disirict, 489 U.S. 782, 793 (1989) (in other fee-shifting statutes,
overall success goes to reasonableness, not availability, of the award).
The government's position regarding substantial justification appears to be that
it always recognized that it owed K&K compensation for the cracked hinge casting,
3
but that K&K's failure to properly support its claims deprived the government of its
ability to make a reasonable settlement and thus compelled it to engage in this
litigation (gov't opp'n at 6). In particular_ it argues that two specific failures of K&K
to support its claim led to this result: first, K&K supposedly failed to produce a
schedule demonstrating that the hinge work was on the critical path to project
completion (id. at 7); second, the government argues that the consultant fees sought by
K&K were apparently for claim preparation and thus it was reasonable for it to dispute
them (id. at 8). Neither matter makes the government's position substantially justified.
First with respect to the lack of a critical path analysis, the actual
circumstances before the government during contract performance set forth in our
decision on the merits made clear that the cracked hinge substantially held up progress
on the large scale work on the project. See K&K, 18-1 BCA, 37,134 at 180,721-23.
The scope of this work, as described in our opinion, was significant and readily
apparent. Thus, the government, being present while the work was being performed,
did not need a formal critical path analysis to judge that it was responsible for the 21
days of delay, and hewing to this formalism, under these circumstances, was not a
substantially-justified position.
Turning to the consulting fees, although we agree that K&K would not have
been eligible for an award in the event that the fees were for claim preparation, we held
on the merits that the fees awarded were not for such a purpose. 18-1 BCA , 37,134
at 180,724. We did so based upon the timing of the incurred costs (id.), which was a
fact that would have been known to the government when it denied the claim.
Given the foregoing, a reasonable person could not think that the government's
decision to litigate this appeal had a '·reasonable basis in Jaw and fact." Thus, we find
the government's position not substantially justified. Pro-Built, 18-1 BCA, 36,975
at 180,116 (citing Pierce, 487 U.S. at 566 n.2; Rex Sys., 02-1 BCA, 31,760 at 156,854).
Request for Enhanced Attorneys' Fees
Notwithstanding the EAJA's limitation of the attorney fee rate to $125 per hour
under 5 U.S.C. § 504(b)(l)(A), K&K requests increased rates of$275.00 and $180.00
per hour for attorneys' fees, for a total of$44,322.55 of attorneys' fees and costs
directly related to this appeal, due to alleged special circumstances (app. br. at 2).
Unlike the portion of the EAJA which permits enhanced attorneys' fees in cases
brought before the federal courts pursuant to 28 U.S.C. § 2412(d)(2)(A), the provision
of the EAJA applicable to adjudication before administrative agencies, such as the
Board, only permits the assessment of fees greater than $125 per hour if an agency
regulation provides for it. See 5 U.S.C. § 504(b)(l)(A); Optimum Services, Inc.,
ASBCA Nos. 58755, 59952, 17-1 BCA, 36,816 at 179,431-32. As of the date of this
decision, no such regulation has been issued by the Department of Defense, and we
4
consequently possess no authority to award enhanced fees. Accordingly, the hourly
rate will not be increased above the statutorily allowed $125 per hour.
K&K's application listed the number of hours worked by attorneys in this
appeal as 181.5: 74.8 hours billed at $275.00 per hour and 106.7 hours billed at
$180.00 per hour. It also seeks 29.4 hours worked by paralegals and billed at $90.00
per hour (app. br. at 2, ex. 4 at 9). Additional litigation expenses were listed in the
amount of $1,900.55, for a total of $44,322.55 related to the appeal (id., ex. 5 at 2).
The government has not challenged the reasonableness of the number of hours claimed
by K&K (gov't opp'n at 2). Keeping in mind the $125 per hour statutory limit, we
award attorneys' fees, paralegal fees, and litigation expenses as follows:
Type Rate Hours Fees
Attorneys' Fees $125/hour 181.5 $22,687.50
I Paralegal Fees $90/hour 29.4 $2,646.00
! Litigation $1,900.55
! Expenses
TOTAL 27,234.05
Request for Expert Fees
K&K requests $7,900 of incurred costs for its consulting and testifying expert
in addition to attorneys' fees (app. br. at 2). The government stipulated that it does not
dispute the reasonableness of the consultant expenses (gov't opp'n at 2-3).
Accordingly. we grant K&K's request for $7,900 for expert witness fees.
Travel and Miscellaneous Costs
K&K also requests lay witness travel expenses of$1,777.69 for its witness who
testified at the March 8, 2018 hearing in the underlying appeal (app. br. at 2). The
government responds that the claimed expenses are not reimbursable under the EAJA
and our precedent (gov't opp'n at 3). We have consistently held that fees oflay
witnesses are generally not reimbursable, and K&K has not responded to the
government's argument apparently abandoning this request. We thus deny this
portion ofK&K's application. See Optimum Servs., 17-1 BCA, 36,816 at 179,433
(citing Watsky Construction Co .. ASBCA No. 41541, 95-2 BCA ~ 27,889 at 139,137).
5
CONCLUSION
K&K has established that it is an eligible party entitled to fees under the EAJA.
Conversely, the government has not carried its burden to prove that its defense of this
appeal was substantially justified or that special circumstances exist precluding an
award. K&K's application for fees and costs under the EAJA is granted. K&K is
awarded fees and costs as follows:
I Category Amount
I Attorneys· and Paralegal Fees $25,333.50
l_1itigation Costs ------~~---
$1,900.55
/ Expert Fees & Related Costs $7,900.00
I TOTAL AWARD $35,134.05
Dated: May 16, 2019
J. REID PimUTY
Administrative Judge
Vice Chairman
Armed Services Board
of Contract Appeals
I concur
I ~
RICHARD SHACKLEFORD
Administrative Judge mistrative Judge
Acting Chairman cting Vice Chairman
Armed Services Board Armed Services Board
of Contract Appeals of Contract Appeals
6
I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals on an application for fees and other
expenses incurred in connection with ASBCA No. 61189, Appeal of K&K Industries,
Inc., rendered in accordance with 5 U.S.C. § 504.
Dated:
PAULLA K. GATES-LEWIS
Recorder, Armed Services
Board of Contract Appeals
7