Gilbane Federal v. United Infrastructure Projects ( 2019 )


Menu:
  •                                                                             FILED
    NOT FOR PUBLICATION
    JUN 25 2019
    UNITED STATES COURT OF APPEALS                       MOLLY C. DWYER, CLERK
    U.S. COURT OF APPEALS
    FOR THE NINTH CIRCUIT
    GILBANE FEDERAL, FKA ITSI Gilbane                No.   17-16814
    Company,
    D.C. No. 3:14-cv-03254-VC
    Plaintiff-counter-
    defendant-Appellee,
    MEMORANDUM*
    v.
    UNITED INFRASTRUCTURE
    PROJECTS FZCO, a foreign corporation;
    UNITED INFRASTRUCTURE
    PROJECTS SAL (OFFSHORE)
    LEBANON, a foreign corporation,
    Defendants-counter-
    claimants-Appellants.
    Appeal from the United States District Court
    for the Northern District of California
    Vince Chhabria, District Judge, Presiding
    Argued and Submitted June 13, 2019
    San Francisco, California
    *
    This disposition is not appropriate for publication and is not precedent
    except as provided by Ninth Circuit Rule 36-3.
    Before: GOULD and IKUTA, Circuit Judges, and PEARSON,** District Judge.
    United Infrastructure Projects FZCO and United Infrastructure Projects
    Lebanon (collectively “UIP”) appeal the district court’s ruling that Gilbane Federal
    was entitled to terminate UIP for a default, as defined in the Federal Acquisition
    Regulation 52.249-10, 48 C.F.R. § 52.249-10.1 We have jurisdiction under 28
    U.S.C. § 1291.
    We first reject UIP’s arguments that the original contract deadline of
    December 4, 2014, should be extended due to excusable delays. See 48 C.F.R.
    § 52.249-10(b). The district court did not clearly err in finding that UIP was not
    entitled to an extension of the deadline due to Kinney allegedly being a sole source
    provider. The record supports the district court’s finding that UIP refused to deal
    with Kinney because of Kinney’s prices, rather than due to UIP’s concern about
    ethical improprieties. Further, the district court did not clearly err in rejecting
    UIP’s argument that it was entitled to an extension of the deadline under United
    States v. Spearin, 
    248 U.S. 132
    (1918), due to the Navy’s requirement that the
    **
    The Honorable Benita Y. Pearson, United States District Judge for the
    Northern District of Ohio, sitting by designation.
    1
    We analyze this issue under federal law because both parties assume that
    federal law applies to the interpretation of the contract’s definition of default. See
    Glickman v. Collins, 
    13 Cal. 3d 852
    , 857 n.1 (1975), disapproved of on other
    grounds by In re Marriage of Dawley, 
    17 Cal. 3d 342
    (1976); Wells v. Wells, 
    74 Cal. App. 2d 449
    , 453 (1946).
    2
    switchgear include a fourth position indicator. Although this was subsequently
    determined to be an erroneous requirement, Gilbane did not know that when it
    terminated the contract. See McDonnell Douglas Corp. v. United States, 
    323 F.3d 1006
    , 1019 (Fed. Cir. 2003) (courts consider only what the parties knew at the time
    of termination). The district court did not clearly err when it determined that, at
    the time of termination, Gilbane knew only that UIP refused to contract with
    providers who could comply with the fourth position indicator requirement, and
    the requirement remained in place as of the date Gilbane terminated the contract.
    Lastly, the district court did not clearly err in finding that programming was not on
    the project’s critical path. Although Gilbane subsequently told the Navy that
    programming was a critical path item, the district court’s conclusion that this
    statement was false was not clearly erroneous.
    Because UIP was not entitled to an extension of the contract deadline for
    excusable delays, the district court did not err in determining that Gilbane was
    justifiably insecure that there was “no reasonable likelihood that the [contractor]
    could perform the entire contract effort within the time remaining for contract
    performance,” namely December 4, 2014. Lisbon Contractors, Inc. v. United
    States, 
    828 F.2d 759
    , 765 (Fed. Cir. 1987). The record establishes that the
    switchgear was on the project’s critical path, including evidence that the Navy,
    3
    UIP, and Gilbane all identified the switchgear as such a critical path item.
    Because the switchgear had a lead time of six to nine months for delivery, and UIP
    had failed to submit a compliant switchgear submittal that met the Navy’s
    specifications as of June 2014, Gilbane was justified in believing there was no
    reasonable likelihood that UIP could complete the contract by December 4, 2014.
    
    Id. Because the
    record clearly establishes that UIP could not complete the work
    within the required time, Gilbane was not required to complete a time impact
    analysis before reaching such a conclusion.2 Cf. 
    id. AFFIRMED. 2
           Because we affirm on this ground, we need not consider Gilbane’s
    argument that UIP has waived the right to argue that it is entitled to an excusable
    delay under Greg Opinski Construction, Inc. v. City of Oakdale, 
    199 Cal. App. 4th 1107
    (2011).
    4