Atlas Piers NEO v. Summit Constr. Co., Inc. , 2021 Ohio 2024 ( 2021 )

[Cite as Atlas Piers NEO v. Summit Constr. Co., Inc., 2021-Ohio-2024.]
STATE OF OHIO ) IN THE COURT OF APPEALS
)ss: NINTH JUDICIAL DISTRICT
COUNTY OF SUMMIT )
ATLAS PIERS NEO C.A. No. 29457
Appellee
v. APPEAL FROM JUDGMENT
ENTERED IN THE
SUMMIT CONSTRUCTION CO., INC. COURT OF COMMON PLEAS
COUNTY OF SUMMIT, OHIO
Appellant CASE No. CV-2014-09-4072
DECISION AND JOURNAL ENTRY
Dated: June 16, 2021
CARR, Presiding Judge.
{¶1} Defendant-Appellant Summit Construction Co., Inc. (“Summit”) appeals the
decisions of the Summit County Court of Common Pleas. This Court affirms.
I.
{¶2} In 2011, Summit was the general contractor on an Akron Metropolitan Housing
Authority (“AMHA”) project in Akron. The original architectural and structural drawings were
prepared by TC Architects, Inc, who was, at the time, the structural engineer of record. The plans
set forth the locations of the helical piers and the loads for the foundation. Separate documents set
forth the specifications for the helical piers themselves. The specifications required the piers be
designed with a safety factor of 2 to 1. Summit subcontracted with Plaintiff-Appellee Atlas Piers
NEO, a division of TCS, Inc. (“Atlas”), for, inter alia, the installation of helical screws and piers
in buildings 3-10. Atlas provides services that help stabilize buildings constructed in poor soil
conditions. The contract price was $240,278.00. The contract provided that
2
[Summit] shall retain out of each payment due [Atlas] 10% thereof [f]or a period
of 30 days from Contractor’s final acceptance. This period shall be computed for
each structure or improvement from the date of completion of [Atlas’] work therein
and [Summit’s] final acceptance thereof. If [Atlas’] shall fail to repair promptly
and efficiently any such defective work [Summit] upon notice may cause repairs to
be made and may deduct the cost thereof from the retained amount. [Atlas’]
liability hereunder shall not be limited to the retained amount.
{¶3} While the contract was dated April 11, 2011, it was not signed by Summit until
August 18, 2011. Atlas and Summit had concerns about the specifications and plans. In the spring
of 2011, Summit contracted with Ebersole Structural Engineers, Ltd. (“Ebersole”) to prepare shop
drawings for the helical piers. Steven Ebersole described his role as providing a foundation design.
In reviewing the documents provided, Ebersole determined that the plans of TC Architects, Inc.
were not accurate as they had not factored in the weight of the concrete. Ebersole then developed
new plans at Summit’s request. The plans were submitted in May 2011 but Ebersole was asked to
revise and resubmit those plans, which it did so. In a June 2011 meeting there was a discussion as
to whether to reduce the design loads and safety factor. In June 2011 correspondence to Ebersole,
Summit noted that TC Architects, Inc. needed to formally address that it changed the safety factor
from 2 to 1. Summit also sent correspondence to TC Architects, Inc. seeking guidance on what
loads to use for the shop drawings and for revised specifications to show the safety factor to
calculate the loads. Revised specifications that were issued did not list a safety factor. When
Summit questioned TC Architects, Inc. about the safety factor, TC Architects, Inc. responded that
the safety factor for the helical design was to be 1.0 and that the loads presented by Ebersole were
acceptable. On June 30, 2011, Atlas installed four test piers.
{¶4} The revised plans were approved in July 2011. Two change orders were signed by
the parties during the period from April 2011 until August 18, 2011. In July 2011, change order
number one was issued which provided that Atlas would perform engineering on the helical piers
3
for $1800.00. In response, Atlas contracted with Earth Contact Products and obtained a
preliminary design for the helical piers and sent it to Summit. Summit sent the Ebersole plans and
the preliminary design from Earth Contact Products to TC Architects, Inc. Summit then asked
Atlas to estimate the cost of the installation of the piers based upon Ebersole’s July plans and the
preliminary design from Earth Contact Products. The estimate broke the cost down per building
and totaled over $665,000.00. On July 21, 2011, Summit told Atlas to order materials needed to
begin work on buildings 3, 9, and 10. On July 26, 2011, TC Architects, Inc. approved Ebersole’s
foundation design, the drawings and specifications for the helical installation, and the Earth
Contact Product’s engineered design. Earth Contact Products noted that the design provided
ultimate capacities with no factor of safety and it recommended a safety factor of 2 be applied.
Change order number two was issued in August 2011 and provided for the cost and labor for the
four helical test piers that were installed in June 2011 at an increased cost of $3,174.00.
{¶5} Change order number 3 was issued August 19, 2011 and signed a few days later.
This change order removed the original contract amount and added the cost of installing piers in
buildings 3, 9, and 10. The new contract price under the change order was $268,539.13. Change
order 3 required Atlas to install the piers in accordance with the TC Architects, Inc. approved shop
drawings and submittals. It indicated that Atlas would be paid on a unit price basis. On August
23, 2011, TC Architects, Inc. issued supplemental instructions that stated, inter alia, that buildings
9 and 10 would no longer require helical piers. It also stated that the helical piers that would be
installed would be installed under the direction of Summit Testing & Inspection Company and to
the depth required by Summit Testing & Inspection Company. Between August 22, 2011 and
September 2, 2011, Atlas installed piers in building 3. Atlas averred that it only billed for the piers
that it actually installed. While the original design did call for 15 additional piers to be installed
4
for privacy walls, Summit told Atlas that AMHA was not going to put piers in the privacy walls
and instead it was going to use a different foundation. The application for payment, when
compared with documents evidencing the piers installed, demonstrates that Atlas actually billed
Summit for less than it installed.
{¶6} Atlas indicated that the installation went well until someone from Summit Testing
& Inspection began providing different instructions than that provided by the designs. Atlas asked
Summit about the issue and Summit told Atlas to follow the direction of Summit Testing &
Inspection. Atlas requested that Summit release it from liability due to the changes ordered by
Summit Testing & Inspection and also asked for a change order to verify the decrease in safety
factor but the request was not granted. In addition, Summit Testing & Inspection caused delays in
the installation by requiring Atlas to twice get a new gauge because Summit Testing & Inspection
thought there was a problem with the gauge. After still being unhappy with the gauge, Summit
Testing & Inspection then told Atlas to put the original gauge back on. Atlas requested payment
for the lost time in an email to Summit. Summit responded that it would be submitting a claim for
the delay and that Atlas would be a part of that claim. Summit, TC Architects, Inc., and AMHA
entered into a change order that included $10,000 for delay costs. However, Summit did not pay
any of those funds to Atlas.
{¶7} After the piers were installed, concerns arose, and, in early October Atlas performed
a load test on some of the piers. Change order 5 was issued to address Atlas’ costs with conducting
the load test. Summit provided assurances to Atlas that Atlas was only responsible for the proper
installation and not the design and stated that, with respect to building 3, Summit was directed by
TC Architects, Inc. to install per the direction of Summit Testing & Inspection Company. As of
the beginning of October, even Summit believed that Atlas had done its job with respect to building
5
3. On October 7, 2011, TC Architects, Inc. sent a letter to Summit expressing concern to Summit
about the manufacturer’s engineer, who was not licensed in Ohio, stamping a recommendation
letter while onsite at the load test. TC Architects, Inc. asked Summit how it was going to remedy
the issue. The president of Atlas testified that, after the load test report came out, at the end of
October 2011, a meeting was held at Summit Testing & Inspection and the discussion was that
“building [3] [wa]s finished and that we all accept it and approved it.” On October 17, 2011, a
representative from Summit emailed the president of Atlas and informed him that Ebersole was
willing to review and stamp the Earth Concept Products design to fulfill the requirements for an
Ohio stamp. Ultimately, Ebersole became the structural engineer of record and did review the pier
design and stamp it with an Ohio stamp. Ebersole did not think it billed for providing the review
and stamp.
{¶8} Ebersole reviewed the load test report and concluded, based upon its understanding
that a 1.5 factor of safety was being used, that additional piers were required. However, Ebersole
acknowledged that if the factor of safety had been eliminated there would not have been a need
for the additional piers. Ebsersole did not have any reason to believe that the need for additional
piers was due to any failure on Atlas’ part to comply with the drawings.
{¶9} On December 28, 2011, Summit notified Atlas that Ebersole had determined
modifications to the helical pier foundation were necessary in order for Ebersole to provide an
Ohio stamp. Specifically, six additional piers were required in order to meet the load requirements
in the original shop drawings. These additional piers did not appear on the approved shop
drawings. Summit told Atlas that the “work is to be done at the unit cost rates agreed upon in your
change order number 3.” Atlas responded with a list of items that needed to be discussed before
6
work could proceed, including a change order for remobilizing. Summit refused to provide a
change order as it believed one was not necessary.
{¶10} On January 4, 2012, Summit sent Atlas a letter giving it 48 hours to comply. On
January 9, 2012, Summit sent Atlas a letter terminating the subcontract. Summit then contracted
with Geotech Services, Inc. to install the helical piers for $3,300.00. While Summit did pay Atlas
during 2011 for the invoices that were submitted, Summit withheld a retainer on each payment,
which was authorized under the contract. Nonetheless, Summit maintained that it did not owe
Atlas the retainer as it had paid Atlas appropriately for the work that was completed and because
Atlas did not have its work stamped by an Ohio engineer; instead, Summit had to procure an Ohio
stamp from Ebersole. Summit noted that the engineer from Earth Contact Products who came to
the job site for the October 2011 load test could only provide a Texas stamp and it included a
limited liability clause in its paperwork. Summit also maintained that 41 of the .203 stock piers
were to be installed in building 3 and only 26 were installed; thus, when building 3 required an
additional 6 piers, those piers should have already been covered. Summit also maintained that
Atlas had billed it for the 41 piers despite only installing 26. It also asserted that Atlas overcharged
for materials and thus was not entitled to the retainer. Irrespective, there appears to be no dispute
that the monies retained by Summit totaled $20,985.64. Summit received its final retainage
payment from AMHA in February 2014.
{¶11} In 2012, Summit filed a suit against Atlas. In turn, Atlas filed a counterclaim
asserting that Summit breached the contract. Atlas maintained that it was entitled to its lost time,
work, and lost profits. In addition, Atlas sought to recover the retainer withheld by Summit as
well as attorney fees and costs. Ultimately, this suit was dismissed. Atlas refiled the suit, which
became the instant matter. Atlas alleged that Summit breached the contract and sought money for
7
lost time, extra work performed, lost profits, and the retainer that was withheld. Atlas further
asserted that Summit failed to timely pay Atlas in violation of R.C. 4113.61. Summit answered
and filed a counterclaim. In its counterclaim, Summit alleged that Atlas breached the contract.
{¶12} Ultimately, the matter proceeded to a bench trial. In the trial court’s judgment
entry, it characterizes Atlas’ claims as seeking damages for the retainer, for the delay, for the work
Atlas failed to invoice Summit for, and for failing to timely pay in violation of R.C. 4113.61, which
also allows for an award of 18% interest and attorney fees. The trial court concluded that Summit
had abandoned its counterclaim by failing to include it in its proposed findings of fact and
conclusions of law.
{¶13} After setting forth how it reached its conclusion, the trial court found that the
amounts Atlas billed Summit reflected the amounts agreed to in change order 3 and the work
performed, aside from the work that Atlas mistakenly failed to bill for. The trial court concluded
that Atlas was not entitled to damages for the piers that it did not submit an invoice for. The trial
court determined that Atlas did not have an obligation to remobilize and install the six additional
piers without a change order and that the contract documents did not require that Atlas provide an
Ohio stamped engineered pier design. Additionally, the trial court found that Atlas was entitled to
damages for delay and awarded it prejudgment interest as well. As to the amounts retained by
Summit, the trial court concluded that Summit owed Atlas those amounts. Based upon the amounts
and dates of the retainer released to Summit, the trial court awarded Atlas $19,105.24 plus 18%
interest from February 18, 2013, $1,692.36 plus 18% interest from April 18, 2013, and $188.04
plus 18% interest from March 6, 2014. The trial court further stated that Atlas was entitled to
attorney fees and a hearing on the issue would be subsequently held.
8
{¶14} A hearing on attorney fees was held before a magistrate. Prior to the hearing, the
parties submitted briefs and expert reports related to the issue. Atlas argued that its claims were
too intertwined to separate out the work for the R.C. 4113.61 claim. Summit maintained that Atlas
failed to satisfy the factors in the statute and that Atlas was only entitled to fees for the R.C.
4113.61 claim. The magistrate ultimately concluded that the claims were too intertwined to
separate out the attorney fees. The magistrate awarded Atlas $51,847.63 for litigating it claims
against Summit, $7,545.00 to litigate the attorney fees claim, and $1,500.00 to prepare a post-
hearing brief. Summit filed objections to the magistrate’s decision. Thereafter, the trial court
issued a judgment entry adopting the magistrate’s decision and entered judgment in favor of Atlas
on its claims for attorney fees. The trial court awarded Atlas $4,082.25 in attorney fees for filing
its brief in support of the magistrate’s decision.
{¶15} Summit has appealed, raising three assignments of error for our review.
II.
ASSIGNMENT OF ERROR I
THE TRIAL COURT ERRED IN DETERMINING A VIOLATION OF R.C.
4113.61, THE OHIO PROMPT PAY ACT WHEREIN GOOD FAITH
DEFENSES EXISTED WITH RESPECT TO THE APPELLEE’S UNDERLYING
CLAIM.
{¶16} Summit argues in its first assignment of error that the trial court in its April 30,
2018 judgment determined Summit violated R.C. 4113.61 simply because it did not pay Atlas
within 30 days after the receipt of payment from AMHA. Summit asserts that the trial court failed
to analyze the facts and circumstances to determine whether there were good faith allegations or
defenses asserted by Summit in order to determine whether attorney fees were appropriate. See
R.C. 4113.61(B)(2)(a). While Summit addresses this broadly in terms of whether the trial court
9
properly found a violation of R.C. 4113.61, in actuality, Summit is asserting that the trial court
failed to make the appropriate findings to authorize an award of attorney fees.
{¶17} R.C. 4113.61(B) provides:
(1) If a contractor, subcontractor, material supplier, lower tier subcontractor, or
lower tier material supplier has not made payment in compliance with division
(A)(1), (2), (3), (4), or (5) of this section within thirty days after payment is due, a
subcontractor, material supplier, lower tier subcontractor, lower tier material
supplier, or laborer may file a civil action to recover the amount due plus the interest
provided in those divisions. If the court finds in the civil action that a contractor,
subcontractor, material supplier, lower tier subcontractor, or lower tier material
supplier has not made payment in compliance with those divisions, the court shall
award the interest specified in those divisions, in addition to the amount due.
Except as provided in division (B)(3) of this section, the court shall award the
prevailing party reasonable attorney fees and court costs.
(2) In making a determination to award attorney fees under division (B)(1) of this
section, the court shall consider all relevant factors, including but not limited to the
following:
(a) The presence or absence of good faith allegations or defenses asserted by the
parties;
(b) The proportion of the amount of recovery as it relates to the amount demanded;
(c) The nature of the services rendered and the time expended in rendering the
services.
(3) The court shall not award attorney fees under division (B)(1) of this section if
the court determines, following a hearing on the payment of attorney fees, that the
payment of attorney fees to the prevailing party would be inequitable.
{¶18} After fully setting forth its findings of fact and analysis related to the issues, which
included a discussion of Summit’s claims and defenses, the trial court, in its April 30, 2018 entry,
concluded that “[b]ecause Summit [] failed to make any payment to Atlas within thirty days after
payment was due, and because Atlas had to file this lawsuit to recover the retainage due, Atlas is
also entitled to an award of reasonable attorney fees and court costs incurred in prosecuting the
within matter. By separate Order, the Court will schedule a hearing on the fees and costs incurred.”
Thus, the trial court’s April 30, 2018 entry did not actually award any amount of attorney fees to
10
Atlas. Instead, as required by the statute, it ordered that a hearing take place. See R.C.
4113.61(B)(3).
{¶19} Briefs and exhibits were then filed, and a hearing was held before a magistrate on
the attorney fees issue. The magistrate issued a decision, to which Summit filed objections.
Thereafter, the trial court issued its May 30, 2019 judgment entry. In that entry, the trial court
recited the statutory language of R.C. 4113.61(B)(2), which Summit argues was absent from the
April 30, 2018 entry, and provided an analysis of the factors.
{¶20} Even assuming there was some error in the trial court’s April 30, 2018 entry,
Summit has not explained how any error would not be rendered moot by the thorough analysis in
the May 30, 2019 entry, which was the entry that actually awarded attorney fees to Atlas.
Accordingly, we cannot say that Summit has demonstrated any reversible error on the part of the
trial court. Summit’s first assignment of error is overruled.
ASSIGNMENT OF ERROR II
THE TRIAL COURT’S FINDING OF A VIOLATION OF R.C. 4113.61, THE
OHIO PROMPT PAY ACT, WAS AGAINST THE MANIFEST WEIGHT OF
THE EVIDENCE SINCE OVERWHELMING EVIDENCE OF GOOD FAITH
DEFENSES TO APPELLEE’S UNDERLYING CLAIM WAS PRESENTED AT
TRIAL BY THE APPELLANT.
{¶21} Summit argues in its second assignment of error that the trial court’s finding that
there was a violation of R.C. 4113.61 was against the manifest weight of the evidence.
{¶22} Where a party claims that a trial court’s judgment is against the manifest weight of
the evidence, “[t]he [reviewing] court * * * weighs the evidence and all reasonable inferences,
considers the credibility of witnesses and determines whether in resolving conflicts in the
evidence, the [finder of fact] clearly lost its way and created such a manifest miscarriage of justice
that the [judgment] must be reversed and a new trial ordered.” (Internal quotations omitted.)
11
Eastley v. Volkman, 132 Ohio St.3d 328, 2012-Ohio-2179, ¶ 20, quoting Tewarson v. Simon, 141
Ohio App.3d 103, 115 (9th Dist.2001). “In weighing the evidence, the court of appeals must
always be mindful of the presumption in favor of the finder of fact.” Eastley at ¶ 21. “[I]n
determining whether the judgment below is manifestly against the weight of the evidence, every
reasonable intendment and every reasonable presumption must be made in favor of the judgment
and the finding of facts. * * * If the evidence is susceptible of more than one construction, the
reviewing court is bound to give it that interpretation which is consistent with the verdict and
judgment, most favorable to sustaining the verdict and judgment.” (Internal quotations and
citations omitted.) Id.{¶23} In its post-trial brief, Atlas sought recovery pursuant to R.C. 4113.61(A)(3). R.C.
4113.61(A)(3) provides:
If a contractor receives any final retainage from the owner for improvements to
property, the contractor shall pay from that retainage each subcontractor and
material supplier the subcontractor’s or material supplier’s proportion of the
retainage, within ten calendar days after receipt of the retainage from the owner, or
within the time period provided in a contract, invoice, or purchase order between
the contractor and the subcontractor or material supplier, whichever time period is
shorter, provided that the contractor has determined that the subcontractor’s or
material supplier’s work, labor, and materials have been satisfactorily performed or
furnished and that the owner has approved the subcontractor’s or material supplier’s
work, labor, and materials.
If the contractor fails to pay a subcontractor or material supplier within the
appropriate time period, the contractor shall pay the subcontractor or material
supplier, in addition to the retainage due, interest in the amount of eighteen per cent
per annum of the retainage due, beginning on the eleventh day following the receipt
of the retainage from the owner and ending on the date of full payment of the
retainage due plus interest to the subcontractor or material supplier.
{¶24} There is no dispute that Summit failed to pay Atlas the $20,985.64 retainer that was
withheld. Summit’s argument on appeal is that it “asserted numerous good faith defenses to the
payment of the retainage alleged due.” In so doing, it focuses on the language in the statute that
12
states the contractor shall pay the subcontractor’s retainage in a specified time period “provided
that the contractor has determined that the subcontractor’s or material supplier’s work, labor, and
materials have been satisfactorily performed or furnished and that the owner has approved the
subcontractor’s or material supplier’s work, labor, and materials.” R.C. 4113.61(A)(3). Without
any citations to the nearly 500 page transcript or any of the more than 100 exhibits, see App.R.
16(A)(7), Summit asserts that Atlas’ work was not satisfactorily performed or approved because
of the absence of an Ohio stamped drawing that was required under the contract and because Atlas
was paid in full for the work it did. Notably, in its argument, Summit does not point to any
provision in the contract or change order 3 that would indicate an Ohio stamp was required to be
provided by Atlas. See id. Likewise, in its argument, Summit points to no documentary evidence
in support of its claim that Atlas was already fully paid for the work it did. See id. Further, the
mere fact that Summit presented numerous defenses does not require the conclusion that the trial
court found those defenses credible. This Court remains mindful that “[i]n reaching its verdict,
the [trier of fact] was in the best position to evaluate the credibility of the witnesses and it was
entitled to believe all, part, or none of the testimony of each witness.” (Internal quotations and
citations omitted.) Wade v. Mancuso, 9th Dist. Lorain No. 16CA010978, 2018-Ohio-1563, ¶ 33.
{¶25} The trial court concluded that Summit did not identify any language in the
subcontract agreement that specifically required Atlas to provide an Ohio stamp and also closely
examined whether Atlas appropriately billed for its work and set forth its calculations. Summit
has not developed an argument discrediting the trial court’s findings and conclusions. Given the
limited arguments made on appeal, and after a thorough review of the record, we cannot say that
Summit has demonstrated that the trial court’s judgment is against the manifest weight of the
evidence. See Herhold v. Smith Land Co., 9th Dist. Summit No. 28915, 2019-Ohio-2418, ¶ 73.
13
{¶26} Summit’s second assignment of error is overruled.
ASSIGNMENT OF ERROR III
THE TRIAL COURT ERRED IN ADOPTING THE MAGISTRATE’S
DECISION AWARDING 100% OF THE ATTORNEY FEES REQUESTED BY
APPELLEE IN CONNECTION WITH THE AWARD OF ATTORNEY FEES
PURSUANT TO R.C. 4113.61, THE OHIO PROMPT PAY ACT, DESPITE THE
PROMPT PAY CLAIM ASSERTED BY THE APPELLEE ONLY CONSISTING
OF A SMALL PERCENTAGE OF APPELLEE’S OVERALL CLAIMS
ASSERTED AT TRIAL, AND THE APPELLEE FAILED TO EVEN ATTEMPT
TO SEPARATE OUT ATTORNEY FEES RELATED ONLY TO THE PURSUIT
OF THE PROMPT PAY ACT CLAIM VERSUS OTHER CLAIMS AND
DEFENSES ASSERTED AND TRIED IN THE PENDING LITIGATION.
{¶27} Summit argues in its third assignment of error that the trial court erred in awarding
Atlas all of its requested attorney fees. Summit maintains that Atlas was only entitled to the fees
expended in pursuing its claim under R.C. 4113.61. Summit notes that Atlas did not recover a
large portion of the money it sought; in fact, Atlas recovered substantially more in attorney fees
than it did under the trial court’s verdict. Summit also argues that Atlas’ claims were not
intertwined. Summit points to Atlas’ billing statements which it asserts include time spent on the
2012 case which did not specifically reference a claim under R.C. 4113.61, as well as numerous
other items that are unrelated to the R.C. 4113.61 claim. Summit maintains that the trial court
should have deducted time billed in the first case, time clearly assignable to Atlas’ claim for lost
profits or delay, and redundant time not necessary for the R.C. 4113.61 claim. It does not appear
that Summit challenges the award of attorney fees to Atlas for fees it incurred in litigating the
attorney fees issues, a sum which totals $13,127.25. Thus, the challenged sum actually amounts
to $51,847.63.
{¶28} Generally, this court reviews an award of attorney fees for an abuse of discretion.
See Westbury Place Homeowners Assn., Inc. v. Murea, 9th Dist. Medina No. 19CA0075-M, 2020-
Ohio-2879, ¶ 7. Other courts have extended this standard of review to cases involving attorney
14
fees awarded pursuant to R.C. 4113.61. See Xtreme Elements, LLC v. Foti Contracting, LLC, 11th
Dist. Lake No. 2017-L-099, 2018-Ohio-3323, ¶ 19, citing Frank Novak & Sons, Inc. v. A-Team,
L.L.C., 8th Dist. Cuyahoga No. 99777, 2014-Ohio-922, ¶ 63. Further, the Supreme Court of Ohio
has stated that “[i]t is well settled that where a court is empowered to award attorney fees by statute,
the amount of such fees is within the sound discretion of the trial court. Unless the amount of fees
determined is so high or so low as to shock the conscience, an appellate court will not interfere.”
Bittner v. Tri-County Toyota, Inc., 58 Ohio St.3d 143, 146 (1991). “The trial judge which
participated not only in the trial but also in many of the preliminary proceedings leading up to the
trial has an infinitely better opportunity to determine the value of services rendered by lawyers
who have tried a case before him than does an appellate court.” Id.{¶29} In Bittner, which involved awarding attorney fees pursuant to R.C. 1345.09(F)(2)
as part of the Consumer Sales Practices Act (“CSPA”), the Court also noted that, “[w]here * * *
the claims can be separated into a claim for which fees are recoverable and a claim for which no
fees are recoverable, the trial court must award fees only for the amount of time spent pursuing the
claim for which fees may be awarded. Id. at 145. Other courts have noted that, however, “when it
is not possible to divide claims in this fashion, such as when claims not covered under the CSPA
involve a common core of facts with claims arising under the CSPA, then the court may award
attorney fees for all time reasonably spent pursuing all claims.” Bryant v. Walt Sweeney
Automotive, Inc., 1st Dist. Hamilton Nos. C-010395, C-010404, 2002-Ohio-2577, ¶ 35; Williams
v. Sharon Woods Collision Ctr., Inc., 1st Dist. Hamilton No. C-170511, 2018-Ohio-2733, ¶ 19.
{¶30} “There is a strong presumption that the reasonable hourly rate multiplied by the
number of hours worked, which is sometimes referred to as the ‘lodestar,’ is the proper amount for
an attorney-fee award.” Phoenix Lighting Group, L.L.C. v. Genltye Thomas Group, L.L.C., 160
15
Ohio St.3d 32, 2020-Ohio-1056, paragraph one of the syllabus. R.C. 4113.61(B) states in relevant
part:
Except as provided in division (B)(3) of this section, the court shall award the
prevailing party reasonable attorney fees and court costs.
(2) In making a determination to award attorney fees under division (B)(1) of this
section, the court shall consider all relevant factors, including but not limited to the
following:
(a) The presence or absence of good faith allegations or defenses asserted by the
parties;
(b) The proportion of the amount of recovery as it relates to the amount demanded;
(c) The nature of the services rendered and the time expended in rendering the
services.
(3) The court shall not award attorney fees under division (B)(1) of this section if
the court determines, following a hearing on the payment of attorney fees, that the
payment of attorney fees to the prevailing party would be inequitable.
{¶31} In support of its claim for attorney fees, Atlas submitted the affidavit of its counsel.
Atlas’ counsel averred that Atlas agreed to compensate Atlas’ counsel at a rate of $200.00 per hour
for legal services performed out of office, $150.00 per hour for legal services performed in office,
and $75.00 per hour for research and clerk services performed in furtherance of litigation. It does
not appear that Summit asserts that the rates charged by Atlas’ counsel were unreasonable.
Attached to the affidavit was a copy of the invoices detailing the work performed, the hours
expended, and the costs incurred. Atlas’ counsel also testified at the hearing, as did an expert
witness. The expert witness opined that the claims in the matter were so intertwined such that it
was not possible to separate them out. In turn, Summit presented the testimony of an expert
witness who maintained that the fees could be separated out into the fees solely for the R.C.
4113.61 claim and asserted that Atlas was only entitled to $14,460.00 in attorney fees.
16
{¶32} To the extent Summit challenges the trial court’s award of attorney fees for 2012
litigation, based upon its argument on appeal, we conclude its contention is without merit. Summit
only asserts that Atlas is not entitled to those fees because Atlas’ 2012 counterclaim lacked a
separate claim under R.C. 4113.61. As mentioned above, Atlas’ 2012 counterclaim included
allegations that Summit owed Atlas the retainer withheld for worked performed on building 3
totaling $20,985.00. In addition, Atlas sought attorney fees and costs. Civ.R. 8(A) only requires
that, “[a] pleading that sets forth a claim for relief, whether an original claim, counterclaim, cross-
claim, or third-party claim, shall contain (1) a short and plain statement of the claim showing that
the party is entitled to relief, and (2) a demand for judgment for the relief to which the party claims
to be entitled.” At the hearing on attorney fees, Atlas’ counsel testified that a claim under R.C.
4113.61 was part of the 2012 action, it was just not listed as a separate count; in the second action,
Atlas chose to include it as a second count for the sake of clarity. Given the minimal requirements
of Civ.R. 8(A), and Summit’s limited argument on appeal, we cannot say that it would be
unreasonable for the trial court to conclude that the 2012 action included a claim pursuant to R.C.
4113.61.
{¶33} The remainder of Summit’s argument largely focuses on the notion that Atlas’
attorney fees could be separated by claim. Summit aptly points to its own expert who did aver that
only a portion of Atlas’ attorney fees were connected to the R.C. 4113.61 claim. This is certainly
evidence that the fees could be separated; however, Atlas presented evidence and argument that it
was not within reason to do so. After a review of the record, we cannot say that the trial court
abused its discretion in concluding that it was not reasonable to separate out the fees by claim. The
matter before the trial court involved complex construction litigation centering around one
subcontract and modifications to it via change orders. The vast majority of the litigation centered
17
around whether Atlas performed its obligations under the subcontract and change orders. This is
further evidenced by Summit’s arguments in the previous assignments of error which attempt to
demonstrate that Summit had a reasonable basis for not paying Atlas its retainer. Summit
maintained that its grounds for nonpayment required that Atlas should not succeed on its R.C.
4113.61 claim. Thus, for Summit to argue that the claims in this lawsuit are not intertwined is
untenable.
{¶34} To the extent that Summit asserts that the award of attorney fees to Atlas is
disproportionate and unreasonable in light of the sum recovered by Atlas as compared to the
asserted value of its claims, we note that R.C. 4113.61(B)(2) lists factors to be considered and does
not provide an exhaustive list. Nothing in the statute evidences that the factors are to be equally
weighted, nor does the statute indicate that it is per se unreasonable for an award of attorney fees
to substantially exceed the funds recovered by the prevailing party. While it is true that Atlas did
not recover a large proportion of the money it sought, it was nonetheless successful in its litigation.
Not only did it succeed on a portion of its claims, Summit failed to succeed on its counterclaim, in
which it sought over $400,000.
{¶35} The trial court provided a detailed analysis of the statutory factors in its judgment
entry, and in light of Summit’s arguments on appeal, overall, we cannot say that it has
demonstrated that the trial court abused its discretion in its attorney fees award to Atlas.
{¶36} Summit’s third assignment of error is overruled.
III.
{¶37} Summit’s assignments of error are overruled. The judgment of the Summit County
Court of Common Pleas is affirmed.
Judgment affirmed.
18
There were reasonable grounds for this appeal.
We order that a special mandate issue out of this Court, directing the Court of Common
Pleas, County of Summit, State of Ohio, to carry this judgment into execution. A certified copy
of this journal entry shall constitute the mandate, pursuant to App.R. 27.
Immediately upon the filing hereof, this document shall constitute the journal entry of
judgment, and it shall be file stamped by the Clerk of the Court of Appeals at which time the period
for review shall begin to run. App.R. 22(C). The Clerk of the Court of Appeals is instructed to
mail a notice of entry of this judgment to the parties and to make a notation of the mailing in the
docket, pursuant to App.R. 30.
Costs taxed to Appellant.
DONNA J. CARR
FOR THE COURT
HENSAL, J.
TEODOSIO, J.
CONCUR.
APPEARANCES:
MARK W. BERNLOHR and SANDRA K. ZERRUSEN, Attorneys at Law, for Appellant.
DANIEL MARK WALPOLE, Attorney at Law, for Appellee.