Scottsdale Ins. Co. v. Altman Mgmt. Co. ( 2021 )


Menu:
  •                          NOT RECOMMENDED FOR PUBLICATION
    File Name: 21a0016n.06
    No. 20-1361
    UNITED STATES COURT OF APPEALS
    FOR THE SIXTH CIRCUIT
    FILED
    SCOTTSDALE INSURANCE COMPANY,                            )                      Jan 08, 2021
    )                  DEBORAH S. HUNT, Clerk
    Plaintiff-Appellant,                              )
    )
    v.                                                       )      ON APPEAL FROM THE
    )      UNITED STATES DISTRICT
    ALTMAN MANAGEMENT COMPANY,                               )      COURT FOR THE EASTERN
    )      DISTRICT OF MICHIGAN
    Defendant-Appellee.                               )
    )
    Before: KETHLEDGE, THAPAR, and READLER, Circuit Judges.
    KETHLEDGE, Circuit Judge. The district court dismissed under Civil Rule 12(b)(6)
    Scottsdale Insurance Company’s complaint against Altman Management Company. Scottsdale
    appeals and argues that the court improperly delegated a dispute about insurance coverage to
    appraisers. We reject Scottsdale’s argument and affirm.
    Altman managed an apartment building and bought a policy for excess insurance from
    Scottsdale. The policy covered all “direct physical loss or damage” to the building, including rents
    or business lost because of the damage. The policy covered losses or damages only during a
    “recovery period,” which began on the date of any damage and continued for as long as “would
    be required with the exercise of due diligence and dispatch” to repair the building. The policy also
    provided that appraisers could resolve any dispute regarding “the amount of loss.” In that
    circumstance both Scottsdale and Altman each would choose one appraiser for an appraisal panel,
    which would estimate the loss and issue an award.
    No. 20-1361, Scottsdale Ins. Co. v. Altman Mgmt. Co.
    In July 2017, a fire engulfed the building. The damage required extensive repairs and
    forced out all the building’s tenants. Altman notified Scottsdale of the fire and submitted claims
    for lost rents and the cash value of the repairs. By March 2019, Scottsdale had paid more than
    $1.5 million for repairs and lost rents. That month, Scottsdale notified Altman in writing that the
    “recovery period” for the building would close in April 2019, because in Scottsdale’s view Altman
    had unreasonably delayed the commencement of repairs. Altman responded that it had been
    diligent and that Scottsdale’s own delay in accepting estimates for the cost of repairs had caused
    any construction delays. To resolve the dispute, Altman invoked the policy’s appraisal provision
    and demanded that appraisers decide the length of the recovery period.
    Scottsdale then brought this suit, seeking a declaration that whether Scottsdale’s alleged
    delay extended Altman’s recovery period under the policy was a question of law for the court
    rather than the appraisers. Altman for its part moved to dismiss the complaint under Rule 12(b)(6).
    The district court rendered a split decision. The court held that whether Scottsdale’s alleged delay
    could extend the recovery period was a question of law; and the court proceeded to answer that
    question, by saying that, yes, under the policy’s terms, unreasonable delay by Scottsdale could
    extend the recovery period. But the court also held that whether either party had in fact
    unreasonably delayed the start of the project was a “factual question about damages” for the
    appraisers to decide. The court therefore granted Altman’s motion to dismiss.
    We review that decision de novo. See Valassis Commc’ns, Inc. v. Aetna Cas. & Sur. Co.,
    
    97 F.3d 870
    , 873 (6th Cir. 1996). The parties agree that Michigan law governs interpretation of
    the policy’s terms.
    We affirm substantially for the reasons stated in the district court’s careful opinion. The
    district court has already interpreted the policy’s terms. The remaining task is to determine the
    2
    No. 20-1361, Scottsdale Ins. Co. v. Altman Mgmt. Co.
    facts to which to apply them. And in Michigan appraisers resolve (at least in the first instance)
    any factual disputes about the amount of an insured’s loss. See Auto-Owners Ins. Co. v. Kwaiser,
    
    476 N.W. 2d 467
    , 469 (Mich. Ct. App. 1991). The claim here is that Scottsdale unreasonably
    delayed payments for the building repairs, which delayed the start of the repair project, which in
    turn delayed the tenants’ return—thereby increasing Altman’s losses. Whether an insurer has
    unreasonably delayed payment is a question of fact for the appraisers. See Bronson Methodist
    Hosp. v. Auto-Owners Ins. Co., 
    814 N.W. 2d 670
    , 680 (Mich. Ct. App. 2012). So too, plainly
    enough, is whether the delay in payments in fact delayed completion of the repair project. The
    district court was therefore correct to bow out in favor of the appraisers.
    The district court’s judgment is affirmed.
    3
    

Document Info

Docket Number: 20-1361

Filed Date: 1/8/2021

Precedential Status: Non-Precedential

Modified Date: 1/8/2021