Yacht West, Ltd. v. Christensen Shipyards, Ltd. , 464 F. App'x 626 ( 2011 )

NOT FOR PUBLICATION
UNITED STATES COURT OF APPEALS FILED
FOR THE NINTH CIRCUIT DEC 29 2011
MOLLY C. DWYER, CLERK
U.S. COURT OF APPEALS
YACHT WEST, LTD., a Cayman Islands No. 10-35382
company,
D.C. No. 3:07-cv-01547-KI
Plaintiff - Appellee,
v. MEMORANDUM*
CHRISTENSEN SHIPYARDS, LTD., a
Washington corporation; DAVID H.
CHRISTENSEN,
Defendants - Appellants.
YACHT WEST, LTD., a Cayman Islands No. 10-35383
company,
D.C. No. 3:07-cv-01547-KI
Plaintiff - Appellant,
v.
CHRISTENSEN SHIPYARDS, LTD., a
Washington corporation; DAVID H.
CHRISTENSEN,
Defendants - Appellees.
*
This disposition is not appropriate for publication and is not precedent
except as provided by 9th Cir. R. 36-3.
Appeal from the United States District Court
for the District of Oregon
Garr M. King, Senior District Judge, Presiding
Argued and Submitted November 14, 2011
Portland, Oregon
Before: FISHER, PAEZ, and CLIFTON, Circuit Judges.
We consider here the cross-appeals by Christensen Shipyards, Ltd. and
Yacht West, Ltd. from the district court’s post-trial order granting in part and
denying in part the parties’ motions for judgment as a matter of law under Federal
Rule of Civil Procedure 50(b). We have jurisdiction under 28 U.S.C. § 1291, and
affirm.
I. Christensen’s Rule 50(b) Motion
A jury’s verdict of compensatory damages is reviewed for substantial
evidence. In re Exxon Valdez, 270 F.3d 1215, 1247–48 (9th Cir. 2001). It must be
affirmed “unless the amount is grossly excessive or monstrous, clearly not
supported by the evidence, or based only on speculation or guesswork.” Del Monte
Dunes at Monterey, Ltd. v. City of Monterey, 95 F.3d 1422, 1435 (9th Cir. 1996).
In calculating damages, a factfinder is entitled to “make a reasonable
inference of damages from the facts adduced.” Holland Livestock Ranch v. United
States, 655 F.2d 1002, 1006 (9th Cir. 1981).
2
1. Substantial evidence supported the jury’s award of $2.6 million to Yacht
West for the nonconforming exhaust system. Yacht West’s expert testified that his
conceptual analysis showed that it was possible to reroute the exhaust system to
discharge at the rear of the boat for $2.6 million, and that a variety of specific
implementations of his general concept were feasible.
2. Substantial evidence did not support the jury’s award of $2 million to Yacht
West for a structural defect in the form of either a vibration or weight in excess of
the contract requirements. A Yacht West expert opined that the vibration was
“hull-springing vibration” caused by a “lack of stiffness in the structure,” but
admitted that he could not tell the jury how the problem could be corrected because
“it requires further testing.” Another Yacht West expert testified that it would cost
$4 million “to repair the structural inadequacy of the vessel,” but that it would first
entail “a very substantial effort . . . to find out why the boat is vibrating the way
that it is.”
Because neither Yacht West expert could identify the source of the vibration
or specify how to fix it, the jury was required to impermissibly speculate about the
provenance and redressability of the vibration. The district court therefore correctly
granted Christensen’s Rule 50(b) motion on this issue.
3
II. Yacht West’s Rule 50(b)Motion
1. Substantial evidence supported the jury’s award of $1,674,242 to
Christensen for delay damages not stemming from unabsorbed overhead.
Interpretation of an integrated agreement “is to be determined by the trier of fact if
it depends on . . . a choice among reasonable inferences to be drawn from extrinsic
evidence.” Berg v. Hudesman, 801 P.2d 222, 229 (Wash. 1990) (quoting
Restatement (Second) of Contracts § 212 (1981)) (internal quotation marks
omitted). The parties presented testimony to the jury about the meaning of the
contract. The jury received a general instruction and special verdict form, and
neither party objected that the jury instructions or special verdict were improper.
Further, Christensen’s expert testified that Yacht West and its contractors and
suppliers delayed construction by failing to provide necessary information and
materials, and that these delays subsumed any delays caused by Christensen.
Substantial evidence supported the jury’s finding that the contract permitted an
award for delay damages and the amount of delay damages it awarded.
2. “The raison d’etre of Eichleay requires at least some element of uncertainty
arising from suspension, disruption or delay of contract performance. Such delays
are sudden, sporadic and of uncertain duration. As a result, it is impractical for the
contractor to take on other work during these delays.” C.B.C. Enters. v. United
4
States, 978 F.2d 669, 675 (Fed. Cir. 1992). In Washington, unabsorbed overhead is
recoverable “if the delay prevented the contractor from obtaining contracts during
the delay period that would have ‘absorbed’ the ongoing overhead expense.” Golf
Landscaping, Inc. v. Century Constr. Co., 696 P.2d 590, 593 (Wash. Ct. App.
1984). Christensen’s workforce was never placed on standby during the
construction of the Party Girl, and there is no evidence that the delays prevented
Christensen from taking on new contracts. Christensen is therefore precluded from
obtaining damages for unabsorbed overhead.
AFFIRMED.
5
FILED
DEC 29 2011
Yacht West, Ltd. v. Christensen Shipyards, Ltd., No. 10-35382
MOLLY C. DWYER, CLERK
U.S. COURT OF APPEALS
RAYMOND C. FISHER, Circuit Judge, concurring in part and dissenting in part:
I concur in all but part I.2 of the memorandum disposition, from which I
respectfully dissent. I would hold that substantial evidence supports the jury’s
award of $2 million to Yacht West for the structural defect. All parties agree that
the yacht is overweight, that it suffers from a vibration, that the vibration is
structural and hull-related and that further evaluating and remedying the defect will
be extremely costly. Yacht West’s expert testified that the defect would cost at
least $4 million to repair, and Christensen did not offer a repair estimate of its own
to refute that testimony. There was also testimony that the structural defect
affected the market value of the yacht, which in any event is self-evident, as well as
the uses to which the yacht could safely be put. That the jury awarded Yacht West
only half of what it requested further indicates that the jury exercised its discretion.
It is true that Yacht West’s experts could not isolate the precise source of the
problem or set out a specific plan for repair without further evaluation, but I do not
believe Yacht West was required to tear the vessel apart to establish an entitlement
to damages. See Holland Livestock Ranch v. United States, 655 F.2d 1002, 1006
(9th Cir. 1981) (“Once injury has been proven, the fact that damages are not
susceptible to precise measurement does not preclude recovery”). I accordingly
dissent from part I.2 of the disposition.