Fulton County, Georgia v. Soco Contracting Company, Inc. ( 2017 )

FOURTH DIVISION
DILLARD, C. J.,
RAY, P. J., and SELF, J.
NOTICE: Motions for reconsideration must be
physically received in our clerk’s office within ten
days of the date of decision to be deemed timely filed.
http://www.gaappeals.us/rules
October 25, 2017
In the Court of Appeals of Georgia
A17A1001. FULTON COUNTY, GEORGIA v. SOCO
CONTRACTING COMPANY, INC.
RAY, Presiding Judge.
In 2013, Fulton County (the “County”) and SOCO Construction Company, Inc.
(“SOCO”) executed a written contract for the construction of a cultural center. The
contract was approved by the Fulton County Board of Commissioners. As a result of
several delays, including those caused by change orders, inclement weather, and the
shutdown of the federal government, the scope of the work and time line was altered.
SOCO filed the instant complaint against the County for, inter alia, breach of
contract and bad faith performance of the contract. SOCO also sought attorney fees
and injunctive relief. Soco and the County filed cross-motions for summary judgment
on all claims. The trial court granted summary judgment in favor of SOCO and
against the County.1 In the same order, the trial court also denied the County’s motion
for reconsideration of its denial of the County’s motion to withdraw admissions.
We reverse the trial court’s denial of the County’s motion for summary
judgment on the grounds that any claims arising from unwritten change orders are
barred under the doctrine of sovereign immunity. Further, we affirm in part and
reverse in part the trial court’s order denying the County’s motion for reconsideration
of its motion to withdraw admissions. Finally, we vacate and remand the trial court’s
ruling on attorney fees.
To prevail at summary judgment, the moving party must demonstrate
that there is no genuine issue of material fact and that the undisputed
facts, viewed in the light most favorable to the nonmoving party,
warrant judgment as a matter of law. . . . We conduct a de novo review
a trial court’s grant of summary judgment.
(Citations and punctuation omitted.) Bright v. Sandstone Hospitality, LLC, 327 Ga.
App. 157, 157-158 (755 SE2d 899) (2014).
In May 2013, the County and SOCO executed a written contract for the
construction of the Aviation Community Cultural Center near the Fulton County
1
The Association of County Commissioners of Georgia has filed an amicus
curiae brief in this case.
2
Airport. The contract specified that the work should be completed within 287 days
from the County’s issuance of the notice to proceed or the day the work began,
whichever came first, with that period to be increased by change order due to changes
in the scope of work, or upon the occurrence of other delays or events not the fault
of the contractor. Section 00700-87A of the “General Conditions” portion of the
contract provides that
[a] Change Order is a written order to the Contractor signed to show the
approval and authorization of the County, issued after execution of the
Contract, authorizing a change in the Work and/or an adjustment in the
Contract Sum or the Contract Time. Change Orders shall be written
using forms designated by the County with Contractor providing
supporting documentation as required by the Construction Manager. The
Contract Sum and the Contract Time may be changed only by approved
Change Order pursuant to Fulton County Procedure 800-6. . . . A
Change Order signed by the Contractor indicates the Contractor’s
agreement therewith, including the adjustment in either or both of the
Contract Sum or the Contract Time.
(Emphasis supplied.) It also provides that “[t]he County, without invalidating the
Contract, may order changes in the Work within the general scope of the Contract as
defined herein.”
3
Fulton County Policy and Procedure 800-6 (“Procedure 800-6”), titled
“Procedures for Handling Change Orders,” provides that “except as otherwise
provided . . . , change orders shall be effected only through a written, bilateral
agreement (Modification) between the County, acting through its Board of
Commissioners, and the contractor.” Procedure 800-6 allows for the authorization of
change orders when needed, inter alia, to correct deficiencies in design or
construction documents provided by architects or engineers, to remedy concealed
conditions, abnormal inclement weather, and owner-requested changes within the
scope of the contract. It further provides that the proper “Change Order Procedure”
requires the “[a]greement between County and contractor for change [to be] clearly
defined in a Written Modification,” signed by the Contractor and approved by the
Board of Commissioners. Section G (2) of Procedure 800-6, captioned “Extraordinary
Circumstances,” provides that the “County Manager is authorized to approve change
orders regardless of the amount when due to extraordinary circumstances, work must
be implemented before the Board of Commissioners can act.” Such extraordinary
circumstances include a “[l]oss of substantial resources due to delay, including delay
to critical path schedule.”
4
SOCO began work on the cultural center on May 29, 2013. However, SOCO
did not achieve substantial completion of the project until May 29, 2014, beyond the
time anticipated in the contract. SOCO contends that the construction of the cultural
center was delayed due to, inter alia, adverse weather conditions, delays caused by
the County’s design for the cultural center, the County’s unwillingness to make
timely decisions on changes, and the impact that the federal government’s shut down
had on obtaining certain permits. As a result of these issues, the County ordered
changes to SOCO’s scope of work, and the County’s program manager listed more
than 30 change orders in its September 5, 2014, change order evaluation log.
However, SOCO does not provide citations to the record, nor can we find any,
indicating that the change orders were executed through bilateral, written agreements.
SOCO admits that the County never issued a change order extending the contract
time, despite these delays. Further, the County did not release its Certificate of
Substantial Completion until February 17, 2015, and withheld release of certain
retainage fees until January 21, 2015.
SOCO then filed suit against the County for breach of contract and bad faith.
It also sought attorney fees and injunctive relief. The County answered. On June 30,
2015, SOCO sent its first Request for Admissions to the County by hand-delivery.
5
The County did not respond until on August 3, 2015, 33 days later. Because the
County’s response to the Requests for Admissions was served to SOCO more than
30 days after service of the request, the Requests for Admissions were deemed
admitted pursuant to OCGA § 9-11-36 (a) (2). See Adewumi v. Amelia Grove/Ashland
Park Homeowners Assoc., Inc., 337 Ga. App. 275, 277 (2) (787 SE2d 761) (2016).
On April 26, 2016, the County filed a motion to withdraw the Requests for
Admissions. The County attached an affidavit of Tommy Walton, a paralegal with the
Fulton County Attorney’s Office, who averrred that the responses to the Request for
Admissions were late due to an administrative error. The County also alleged that it
mistakenly admitted SOCO’s Request for Admission #37 that it was liable for “all
damages alleged by SOCO in its Complaint.” The trial court denied the motion to
withdraw. The trial court also denied the County’s petition for interlocutory review,
and the County filed its motion for reconsideration of the trial court’s denial of the
motion to withdraw admissions.
On June 27, 2016, the County moved for summary judgment on the grounds
that the trial court lacked subject matter jurisdiction because of sovereign immunity.
In its final order, the trial court, inter alia, denied the motion for reconsideration and
6
denied the County’s motion for summary judgment. The County appeals from that
order.
1. The County argues that the trial court erred in denying its motion for
summary judgment because the trial court lacked subject matter jurisdiction due to
the applicability of sovereign immunity. The County argues that although the State
has waived sovereign immunity for the breach of any written contract, it did not
waive immunity for causes of action arising from modifications to the written contract
that failed to follow the written change order policy outlined in the contract. We
agree.2
In Georgia, the doctrine of sovereign immunity has constitutional status and
may be waived only by an act of the General Assembly or by the Constitution itself.
Ga. Dept. of Corrections v. Couch, 295 Ga. 469, 472 (2) (759 SE2d 804) (2014). The
Georgia Constitution addresses the waiver of the State’s immunity of liability for
breach of contract as follows:
(c) The [S]tate’s defense of sovereign immunity is hereby waived as to
any action ex contractu for the breach of any written contract now
2
While we find that the County was entitled to summary judgment on the
claims relating to modifications to the contract which were not properly executed, we
note that there were claims presented related to the original contact.
7
existing or hereafter entered into by the [S]tate or its departments and
agencies. . . .
(e) Except as specifically provided in this Paragraph, sovereign
immunity extends to the [S]tate and all of its departments and agencies.
The sovereign immunity of the [S]tate and its departments and agencies
can only be waived by an Act of the General Assembly which
specifically provides that sovereign immunity is thereby waived and the
extent of such waiver.
Ga. Const., Art. I, Sec. II, Par. IX (c) and (e). “The sweep of sovereign immunity
under the Georgia Constitution is broad, [and its] plain and ambiguous text . . . shows
that only the General Assembly has the authority to waive the State’s sovereign
immunity.” (Citation omitted.) Olvera v. Univ. Sys. of Ga.’s Bd. of Regents, 298 Ga.
425, 426 (782 SE2d 436) (2016).
“[S]overeign immunity is a threshold issue that the trial court [is] required to
address before reaching the merits of any other argument.” (Footnote omitted.)
Albertson v. City of Jesup, 312 Ga.App. 246, 248 (1) (718 SE2d 4) (2011). It is
axiomatic that “[t]he party seeking to benefit from the waiver of sovereign immunity
bears the burden of proving such waiver.” (Citations omitted.) Bd. of Regents of the
Univ. Sys. of Ga. v. Doe, 278 Ga.App. 878, 881(1) (630 SE2d 85) (2006). “Whether
8
sovereign immunity has been waived under the undisputed facts of this case is a
question of law, and this Court’s review is de novo.” (Citation omitted.) Ga. Dept. of
Labor v. RTT Assocs., Inc., 299 Ga. 78, 81 (1) (786 SE2d 840) (2016).
In the instant case, the County argues that although it did have a written
contract with SOCO, it did not waive its defense of sovereign immunity as to any
claims arising from modifications to that contract that did not follow the protocol for
written change orders as outlined in the contract and in Fulton Procedure 800-6. The
County cites to RTT Assocs. Inc., supra at 82-83 (2), for the assertion that the limited
waiver of sovereign immunity for actions ex contractu applies only to written
agreements, and may not be extended by oral directives or course of conduct. We
agree.
In RTT Assocs., Inc., supra, the Department of Labor (“DOL”) executed a
written contract with software vendor, RTT, that by its terms expired on June 30,
2012. The written contract also specified that amendments must be made in writing
and fully executed by both parties. Id. at 78-79. The DOL executed two internal
project change request documents extending the scope and timeline of the project.
However, the change requests were not executed by RTT, and no written amendment
to the contract was executed by either party to extend the expiration of the contract
9
or modify other contract terms. Id. at 79. After the DOL refused to compensate RTT
for work performed after the contract expired, RTT claimed that the contract had been
extended by certain internal writings of the department and by the parties’ course of
conduct. Id. at 79. Our Supreme Court held that “even if . . . DOL and RTT waived,
through their course of conduct, the provision that the contract could be amended
only in writing and similarly waived or extended the required completion date, this
conduct could not have waived DOL’s sovereign immunity.” Id. at 82 (2). The Court
explained that although
private parties . . . may be able to modify and extend written contracts
by manifesting their intent to do so even without a written agreement,
the enforceability of a contract against the [S]tate is governed by the
Constitution and by statute. . . . General rules of contract law that might
otherwise support a claim for breach of contract damages between
private parties, however, will not support a claim against the [S]tate or
one of its agencies if the contract is not in writing so as to trigger the
waiver of sovereign immunity.
(Citations omitted.) Id. at 82 (2).
Unlike the written contract in RTT Assocs., Inc., supra, the written contract in
the instant case provides a procedure for obtaining a written Change Order to amend
the contract, and that procedure provides a method by which parties can bypass the
10
necessity for a written Change Order in the event “extraordinary circumstances”
warrant it. The trial court in its motion denying the County’s motion for summary
judgment found that the parties complied with Fulton County Procedure 800-6 G (2)
because the changed work ordered by County administrators were necessary to avoid
delay to the “critical path schedule of the work[,]” and thus constituted “extraordinary
circumstances” which invoked an exception to the written change order requirement
under Fulton Procedure 800-6 G (2), as incorporated into the parties’ contract.
However, Fulton Procedure 800-6 G (2), captioned “Extraordinary
Circumstances[,]” provides a specific procedure that must be followed in order to
bypass the contractual requirement that any changes be made by a written Change
Order. Specifically, Fulton Procedure 800-6 G (2) provides that “[t]he County
Manager is authorized to approve change orders regardless of the amount when due
to extraordinary circumstances, work must be implemented before the Board of
Commissioners can act.” These extraordinary circumstances include, inter alia, when
immediate action must be taken to protect the County’s interest due to a threat of
“[l]oss of substantial resources due to delay, including delay to critical path
schedule.” Fulton Procedure 800-6G (2) (d) provides that “[a]t a minimum, the
following procedures must be observed” in the event of such an extraordinary
11
circumstance: (1) the contractor must execute a “written contract Modification” that
describes the scope of the work and its cost; (2) the department head shall obtain
approval of the purchasing agent; and (3) the work may proceed upon approval of the
County Manager, which includes a sign-off sheet, and the County Manager shall
place the change order on the Board of Commissioners’ agenda.
In the instant case, SOCO argues that the County ordered more than 30
modifications to the existing budget and timeline under the Contract. However,
SOCO does not allege that they followed the procedure outlined under the
“Extraordinary Circumstances” provision in Fulton Procedure 800-6 G (2) (d). SOCO
does not allege, and provides no citations to the record, that it provided a written
contract modification describing the scope of the work or its cost, that the purchasing
agent approved the changes, or that the County Manager approved the changes or the
sign-off sheet before work commenced. Indeed, SOCO relies heavily on the
contentions deemed admitted as a matter of law when the County failed to respond
timely to its request for admissions. However, as our Supreme Court noted in RTT
Assocs. Inc., supra, sovereign immunity cannot be waived by the County’s actions
outside of the written contract, and this “rule would apply to any admissions made by
[the County] that the contract had been extended, when the evidence shows any
12
agreements to extend did not meet the written contract requirement set forth in the
applicable statute and constitutional provision relating to the waiver of sovereign
immunity.” Id. at 87 (3).
The constitutional provision “expressly reserving the power to waive sovereign
immunity to the legislature does not allow for exceptions to be created by the courts.”
(Citation and punctuation omitted.) Id. Accordingly, this Court cannot create an
exception to the rules regarding waiver of sovereign immunity based upon any
reliance that SOCO may have placed on the County’s request for changes, upon the
parties’ course of conduct, or upon facts deemed admitted pursuant to OCGA § 9-11-
36 (2). Accordingly, we reverse the trial court’s denial of the County’s summary
judgment on all of SOCO’s claims arising from modifications of the May 2013
contract. Although “this result may seem harsh, parties are presumed to know the law,
and are required ‘at their peril’ to ascertain the authority of a public officer with
whom they are dealing.” (Citation omitted.) Id. Further, the “fundamental purpose of
sovereign immunity is the protection of [S]tate funds[, and] it follows that one of the
purposes of the Constitution’s requirement that contracts must be in writing in order
to invoke the [S]tate’s waiver of sovereign immunity is to protect the [S]tate from
13
exposure to unanticipated damages.” (Citation and punctuation omitted.) Id. at 87-88
(3).
2. The County argues that the trial court erred in denying its motion to
withdraw admissions and in denying its motion for reconsideration of that denial. The
County argues that the trial court misapplied OCGA § 9-11-36 (b) and that the trial
court should not have deemed certain requests for admissions admitted, as they are
based on inappropriate legal conclusions. For the following reasons, we affirm in part
and reverse in part.3
Under Georgia law,
[a] party’s failure to timely respond to requests for admission
conclusively establishes as a matter of law each of the matters addressed
in the requests. This is true even if the requested admissions require
opinions or conclusions of law, so long as the legal conclusions relate
to the facts of the case. The language in OCGA § 9-11-36 (a) is clear,
unambiguous, and unequivocal and means just what it says. One must
comply strictly and literally with the terms of the statute upon the peril
of having his response construed to be an admission. Thus, matters
deemed admitted under this statute become solemn admissions in judicio
and are conclusive as a matter of law on the matters stated and cannot
3
As found in Division 1 herein, we have concluded that the admissions do not
act as a waiver on sovereign immunity for claims related to the alleged modifications.
Our analysis herein relates to admissions related to the original written contract.
14
be contradicted by other evidence unless the admissions are withdrawn
or amended on formal motion.
(Citation omitted.) Adewumi, supra at 277 (2).
The trial court is vested with broad discretion to permit withdrawal, and “the
trial court’s ruling on this issue may be reversed only upon a showing of abuse of
discretion.” (Citation omitted.) Parham v. Weldon, 333 Ga. App. 744, 746 (1) (776
SE2d 826) (2015).
(a) The County argues that the trial court abused its discretion by “grossly
misapplying” OCGA § 9-11-36 (b)’s two-part test.
There is a two-pronged test to be employed when considering a motion to
withdraw admissions. A court may grant a motion to withdraw when “[1] the
presentation of the merits of the action will be subserved thereby and [2] the party
who obtained the admission fails to satisfy the court that withdrawal or amendment
will prejudice him in maintaining his action or defense on the merits.” OCGA § 9-11-
36 (b). Accord Parham, supra at 746 (1). “If the movant satisfies the court on the first
prong, the burden is on the respondent to satisfy the second prong. Both prongs must
be established, pursuant to the standard provided in OCGA § 9-11-36 (b).” (Citation
and punctuation omitted.) Marlowe v. Lott, 212 Ga. App. 679, 681 (2) (442 SE2d
15
487) (1994). “If the movant fails to make the required showing to satisfy the first
prong of the test, then the trial court is authorized to deny the motion to withdraw the
admissions.” (Citations omitted.) Turner v. Mize, 280 Ga. App. 256, 257 (1) (633
SE2d 641) (2006).
To prove that the presentation of the merits in this case would be subserved by
the withdrawal, the County needed to establish that
the admitted requests either could have been refuted on trial of the issues
by admissible evidence having a modicum of credibility or that the
admitted requests were incredible on their face; and that the denials
being tendered to the court with the motion to withdraw had not been
offered solely for the purposes of delay.
(Citations omitted.) Fox Run Properties, LLC v. Murray, 288 Ga. App. 568, 570-571
(1) (654 SE2d 676) (2007). “The first prong of the test is not perfunctorily satisfied[,]
and the desire to have a trial, standing alone, is not sufficient to satisfy the test.”
(Citation and punctuation omitted.) Turner, supra at 257 (1).
In support of its motion to withdraw admissions, the County relied upon the
affidavit of Freddie Robinson. The trial court’s order found that the County did not
meet its initial burden of showing that presentations of the merits of the action would
be subserved by withdrawal of the admissions. Specifically, the trial court found that
16
the affidavit of County construction manager Freddie Robinson
proffered by the County in support of its motion to withdraw its
admissions was insufficient to support their withdrawal, in part, because
it lacked even a modicum of credibility. It contained facially
contradictory statements, material misstatements on basic elements of
the contract, miscounting of performance days, and other statements that
contradict documents in the record and the County’s own answers to
Interrogatories.
(Emphasis supplied.) The trial court further found that the County failed to credibly
refute specific admitted requests.4
The County argues in its brief that its supporting affidavit had a sufficient
modicum of credibility. However, the trial court, after examining the affidavit in
detail, found the issue not to be one of degree of credibility, but rather, of the utter
absence of it. Robinson’s affidavit directly contradicted the County’s responses to
various interrogatories. When asked in Interrogatory 5 why it issued no change orders
and why payment was withheld from SOCO, the County answered that “SOCO has
refused to amicably negotiate proposed field changes to a final reconciled amount.”
4
In its motion for reconsideration of the trial court’s denial of the County’s
motion to withdraw admissions, the County filed the affidavit of Felicia Strong-
Whittaker. However, Strong-Whitaker’s affidavit was not filed until after the trial
court denied the County’s motion to withdraw the admissions. The trial court
similarly found Strong-Whittaker’s affidavit to be lacking in credibility.
17
In his affidavit, however, Robinson attributes the refusal to issue change orders to
several different reasons, including: SOCO’s improper management and failure to
protect the site during bad weather; superintendent burnout; and poor SOCO staffing.
Further, Robinson miscounted performance days to calculate the completion date of
the project, and his affidavit contradicts evidence in the record without explanation.
Robinson averred that the project was only 50 percent complete on March 31, 2014,
but reports by his superiors show that the project was 65 percent complete two weeks
before that date and 80 percent complete two weeks after it. “Based on these
inconsistencies, the trial court was . . . authorized to find that [Robinson] lacked
credibility and that the admissions were not false.” (Footnote omitted.) Fox Run
Properties, LLC, supra at 571 (1) (trial court did not err in denying motion to
withdraw admissions when supporting affidavit was deemed unreliable because it
contradicted interrogatories and contained inconsistent statements).
“Under these circumstances, we cannot conclude that the trial court abused its
discretion in concluding that [the County] did not present credible evidence to refute
the admissions.” (Citations omitted.) Id. Compare Bailey v. Chase Third Century
Leasing Co., Inc., 211 Ga. App. 60, 61-62 (1) (438 SE2d 172) (1993) (trial court
abused its discretion by denying a motion to withdraw admissions in the face of a
18
sworn affidavit and other admissible evidence that cast doubt on the veracity of the
admissions).
Because the trial court did not err in concluding that the County had not
satisfied its burden in the first prong of this test, we need not address the second
prong. Turner, supra at 257 (1).
(b) The County next argues that the trial court should have withdrawn
Admissions Nos. 23, 36 and 37 on the grounds that they are based on inappropriate
legal conclusions.
(i) We find no error as to Requests for Admissions Nos. 23 and 36. Request for
Admission No. 23 asks the County to admit that SOCO “fully performed its
obligations under the contract[.]” Request for Admission No. 36 asks the County to
admit that “Fulton County acted with bad faith intentionally, with malice, and with
intent to do harm to SOCO in the County’s administration of the Contract.” Requests
for admissions requiring opinions or conclusions of law are specifically permitted,
as long as the legal conclusions relate to the facts of the case. G. H. Bass & Co. v.
Fulton County Bd. of Tax Assessors, 268 Ga. 327, 329 (1) (486 SE2d 810) (1997).
See also State Dept. of Corrections v. Developers Surety & Indemity Co., 291 Ga. 741(763 SE2d 868) (2016) (affirmed on cert. by State Dept. of Corrections v. Developers
19
Surety & Indemnity Co., 324 Ga. App. 371 (750 SE2d 697) (2013) (matters deemed
admitted by the Georgia Department of Corrections as a matter of law established that
it materially breached its contract with a government contractor for re-roofing certain
buildings). Requests are not objectionable because they seek admission of the
ultimate issue in the case but are only objectionable if they seek admission of purely
abstract principles unrelated to the facts of the case. G. H. Bass & Co., supra at 328
(1). A determination of whether the County acted with bad faith is not such an
abstract proposition of law.
(ii) The County argues that the trial court should have withdrawn Request for
Admission No. 37. We agree.
Request for Admission No. 37 asks the County to admit that “Fulton County
is liable to SOCO for each of the damages pleaded and prayed for in its Complaint.”
The damages prayed for in the Complaint included, inter alia, “pre-judgment interest
of at least $25,866.22” on funds that SOCO claims the County unlawfully withheld,
“damages in excess of $406,732.53” resulting from the “County’s refusal to
administer change orders and compensate SOCO for acceleration of the work”;
“damages in excess of $25,000.00” for the County’s interference with SOCO’s
subcontractors; “327,756.99 for unabsorbable extended home office expense,” and
20
“$638,876.50 due to profit on federal work lost as a result of Fulton County’s
wrongful withholding or retainage and intentional delay of project closeout and the
resultant loss of bonding capacity[.]”
The trial court should have withdrawn Request for Admission No. 37 because
some of the damages sought in the complaint arose from causes of action related to
the unwritten change orders on which the County is entitled to sovereign immunity,
as noted in Division 1. Further, other damages, such as SOCO’s lost profits claim, are
outside the County’s realm of knowledge. “While admissions resulting from a party’s
failure to respond to requests for admission are . . . generally considered conclusive
until withdrawn . . . , a party obviously has not the capacity to admit something which
is patently outside the realm of his knowledge.” (Citations omitted.) Cole v. Smith,
182 Ga. App. 59, 63 (3) (354 SE2d 835) (1987). Accord K-Mart Corp. v. Hackett,
237 Ga. App. 127, 133 (4) (514 SE2d 884) (1999) (trial court did not abuse its
discretion in allowing admission that defendant injured each plaintiff in the amount
of $2,500,000.00 because the answer was outside the knowledge of the defendant).
4. The County argues that the trial court erred in awarding attorney fees as part
of the summary judgment order. For the following reasons, we vacate and remand the
trial court’s award of attorney fees.
21
The trial court’s summary judgment order found that the County was liable for
“reasonable attorneys’ fees and litigation costs as SOCO has incurred since this
lawsuit was filed on May 8, 2015[,]” and directed SOCO to submit a statement of
such costs to the Court and to Fulton County within 21 days from the order, and gave
the County 10 days in which to make specific objections to SOCO’s statement of fees.
In Division 1, supra, we reverse the trial court’s denial of the County’s motion for
summary judgment on SOCO’s causes of action arising from the modifications to the
original contract made without written change orders. However, the trial court’s order
does not specify under which statute it awarded attorney fees or on which conduct it
based the award of attorney fees. Accordingly, we cannot determine whether the trial
court’s award was based upon claims from which we have concluded the County is
protected under the doctrine of sovereign immunity or which statute the trial court
relied upon in awarding attorney fees. See Aaron v. Ga. Farm Bureau Mut. Ins. Co.,
297 Ga. App. 403, 408 (c) (677 SE2d 419) (2009) (since appellant “cannot succeed
on his breach of contract . . . claims, he likewise cannot succeed on a claim for
attorney fees”) (footnote omitted). Therefore, we vacate the trial court’s grant of
attorney fees to SOCO and remand to the trial court for further consideration in light
of this opinion. See Cohen v. Nudelman, 269 Ga. App. 517, 523 (5) (604 SE2d 580)
22
(2004) (vacating an award of attorney fees and remanding to the trial court when the
record is unclear on which statutory basis the trial court relied to grant the award of
fees).
Judgment affirmed in part, reversed in part, vacated in part, and case
remanded. Dillard, C. J., and Self, J., concur.
23