Meyer Tool, Inc. v. Mikrolar, Inc. ( 2023 )

[Cite as Meyer Tool, Inc. v. Mikrolar, Inc., 2023-Ohio-704.]
IN THE COURT OF APPEALS
FIRST APPELLATE DISTRICT OF OHIO
HAMILTON COUNTY, OHIO
MEYER TOOL, INC., : APPEAL NO. C-220290
TRIAL NO. A-2101354
Plaintiff-Appellee, :
:
VS. O P I N I O N.
:
MIKROLAR, INC., :
Defendant-Appellant. :
Civil Appeal From: Hamilton County Court of Common Pleas
Judgment Appealed From Is: Affirmed
Date of Judgment Entry on Appeal: March 8, 2023
Graydon Head & Ritchey LLP and Daniel J. Knecht, for Plaintiff-Appellee,
Taft Stettinius & Hollister LLP and Anna M. Greve, for Defendant-Appellant.
OHIO FIRST DISTRICT COURT OF APPEALS
BERGERON, Judge.
{¶1} Most of the time, when you pay for a good, you expect the good to be
provided by the seller (or at least your money back). In this case, the seller endeavors
to convince us that it should be entitled to keep the buyer’s money it received and not
furnish the good. Not only does this flout common sense, but we also cannot reconcile
it with basic doctrines of contract law. The trial court, seeing things the same way,
ruled in favor of the buyer and awarded it the amount it paid for the good in damages.
For the reasons explained below, we affirm its judgment.
I.
{¶2} In October 2016, plaintiff-appellee Meyer Tool, Inc., requested a quote
from defendant-appellant Mikrolar, Inc., for certain custom robotics (called a
“hexapod”). Later that month, Mikrolar’s president Michael Fortier gave Meyer Tool
a quote for two of Mikrolar’s P1000 Hexapod systems and two P1000 sealing systems
(also called “boots”) for a total price of $149,500, plus delivery expenses. In their
discussion, Meyer Tool suggested to Mr. Fortier the possibility that Meyer Tool could
order up to 20 more of the machines, depending on the success of the first two systems.
{¶3} In December 2016, Meyer Tool placed a purchase order for two P1000
Hexapod systems and two P1000 boots consistent with the quote. Mikrolar would
custom-design these machines, fashioned with specifications unique to Meyer Tool.
The purchase contract required that issues concerning the transaction, including any
cancellation, be in writing.
{¶4} In October 2017, Mikrolar delivered the first hexapod to Meyer Tool.
Mikrolar shipped one of the two hexapods per Meyer Tool’s specific instruction. At
this point, Meyer Tool told Mikrolar to pause work because it was not ready for
2
OHIO FIRST DISTRICT COURT OF APPEALS
delivery of the second hexapod. Mikrolar obliged. After some time passed, Mikrolar
began reaching out to Meyer Tool to determine what to do with the second hexapod
that it had already completed.
{¶5} Following a series of communications between the parties, Scott
Hudson of Meyer Tool told Mr. Fortier that he would visit Mikrolar’s facility to review
the second hexapod and would schedule delivery after that inspection. Mr. Fortier
followed up with Meyer Tool a number of times to request a time for inspection of the
hexapod in advance of shipping. In July 2018, Mr. Hudson visited Mikrolar’s facility
to confirm that the hexapod specifications were correct (and, apparently, they were).
After this visit, Mr. Hudson told Mr. Fortier not to ship the second hexapod, explaining
that the lack of manpower at Meyer Tool would prevent them from integrating the
hexapod into their system at that time. Mr. Fortier and Mr. Hudson spoke by phone
several times after Mr. Hudson’s July 2018 visit. Each time, Mr. Hudson told Mr.
Fortier that Meyer Tool was not ready for the second hexapod to be shipped. In
October 2018, however, Meyer Tool issued a $45,000 check to Mikrolar for the final
payment owed to Mikrolar under the purchase contract.
{¶6} In March 2019, Mr. Hudson notified Mr. Fortier that Meyer Tool had
discontinued the program for which they had originally ordered the hexapods. As far
as the record discloses, Meyer Tool did not mention scheduling delivery of the second
hexapod during this phone call, nor did Mikrolar inquire as to what it should do with
the completed hexapod.
{¶7} After nearly two years passed (including an intervening global
pandemic), in January 2021, Meyer Tool’s director of engineering reached out to Mr.
Fortier to inquire into the status of the second hexapod. By this point, however,
3
OHIO FIRST DISTRICT COURT OF APPEALS
Mikrolar no longer had possession of the second hexapod. It is unclear from the record
what happened to the hexapod, whether it was sold to another buyer or disassembled
for its parts. Without the ability to deliver the second hexapod, Mikrolar declined to
reimburse the money Meyer Tool paid for the hexapod, concluding that Meyer Tool
either abandoned the contract or prevented Mikrolar’s performance.
{¶8} After paying $70,000 for the second hexapod and accompanying boots
but ending up empty-handed, in April 2021, Meyer Tool filed a complaint against
Mikrolar for breach of contract and unjust enrichment. After the parties cross-moved
for summary judgment, the trial court granted Meyer Tool’s summary judgment
motion and denied Mikrolar’s cross-motion, finding that Meyer Tool was owed
$70,000 in damages ($60,000 for the hexapod and $5,000 each for the two boots).
Mikrolar now appeals, raising two assignments of error.
II.
{¶9} In its first assignment of error, Mikrolar alleges that the trial court erred
in granting Meyer Tool’s motion for summary judgment. We review this question de
novo, conducting an independent review of the record to determine the propriety of
summary judgment. See Al Neyer, LLC v. Westfield Ins. Co., 1st Dist. Hamilton No.
C-200007, 2020-Ohio-5417, ¶ 13. “Under Civ.R. 56(C), summary judgment is proper
where the moving party establishes that ‘(1) no genuine issue of any material fact
remains, (2) the moving party is entitled to judgment as a matter of law, and (3) it
appears from the evidence that reasonable minds can come to but one conclusion, and
construing the evidence most strongly in favor of the nonmoving party, that
conclusion is adverse to the party against whom the motion for summary judgment is
4
OHIO FIRST DISTRICT COURT OF APPEALS
made.’ ” Id. at ¶ 14, quoting State ex rel. Duncan v. Mentor City Council, 105 Ohio
St.3d 372, 2005-Ohio-2163, 826 N.E.2d 832, ¶ 9.
{¶10} The elements of a breach of contract claim are familiar: “(1) the
existence of a contract, (2) performance by the plaintiff, (3) breach by the defendant,
and (4) damages resulting from the breach.” Brendamour v. City of the Village of
Indian Hill, 1st Dist. Hamilton Nos. C-210504, C-210516 and C-210517, 2022-Ohio-
4724, ¶ 18, citing White v. Pitman, 2020-Ohio-3957, 156 N.E.3d 1026, ¶ 37 (1st Dist.).
Mikrolar insists that Meyer Tool’s claim for breach of contract cannot succeed because
Mikrolar did not breach the contract, invoking various principles of contract law in
support of this assertion. We disagree.
{¶11} Central to our rejection of each of Mikrolar’s defenses to Meyer Tool’s
breach of contract claim is the fact that the purchase order contained a cancellation
clause that provided, “Any order or contract may be terminated by buyer only upon
written notice and payment of reasonable and proper termination charges plus a fixed
sum of 10% of the final net P.O. price * * *.” The contract also reiterated, “[Mikrolar]
shall communicate, in writing, with Meyer Tool, Inc. as it pertains to issues for
resolution, or communication relative to the information contained within this
purchase order.” (Emphasis added.) These clauses are unambiguous. Written
communication was required to cancel the contract. Retirement Corp. of Am. v.
Henning, 1st Dist. Hamilton No. C-180643, 2019-Ohio-4589, ¶ 18 (“Contracts that are
clear and unambiguous will be enforced according to their terms.”).
{¶12} Without any written cancellation to point to, Mikrolar relies on a phone
call in which Meyer Tool’s Mr. Hudson told Mikrolar’s Mr. Fortier that the program
for which it had purchased the two robots had been discontinued. But nowhere in this
5
OHIO FIRST DISTRICT COURT OF APPEALS
phone call (so far as the record discloses) did Mr. Hudson indicate that he no longer
expected the terms of the parties’ existing contract to be performed as agreed, nor did
he purport to cancel the parties’ contract. If Mikrolar believed from either Mr.
Hudson’s phone call or from Meyer Tool’s course of conduct that the contract was
canceled, the express terms of the contract required Mikrolar to memorialize this
inference through a written communication in order to afford Meyer Tool notice of its
intended course of action. Nothing prevented Mikrolar from reaching out to Meyer
Tool, in writing, to give Meyer Tool a final chance to schedule delivery of the second
hexapod upon notice that it would cancel the contract if Meyer Tool failed to do so.
Nor do we see anything in the record that would have prevented Mikrolar from simply
shipping the hexapod (which apparently is about the size of a microwave oven) to
Meyer Tool.
{¶13} Unable to demonstrate compliance with the writing requirement,
Mikrolar posits that Meyer Tool’s conduct waived the requirement that cancellation
be in writing. Specifically, Mikrolar argues that Meyer Tool’s extended delay in
scheduling delivery of the second hexapod sufficed to show cancellation. Where a
contract specifically provides that cancellation must be made in writing, the clause is
valid and binding upon the parties, and the contract cannot be cancelled without a
written directive unless the writing requirement is waived. See Setzekorn v. Kost USA,
Inc., 12th Dist. Warren No. CA2008-02-017, 2009-Ohio-1011, ¶ 11, quoting
Uebelacker v. Cincom Sys., Inc., 48 Ohio App.3d 268, 271, 549 N.E.2d 1210 (1988)
(where the court, in enforcing a contractual provision requiring written notice for
cancellation, noted that “[w]here a contract’s terms are clear and unambiguous, ‘the
court need not go beyond the plain language of the agreement to determine the parties’
6
OHIO FIRST DISTRICT COURT OF APPEALS
rights and obligations; instead, the court must give effect to the agreement’s express
terms.’ ”). “Proof of a waiver must either be in writing, or by clear and convincing
evidence sufficient to leave no reasonable doubt that the [party] intended to waive the
writing requirement.” Joel Lehmkuhl Excavating v. City of Troy, 2d Dist. Miami No.
2004-CA-31, 2005-Ohio-2019, ¶ 30; see 3637 Green Rd. Co. v. Specialized Component
Sales Co., 2016-Ohio-5324, 69 N.E.3d 1083, ¶ 22 (8th Dist.) (“The waiver must be
clear and unequivocal if it contradicts a written contract provision.”). Here, the record
reveals no proof of waiver in writing, and we cannot say that Meyer Tool’s actions
constituted “clear and convincing evidence” of its intent to waive the writing
requirement. A mere extended delay in communication does not rise to the level of
clear evidence that Meyer Tool intended to waive the written cancellation
requirement.
{¶14} In fact, the record discloses no discussions at all about the writing
requirement. While the parties apparently did not speak between 2019 and 2021 (and
blame each other for the lack of engagement), this silence does not rise to the level of
overcoming the plain terms of the written cancellation requirement. Although the
foregoing analysis explains, in large measure, why we reject Mikrolar’s first
assignment of error, we proceed to address each of its subarguments in turn.
{¶15} First, Mikrolar claims that it was released from performance because it
was prevented from performing. Prevention of performance is a defense to a claim for
breach of contract. Lucarell v. Nationwide Mut. Ins. Co., 152 Ohio St.3d 453, 2018-
Ohio-15, 97 N.E.3d 458, ¶ 68 (“[T]he prevention of performance doctrine precludes a
party who prevents another from performing its contractual obligations from relying
on that failure of performance to assert a claim for breach of contract * * *.”).
7
OHIO FIRST DISTRICT COURT OF APPEALS
According to Mikrolar, Meyer Tool’s failure to schedule delivery of the second hexapod
until nearly three years after entering into the purchase agreement constitutes a
prevention of performance.
{¶16} But beyond a few discussions regarding scheduling a delivery, Mikrolar
never attempted to deliver the second hexapod. And as discussed above, it is
undisputed that Meyer Tool paid Mikrolar for the hexapod that it never received and
that neither party provided written notice of repudiation of the contract. Mikrolar
protests that it should not be saddled with holding onto the hexapod indefinitely. Fair
enough, but nothing prevented it from actually delivering the product, or from
continuing to store the second hexapod and perhaps charging Meyer Tool with the
associated storage costs. Mikrolar alone made the unilateral decision to dismantle or
otherwise dispose of the hexapod without advising Meyer Tool that it intended to do
so.
{¶17} Mikrolar references Stone Excavating, Inc. v. Newmark Homes, Inc.,
2d Dist. Montgomery No. 20307, 2004-Ohio-4119, in support of its assertion that it
was prevented from performing, and therefore did not breach the contract. In Stone
Excavating, plaintiff contractor contracted with defendant developer to lay asphalt,
among other work. Id. at ¶ 2-3. Six months after finishing the other work, plaintiff
asked for permission to lay the second and final layer of asphalt. Defendant declined,
citing the need to complete other work first. Id. at ¶ 6. Two years later, defendant
finally requested that plaintiff lay the second layer of asphalt, but plaintiff refused. Id.
at ¶ 8. The Second District affirmed the trial court’s judgment in favor of plaintiff,
explaining, “[i]t is undisputed that [defendant] refused to allow [plaintiff] to place the
final layer of asphalt within the two-year period the trial court found was a reasonable
8
OHIO FIRST DISTRICT COURT OF APPEALS
time for [plaintiff’s] performance of its promises under the contract. Therefore,
[defendant] cannot rely on [plaintiff’s] failure to perform that work * * * to show non-
performance.” Id. at ¶ 18.
{¶18} However, we can easily distinguish Stone Excavating from the case
before us. In Stone Excavating, the court was guided by an existing building
regulation that required contractors to complete all development work within two
years. Id. at ¶ 5. No such regulation requiring delivery of goods within a certain
timeframe is present in the case at hand. And more importantly, the plaintiff in Stone
Excavating never received payment from the defendant for work that the plaintiff later
refused to perform. Id. at ¶ 4. Here, Mikrolar received payment from Meyer Tool for
everything and then refused to deliver the goods as promised. Not surprisingly,
Mikrolar proves unable to point to any case in Ohio where a seller received payment,
declined to supply the good, and the court blessed that arrangement.
{¶19} Next, Mikrolar claims that it was excused from performance because
Meyer Tool exceeded a reasonable time to demand performance.1 Specifically,
Mikrolar argues that Meyer Tool only had a reasonable time to demand delivery, which
it exceeded. Ohio law recognizes that a party has a “reasonable time” to demand
delivery of performance when the promise to perform is clear but the contract fails to
specify any time for performance. See Stocker v. Cochran’s Decorative Curbing Inc.,
7th Dist. Mahoning No. 09 MA 128, 2010-Ohio-1542, ¶ 36; R.C. 1302.22.
{¶20} But none of the cases to which Mikrolar cites stand for the proposition
that if a buyer fails to “demand” delivery of goods for which it has already paid, the
1Mikrolar suggests that, because the contract specified delivery 20 weeks after receipt of order,
Meyer Tool exceeded a reasonable time to demand performance. But Mikrolar concedes that it
worked well past the 20-week timeframe, thus breaching this provision itself.
9
OHIO FIRST DISTRICT COURT OF APPEALS
buyer has forfeited the goods and the money paid for them. And “[t]he obligation of
good faith * * * requires reasonable notification before a contract may be treated as
breached because a reasonable time for delivery or demand has expired. This operates
both in the case of a contract originally indefinite as to time and of one subsequently
made indefinite by waiver.” UCC 2-309, Comment 5; Davis v. Suggs, 10 Ohio App.3d
50, 51, 460 N.E.2d 665 (12th Dist.1983). As discussed above, Mikrolar did not provide
Meyer Tool with notice that it was treating the contract as breached or otherwise
cancelling the contract. We accordingly see no evidence in the record to suggest that
Meyer Tool exceeded a reasonable time to demand performance.
{¶21} Third, Mikrolar asserts that it was excused from performance because
Meyer Tool abandoned the contract. “[A] contract will be treated as abandoned when
the acts of one party, which are inconsistent with the existence of the contract, are
acquiesced in by the other party.” Hunter v. BPS Guard Servs., Inc., 100 Ohio App.3d
532, 541, 654 N.E.2d 405 (10th Dist.1995).
{¶22} But in the case at hand, Meyer Tool paid Mikrolar in full for the two
hexapods and boots—the quintessential act of acknowledging the existence of a
contract. Moreover, in Davis, the Twelfth District considered a seller’s defense of
abandonment. In that case, the buyer paid $1,500 for a truck bed, but found when he
went to retrieve it “over two years later” that the seller had sold it to someone else
without ever providing the original buyer notice. Davis at 51. The seller argued that
there was an implied condition for the buyer to retrieve the truck bed within a
reasonable time, and attempting to retrieve it two years after payment was not
reasonable. Id. The Twelfth District rejected this argument, stating that “ ‘[t]he
obligation of good faith * * * requires reasonable notification before a contract may be
10
OHIO FIRST DISTRICT COURT OF APPEALS
treated as breached * * * .’ ” Id., quoting Comment 5 to R.C. 1302.22 (UCC 2-309).
Here, as discussed above, Mikrolar did not attempt to notify Meyer Tool, in writing or
otherwise, that it was cancelling the contract, reselling the hexapod, or disassembling
the hexapod. And it is well-established in Ohio caselaw that, for a contract to be
abandoned, there must be an “absolute unequivocal relinquishment” of a party’s right.
Davis at 52, quoting State ex rel. Reeder v. Mun. Civ. Serv. Comm., 82 Ohio Law Abs.
225, 237, 165 N.E.2d 490 (C.P. 1958), affirmed 166 N.E.2d 264 (10th Dist.1959).
“Mere non-use is not sufficient to establish the fact of abandonment.” Davis at 52. On
this record—and specifically the fact that Meyer Tool paid Mikrolar for both
hexapods—it cannot be said that Meyer Tool unequivocally relinquished its right to
the delivery of the second hexapod. Accordingly, Mikrolar fails to demonstrate a valid
abandonment defense.
{¶23} Mikrolar goes on to assert that Meyer Tool’s claim for unjust
enrichment fails because a claim for unjust enrichment cannot exist when a contract
governs the transaction. However, the trial court based its decision on its finding that
Mikrolar breached the parties’ contract, and since we agree with that conclusion, it
obviates the need to analyze any unjust enrichment claim.
{¶24} Finally, Mikrolar maintains that Meyer Tool’s damages must be reduced
by virtue of the cancellation provision. The cancellation provision states that “[a]ny
order or contract may be terminated by buyer only upon written notice and payment
of reasonable and proper termination charges plus a fixed sum of 10% of the final net
P.O. price to compensate for disruption in scheduling * * *. Reasonable and proper
termination charges will be as follows: Already purchased components actual price +
20% and the service hours performed at the agreed upon rate. ($100/hr) Added to this
11
OHIO FIRST DISTRICT COURT OF APPEALS
would be 10% of the entire value of the PO.” Relying on this, Mikrolar invokes it to
offset damages.
{¶25} However, as discussed above, Mikrolar adduced no written evidence
that Meyer Tool cancelled the contract, and in fact, Meyer Tool paid in full. Since
neither party invoked the cancellation provision, it would be improper to trigger that
clause to benefit the breaching party.
{¶26} Meyer Tool satisfied its burden of establishing no genuine issue of
material fact on the question of breach of contract, demonstrating that Mikrolar
accepted payment for the second hexapod and two boots, but did not—and cannot—
deliver them as agreed. And as discussed, Mikrolar failed to meet its reciprocal burden
to establish at least a genuine issue of material fact with regard to its various defenses.
Accordingly, Meyer Tool is entitled to summary judgment on its claim for breach of
contract for $70,000, and the trial court properly entered judgment in its favor. We
overrule Mikrolar’s first assignment of error.
III.
{¶27} In its second assignment of error, Mikrolar claims that the trial court
erred in denying its cross-motion for summary judgment, citing the same reasons it
discussed in the first assignment of error. As this is simply a mirror-image of the
analysis of the first assignment of error, we reject it for the same reasons explained
above. The second assignment of error is overruled.
* * *
{¶28} In light of the foregoing analysis, we overrule both of Mikrolar’s
assignments of error and affirm the judgment of the trial court.
Judgment affirmed.
12
OHIO FIRST DISTRICT COURT OF APPEALS
WINKLER, J., concurs.
ZAYAS, P.J., concurs in judgment only.
Please note:
The court has recorded its entry on the date of the release of this opinion.
13