King Aerospace, Inc. ( 2019 )


Menu:
  •                  ARMED SERVICES BOARD OF CONTRACT APPEALS
    Appeal of --                                    )
    )
    King Aerospace, Inc.                            )      
    ASBCA No. 60933
    )
    Under Contract No. W58RGZ-05-C-0302             )
    APPEARANCES FOR THE APPELLANT:                         Joanne Early, Esq.
    Colin G. Martin, Esq.
    Marshall J. Doke, Jr., Esq.
    Elliot Strader, Esq.
    Gardere Wynne Sewell LLP
    Dallas, TX
    APPEARANCES FOR THE GOVERNMENT:                        Raymond M. Saunders, Esq.
    Army Chief Trial Attorney
    Robert B. Neill, Esq.
    Trial Attorney
    OPINION BY ADMINISTRATIVE JUDGE MCILMAIL
    In 2016 the Board held a hearing and found entitlement for appellant, King
    Aerospace, Inc. (King), in this case involving a contract for aircraft maintenance and
    repair, and remanded to the parties for negotiation of quantum. King Aerospace, Inc.,
    
    ASBCA No. 57057
    , 
    16-1 BCA 1
     36,451 at 177,653. Familiarity with that decision is
    assumed. After another hearing, quantum is the issue. In accordance with the Board's
    internal operating procedures, neither this opinion nor the concurrence in result has
    precedential value except for those portions of the opinion in which we all explicitly
    agree. 1
    FINDINGS OF FACT
    King started performing the contract on September 1, 2005. King Aerospace, 
    16-1 BCA 1
     36,451 at 177,647. King knew then, or at the latest very soon after, that aircraft were
    in inferior condition and that the inventory was inadequate (see 2016 tr. 2/118-19, 160-61 ). 2
    
    Id. at 177,647-48
    . King could have tracked the actual cost of dealing with those conditions:
    its controller explained that King's accounting system "has the capability to set up a job cost
    1
    Chairman's note: Our internal procedures regarding the precedential value of
    concurrences in result have changed since the issuance of Lu/us Ostrich Ranch,
    
    ASBCA No. 59252
    , 
    2019 WL 989650
    .
    2
    References to the transcript of the 2016 entitlement hearing are denoted "2016 tr."; all
    others are references to the transcript of the 201 7 quantum hearing.
    code of additional work of some type or another" (see tr. 2/132, 160). The aircraft records are
    available, in boxes in El Paso, Texas (tr. 3/15-16; ex. 9R3). There are still "work cards" for
    these aircraft that describe maintenance or repair actions and how much time it took to
    perform those actions, from which it is possible to determine that work done was to correct a
    problem that the government caused (see tr. 2/221, 226-27).
    King's executive vice-president and (in 2005) controller confirmed that right from the
    start, King could have assigned people with clipboards to track the effect of those problems
    on King's costs; it just would have been complex (see 2016 tr. 2/118-20). Just before it
    started performance, King took "hundreds" of photographs of aircraft maintenance issues
    while looking over the shoulders of its predecessor-contractor (2016 tr. 3/86-87, 100, 200,
    tr. 5/73). King also separately tracked the cost of contract work (not at issue in this appeal)
    that was "over and above" routine contract work (2016 tr. 2/120); it just chose not to do so
    with respect to the work at issue here (tr. 2/161 ). Rather, to demonstrate damage, King
    offers a "measured mile" approach that does not measure productivity (see tr. 1/201-02).
    For its part, the government put on an expert in "evaluating causation and damages
    in the context of commercial and government aerospace and defense programs" who said
    that he "[wasn't] sure if there is another way to actually calculate the damages instead of
    [what he called King's] total cost method," but that under his measured mile approach
    (which compared the affected "El Paso Columbia" site with King's other, unaffected
    sites), King was owed, at most, $3,640,794 for the aircraft condition issue and nothing for
    the inventory issue, a total over $2. 5 million more than he thought before he heard the
    other hearing witnesses testify (tr. 3/60, 67, 74-83, 90-91, 110-13; ex. 10-11).
    The contracting officer received King's certified, $22.6 million claim on
    August 10, 2009. King Aerospace, 16-1 BCA ,r 36,451 at 177,647.
    DECISION
    The issue now is what King can recover "related to the contract's misrepresentation of
    the condition of the aircraft and to issues with government-furnished property" (that is, a
    deficient government-furnished inventory of aircraft parts, drawings, and records). King
    Aerospace, 16-1 BCA ,r 36,451 at 177,653. King must demonstrate that the government
    caused its increased costs. See Servidone Construction Corp. v. United States, 931 F .2d 860,
    861 (Fed. Cir. 1991).
    There is no dispute that King is owed $191,574 for request for equitable
    adjustment preparation costs (app. br., appendix; see gov't br. at 21, ,r 70), so that issue is
    out of the way.
    King says that it is owed $6,418,176 for having to deal with the condition of the
    aircraft, and $2,054,297 for having to deal with the condition of the government-furnished
    2
    I
    parts inventory (app. br., appendix). However, King does not demonstrate that the aircraft
    and inventory conditions increased its costs by those amounts. King wants us to infer from
    fluctuations in labor hours over time compared to a "measured mile" that it spent more than
    it should have because of the inferior condition of the aircraft and the deficient inventory
    (app. br. at 1, 10). But in our entitlement decision we warned that although "King was left
    holding a bag of maintenance and repair issues that were inconsistent with the aircraft
    condition represented in the contract" (we listed the handful of specific issues that King
    identified, like a "bent fuel tank high pressure ejector pump tube") "there is no evidence of a
    comprehensive inspection of the fleet contemporaneous with King taking over maintenance,
    so we do not know whether all the aircraft were in substandard condition when King took
    over, andtowhatextent." 16-1 BCA,r36,451 at 177,651 (emphasis added). That is still
    the case. We also found that "[a]t a minimum, problems with government-furnished
    property at times required King to 'redo' maintenance or repair work that it would have had
    to perform only once if all the listed items had been available and serviceable when King
    first attempted to perform the work," and that "when King took over ... the aircraft drawings
    and historical records were incomplete, and King spent time attempting to acquire drawings
    and other information required to assure the airworthiness of the aircraft." 
    Id.
     at 177 ,651-52
    (emphasis added). But what, specifically, had to be redone, what drawings and other
    information did King spend time attempting to acquire, and what time was actually spent on
    those efforts?
    This is the problem with King's quantum case: it paints with too broad a brush. By
    contrast, King could have tracked the actual costs of dealing with the specific maintenance
    and inventory problems that the government dumped on it. Given the facts stated above, it
    is not the case that King "could not have contemporaneously identified and quantified
    every discrete impact of each of the many thousands of deficient aircraft conditions and
    parts through change order accounting" or could not have "after the fact, waded through
    the hundreds of thousands of aircraft records" (app. br. at 30). First of all, how does King
    know that there were "many thousands of deficient aircraft conditions and parts" without .
    having engaged in some sort of contemporaneous tracking or after-the-fact records
    examination; does it want us to infer all that from a handful of discrete issues and its labor
    hour fluctuations? If so, that would be quite the inference, and such broad generalities and
    inferences are not enough. See Wunderlich Contracting Co. v. United States, 
    351 F.2d 956
    , 969 (Ct. Cl. 1965). By contrast, why didn't someone go through the work cards and
    other aircraft records in El Paso and at least summarize them to demonstrate causation?
    Moreover, just as King took hundreds of photographs of aircraft maintenance issues just
    before taking over performance, it presumably could have continued to do so while its
    own mechanics were working on the aircraft. And with respect to the parts inventory
    problems, the claim is that King had to "redo" maintenance work - that is, when it opened
    an airplane panel and saw that it needed a part, it would find the part unusable or missing
    from inventory, close the panel, and go through the whole process again when a suitable
    part showed up (see app. br. at 2, 18). Surely someone could have contemporaneously
    tracked that scenario; it sounds pretty unusual and discrete. Indeed, although King
    3
    separately tracked the cost of "over and above" work, it chose not to contemporaneously
    track the work at issue here.
    Of course, as we have noted already, King did identify a handful of specific
    aircraft deficiencies; presumably, then, it could have identified others. Was the purpose
    showing the handful to show only (in the words of one King witness (2016 tr. 5/86)) "the
    tip of the iceberg," and expect us to infer from that the size of that iceberg? No aircraft
    maintenance and repair expert testified that the handful of issues shown to us implied a
    problem of the scope that King says cost it $8 million. Of course, King is not interested
    in recovering for only the tip of the iceberg; it has not identified the specific cost of
    dealing with the handful of issues, not even as an alternative basis for recovery.
    Rather than identify specific deficiencies and cost them directly, King estimates that
    the aircraft and inventory conditions are responsible for most of its El Paso labor costs
    above its average labor costs during a "measured mile" that was unaffected by those
    conditions (see app. br. at 1, 10). That estimate is unconvincing. The "'measured mile'
    approach compares the productivity of an impacted period of the project with the
    productivity of an unimpacted period," Advanced Engineering & Planning Corp., ASBCA
    Nos. 53366, 54044, 05-1 BCA ,i 32,806 at 162,325, and King's "measured mile" does not
    measure productivity. However, based upon the testimony of the government's expert, it is
    reasonable to conclude that King spent $3,640,794 dealing with aircraft and inventory
    conditions that the government left it with in September 2005. Therefore the appeal is
    sustained in the amount of$3,832,368 ($3,640,794 plus $191,574), plus interest, under
    
    41 U.S.C. § 7109
    , from August 10, 2009, until the date of payment.
    Dated: April 15, 2019
    ``~
    ~CIL~
    Administrative Judge
    Armed Services Board
    of Contract Appeals
    I concur in result (see separate opinion)          I concur in result (see separate opinion)
    RICHARD SHACKLEFORD                                 J.RE    PROUTY
    Administrative Judge                                Administrative Judge
    Acting Chairman                                     Vice Chairman
    Armed Services Board                                Armed Services Board
    of Contract Appeals                                 of Contract Appeals
    4
    OPINION BY JUDGES PROUTY AND SHACKLEFORD
    CONCURRING IN RESULT
    We concur in the result in this appeal because we agree with the ultimate monetary
    outcome, but not in the brief analysis which leads to that outcome with respect to the
    requirements for a "measured mile," which we find inconsistent with the law. We also
    make factual findings that we find to be a necessary predicate to the decision's adoption
    of the government's expert's results.
    I.     The Approach Taken by King's Expert, Mr. Lochabay
    Judge Mcllmail's opinion rejects the work of King's expert, Mr. Donald Lochabay,
    by concluding that his measured mile approach did not measure productivity. Slip op.
    at 2, 4. That characterization is not the entire picture.
    In simplified terms, Mr. Lochabay used what was described as a modified
    version of the measured mile approach (app. supp. R4, tab 321 at 15-18; tr. 1/73-74).
    Mr. Lochabay's "measured mile" compared King's performance costs during times that
    King was struggling with the consequences of the.poorer-than-expected condition of the
    aircraft to the time after the aircraft had been brought up to the expected standard (the
    years 2012 and 2013 were the baseline of "good years" for labor costs; the years
    2009-2012 were used as the baseline of "good years" for the parts and materials costs)
    (app. supp. R4, tab 321 at 16-18, 24-25; tr. 1/76-78 (labor), 1/115-16 (parts and
    materials)). Of course, the demands on the aircraft were not the same every contract year
    and Mr. Lochabay's analysis understood this and used a metric in which he compared the
    annual amount of maintenance hours required per annual aircraft flight hours 3 between
    the "good" and the "bad" time periods (tr. 1/76-77). The comparison, Mr. Lochabay
    conceded, was not strictly of "productivity" as defined in the dictionary because
    productivity is "level of an input to the level of an output" and what was being measured
    in his measured mile was labor hours per earlier flight hours 4 (tr. 1/201-03). This
    approach did not appear to gamer any criticism from the government's expert who, as
    discussed more below, adopted some of Mr. Lochabay's bottom-line numbers for certain
    contract years.
    3   This comparison included a one-year "lag" from flight hours to maintenance hours.
    Thus, the metric was the number of maintenance hours in each year divided by the
    number of flight hours in the year immediately preceding it. (App. supp. R4,
    tab321 at 16n.16;tr.1/79)
    4
    Frankly, if Mr. Lochabay had intended to be pedantic about it, he could have
    re-arranged his metric and argued that he was measuring productivity in the sense
    that the output was something like "aircraft fit to fly per earlier flight hour" with
    the input being labor hours. That would have been a needlessly complicated and
    artificial construct, and it was unnecessary.
    5
    Mr. Lochabay capped his measured mile damages calculations for labor by what the
    total cost figures would have been for each year, i.e., when the measured mile-derived
    damages were higher than the damages that would have been calculated by a total cost
    damages method, he reduced the damages to the amount that King would have been
    entitled to under the total cost method (app. supp. R4, tab 321 at 19-20; tr. 3/70-72). The
    reason for this reduction was that he and King felt it would be difficult to prove that King
    would have been able to perform better than its contract baseline (tr. 1/82-83). Though this
    was a non-trivial aspect of Mr. Lochabay's methodology, reducing the amount of the claim
    substantially (see app. supp. R4, tab 321 at 18-19; tr. 1/82-83 ), it was not a basis for Judge
    Mcllmail's rejection of it and, it turns out, plays no role in the damages that we accept
    below since King does not argue that it should have been paid more than its expert
    requested (tr. 1/83 (King management agreed with damages caps)).
    II.    Mr. Lochabay's Methodology was Consistent with the Legally-Accepted
    Measured Mile Approach
    The analytic kernel of the measured mile approach, as set forth in the law, is to
    compare "the costs of performing work" on a contract during two different time periods:
    one being when all is well in contract performance; the other being a period when contract
    performance is hindered by some problem, presumably caused by the government. See
    US. Industries, Inc. v. Blake Construction Co., 671 F .2d 539, 54 7 (D.C. Cir. 1982)
    (leading case); see also Bay West, Inc., 
    ASBCA No. 54166
    , 
    07-1 BCA 133,569
    at 166,302 ("The measured mile approach provides a comparison of a production period
    that is impacted by a disruption with a production period that is not impacted" (citing
    cases)); W.G. Yates & Sons Construction Co., ASBCA Nos. 49398, 49399, 
    01-2 BCA 131,428
     at 155,210 (comparison of good period versus bad period). We followed US.
    Industries in our first opinion directly adopting the measured mile methodology, DANAC,
    Inc., 
    ASBCA No. 33394
    , 
    97-2 BCA 129,184
     at 145,153, and in our recent leading case on
    the subject, Optimum Services, Inc., 
    ASBCA No. 59952
    , 
    16-1 BCA 136,490
     at 177,822.
    Although we did reference "productivity" in Optimum Services, we did so because that
    was what was being measured in the expert's analysis in that appeal, not because
    rigidly-defined "productivity" is the only thing that may be subjected to measured mile
    analysis. See 16-1BCA136,490 at 177,822-23. The reference to productivity in the case
    cited by Judge Mcllmail's opinion, Advanced Engineering & Planning Corp., ASBCA
    Nos. 53366, 54044, 
    05-1 BCA 1
     32,806 at 162,325 (see slip op. at 5), did not constitute a
    requirement that any use of the measured mile be strictly limited to something tightly
    defined as "productivity," but merely described the typical operation of the measured mile.
    Indeed, although productivity is certainly a matter for many measured mile applications,
    the word is entirely absent in W.G. Yates & Sons, cited above, and was not the focus of
    US. Industries. We, in fact, discern no opinion in which we or our reviewing court ever
    engaged in a deep examination of the meaning of the word, "productivity" for purposes of
    applying the measured mile; instead, a review of the cases cited above show that
    6
    productivity is more or less a proxy for measuring how much more difficult or costly
    contract performance has become as the consequence of a contract breach.
    Thus, the approach running through all of the measured mile opinions, i.e.,
    comparing the costs of performance during affected periods to unaffected periods, is
    precisely the one taken by Mr. Lochabay here. Neither the government's arguments in
    its brief nor Judge Mcllmail's opinion give us any reason to use the semantic difference
    between dictionary-defined "productivity" and the analytic approach taken by
    Mr. Lochabay as a basis for rejecting his methodology. Accordingly, we conclude that
    Mr. Lochabay utilized an acceptable measured mile methodology. That does not mean,
    however, that King will get all that it seeks.
    III.   We Accept the Government's Substantive Critiques of Mr. Lochabay's
    Analysis
    The government's expert witness, Mr. Timothy Overman, did not disagree with
    the use of a measured mile, but did explain that the data did not support a finding that
    King was adversely impacted for parts and materials or that the labor impacts extended as
    far as King alleged. With respect to parts and materials, Mr. Overman testified that he
    saw no basis for awarding King damages because the data showed only one year where
    the parts and materials costs were above King's pre-bid estimates, 5 and because the parts
    and materials trends were "all over the place," thus they did not support a finding of
    particular costs being caused by the contract breach6 (tr. 3/76-77, 3/81 ).
    Mr. Overman also opined that the data provided by King and Mr. Lochabay only
    supported a finding that the substandard condition of the aircraft affected labor costs for
    three years of contract performance. Those three years were 2009, 2010, and 2011,
    because those were the years that King had increased its parts inventory and incorporated
    them into the aircraft to bring them up to standard. (Tr. 3/79-80) After hearing the
    testimony from King's witnesses at the hearing, Mr. Overman was inclined to agree with
    the increased labor costs set forth in Mr. Lochabay's expert report (the measured mile
    5   To be clear, no legal barrier prevents a contractor from recovering expenses from the
    government when its costs are lower than it once anticipated, so long as the
    government's actions demonstrably caused the costs to be higher than they would
    have otherwise been. Nevertheless, comparison of expected costs to actuals
    certainly may inform our consideration of the analysis. Indeed, this appears to
    have been King's motivation for capping its labor costs by the total cost method,
    which it apparently did not do for the materials and parts costs.
    6   This critique fits with the inconsistency of the years that Mr. Lochabay chooses for his
    base years for the parts and materials costs (2009-2012, see tr. 1/115-16) with those
    he chose for labor cost base years (the years 2012 and 2013, see tr. 1/76-78).
    Although we recognize that they need not exactly match, in these circumstances,
    something is amiss.
    7
    analysis 7) for those years as the maximum damages to which King should be entitled (id.).
    The amount of increased labor costs asserted in Mr. Lochabay's report for those three years
    sums to $3,640,794 (as marked up with overhead costs by Mr. Lochabay) (ex. 11). Under
    examination by Judge Mcllmail during the hearing, Mr. Overman agreed with the
    proposition that the $3,640,794 for the three years as set forth in Exhibit 11 constituted his
    "bottom line conclusions" for the damages (tr. 3/85).
    We agree with Mr. Overman's analysis. Although we do not join Judge Mcllmail's
    critique of King for its failure to track each and every extra hour of work or expense that its
    employees attribute to the bad condition of the aircraft (see slip op. at 3), 8 the measured mile
    analysis, like any damages model, must be grounded upon reality. Cf Optimum Services,
    16-1 BCA ,i 36,490 at 177,824-26 (adjusting measured mile to take into account
    circumstances in the field); Bay West, 07-1 BCA ,i 33,569 at 166,302-03 (same). Moreover,
    the burden of proof is on King to prove its damages. See Wunderlich Contracting Co. v.
    United States, 
    351 F.2d 956
    ,968 (Ct. Cl. 1965) (citing cases). Since, as explained by
    Mr. Overman, the data is inconclusive with respect to the parts and materials costs as well as
    for labor costs for the years beyond 2009-2011, we hold that King has not met its burden of
    proof for damages beyond the $3,640,794 for labor costs and the $191,574 in costs for REA
    preparation accepted by Judge Mcllmail with which we do not quibble.
    7
    The parties discussed Mr. Overman's analysis, adopting Mr. Lochabay's approach for
    base years, as a "measured mile" analysis (see colloquy tr. 3/94-95).
    Judge Mcllmail's opinion adopts Mr. Overman's measured mile analysis (see slip
    op. at 4), but does not reconcile this adoption with the fact that it rests on
    precisely the methodology (for the covered years) that Mr. Lochabay used and
    that Judge Mcllmail summarily rejects earlier in his opinion.
    8   It is a "well-established principle" that damages need not be proved to a mathematical
    certainty so long as we are provided a reasonable basis for their calculation.
    Optimum Services, 16-1 BCA ,i 36,490 at 177,823 (citations omitted).
    8
    CONCLUSION
    Although we disagree with much of his analysis as discussed above, we concur
    with the bottom-line conclusion by Judge Mcllmail that the appeal should be sustained in
    the amount of$3,832,368 plus interest in accordance with 
    41 U.S.C. § 7109
     from August
    10, 2009 until the date of payment.
    Dated: April 15, 2019
    RICHARD SHACKLEFORD                               J. REID PROUTY
    Administrative Judge                              Administrative Judge
    Acting Chairman                                   Vice Chairman
    Armed Services Board                              Armed Services Board
    of Contract Appeals                               of Contract Appeals
    I certify that the foregoing is a true copy of the Opinion and Decision of the
    Armed Services Board of Contract Appeals in 
    ASBCA No. 60933
    , Appeal of King
    Aerospace, Inc., rendered in conformance with the Board's Charter.
    Dated:
    JEFFREY D. GARDIN
    Recorder, Armed Services
    Board of Contract Appeals
    9
    

Document Info

Docket Number: ASBCA No. 60933

Judges: McIlmail

Filed Date: 4/15/2019

Precedential Status: Precedential

Modified Date: 5/6/2019