Gary Moderalli Excavating, Inc. v. Trimat Constr., Inc. , 2013 Ohio 1701 ( 2013 )

[Cite as Gary Moderalli Excavating, Inc. v. Trimat Constr., Inc., 2013-Ohio-1701.]
COURT OF APPEALS
TUSCARAWAS COUNTY, OHIO
FIFTH APPELLATE DISTRICT
GARY MODERALLI EXCAVATING, JUDGES:
INC. Hon. W. Scott Gwin, P. J.
Hon. William B. Hoffman, J.
Plaintiff-Appellant Hon. John W. Wise, J.
-vs-
Case Nos. 2012 AP 03 0022 and
TRIMAT CONSTRUCTION, 2012 AP 03 0023
INC., et al.
Defendants-Appellees OPINION
CHARACTER OF PROCEEDING: Civil Appeal from the Court of Common
Pleas, Case No. 2009 CV 05 0419
JUDGMENT: Affirmed in Part; Reversed in Part and
Remanded
DATE OF JUDGMENT ENTRY: April 25, 2013
APPEARANCES:
For Plaintiff-Appellant For Defendants-Appellees
SHIRLEY J. SMITH WILLIAM H. WOODS
1399 E. Western Reserve Road, Suite 2 JONATHAN M. BRYAN
Poland, Ohio 44514 MCNAMARA AND MCNAMARA
88 East Broad Street
TRACEY A. LASLO Suite 1250
325 East Main Street Columbus, Ohio 43215
Alliance, Ohio 44601
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 2
Wise, J.
{¶1} Plaintiff-Appellant Gary Moderalli Excavating, Inc. appeals the post-verdict
decisions of the Tuscarawas County Court of Common Pleas made following a jury trial.
{¶2} Defendant-Appellee in this appeal is Fidelity and Deposit Company of
Maryland.
STATEMENT OF THE FACTS AND CASE
{¶3} Moderalli Excavating, Inc. and Trimat Construction, Inc. are construction
contractors in the State of Ohio.
{¶4} Moderalli was interested in bidding a public works job known as the
Newcomerstown Landfill Cap Project. The landfill cap project required the layer of
topsoil to be stripped down to the base, take the trash and place it over the center of the
landfill area so that it sloped away from the center, spread dirt across the base thereby
creating a sub-base, then cover the sub-base with a two-foot cap of clay material,
followed by six inches of topsoil and seeding. (T. at 35-36, 417-418).
{¶5} Upon discussion with its insurance agent, Jerry Kernan, about the
possibility of getting a bond for the project, Kernan suggested that Moderalli and Trimat
work together to bid the project, with Trimat putting up the bond. (T. at 36, 412-413).
{¶6} On April 14, 2008, Moderalli submitted the bid under Trimat’s name and
the City of Newcomerstown awarded a line item bid contract of $932,814.70 to Trimat.
Trimat entered into a contract with Moderalli to be the main subcontractor on the job,
with a fixed price of $841,849.70. The difference between the two figures, $90,965.00,
is the result of a $10,965.00 bond premium to be paid to the bonding company, Fidelity
and Deposit Company of Maryland, which provided both a payment bond and a surety
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 3
bond on the project; a $50,000.00 fee to Trimat for supplying the bond for the job; and
$30,000.00 payment to Trimat for doing the seeding work on the project.
{¶7} On June 23, 2008, Trimat entered into a written contract with the Village of
Newcomerstown to complete the project consisting of capping the landfill. The contract
provided that time was of the essence and "[t]he Work will be substantially completed
within 120 days after the Village issues a Notice to Proceed. It further provided Trimat
would pay liquidated damages to the Village of $400.00 for each day that expires after
the time specified ... for Substantial Completion until the Work is substantially
complete.”
{¶8} The contract also provided that Trimat would pay Moderalli within five (5)
days of having received progress payments from the city on the contract. (T. at 39-41).
{¶9} On August 4, 2008, the Village issued the Notice to Proceed stating the
work “will commence to run on August 14, 2008” and “the date of Substantial
Completion is December 14, 2008 ...”
{¶10} At this time, Trimat and Moderalli had not yet executed a written
subcontract. Moderalli continued to work without a signed subcontract until September
26, 2008. (T. at 58-60). It was around this time that Trimat’s president Matt Toler
contacted Moderalli and explained to him that Moderalli had to hire Trimat to provide
supervision on the job at the cost of $20,000.00. (T. at 15, 230, 430-31, 737-38, 1486).
That supervision was provided by Maurice Toler. Id.{¶11} At this point, the project schedule called for the Project to be “[c]omplete
within next 30 days except for final top soil and seeding and mulching.”
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 4
{¶12} As progress was made on the project, Trimat made several applications,
for payment for the portion of work that had been completed. Upon approval of the first
application for payment, Trimat received $277,242.24 on September 18, 2008, and
deposited the same the following day. (T. at 16, 72-74, 80, 103-104, 119, 126, 399,
402). Of that amount, Trimat paid $102,534.77 to Moderalli on October 8, 2008. (T. at
16, 76-77, 80, 126, 150, 211, 452). Trimat claimed that the amount withheld was for
payment of the $50,000 bond, the $10,965 premium, $46,377.00 which it stated was to
pay Fred Boyd, who provided dirt and clay for the Project from his nearby property. Id.{¶13} Fred Boyd testified that Trimat actually only paid him $20,000 at that time
and $17,000 in February, 2009. (T. at 17, 242-43). He claims he is still owed $5,377
due under the agreement. (T. at 247, 453-454).
{¶14} Trimat's second application for payment covered the work completed
between August 25th and September 25th of 2008, requesting payment of $216,184.00.
(T. at 17). At this point, the Project was 55.1% complete. Payment on this application
was issued to Trimat on November 10, 2008. Id. Of this amount, Trimat paid Moderalli
$84,839.64 in two-party checks to Moderalli and its subcontractors. (T. at 131-138).
{¶15} The third application for payment covered the period from September 25
to October 24, 2008. (T. at 18, 146-148). Trimat received payment on this application in
the amount of $236,601.60 on March 26, 2009. Id. Trimat did not pay Moderalli
Excavating any money from pay application number three. (T. at 18).
{¶16} The fourth application, for October 25 to November 25, 2008, was
submitted when completion of the project reached 83%. (T. at 18, 160-161). During this
period, the EPA determined that certain soils and product that was being hauled in from
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 5
outside landowners did not meet their certification requirements. (T. at 18). As a result,
Moderalli was directed by Trimat to do extra work burying the tainted topsoil. Id. This
extra work, along with the delays resulting from the EPA issues and inclement weather,
resulted in the filing of multiple change orders, i.e. applications for payment for the extra
work beyond the contract specifications. (T. at 18-19).
{¶17} The first two change orders resulted in additional payments of
$139,596.18.25. (T. at 169-170).
{¶18} Payment applications five and six resulted in payments to Trimat of
$26,031.96 received on July 9, 2009 and $113,041.02, respectively, with no payment
remitted to Moderalli. (T. at 19, 162, 166-170).
{¶19} On December 9, 2008, Moderalli gave Fidelity notice that they were not
receiving payments from Trimat as agreed and were thus seeking claim on the bond. (T.
at 475-76).
{¶20} Moderalli also filed an attested account in order to freeze payment from
the Village of Newcomerstown to Trimat due to non-payment. (T. at 390-395).
{¶21} Fidelity issued a surety bond to Trimat for release of the funds. At the end
of the year, W.E. Quicksall, the engineer on the job, certified that the cap had been
completed. (T. at 21, 197-198, 272).
{¶22} Altogether, Trimat was paid $1,130,627.42 on the Project. Moderalli
received $187,000.31. (T. at 19).
{¶23} After the job had been certified complete by W.E. Quicksall, Trimat
contacted them to suggest that the job was not actually complete, claiming that
Moderalli was roughly one acre short on the landfill cap. (T. at 20).
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 6
{¶24} According to Moderalli, they were prevented by Trimat from working at the
job site during the months of January, February and March, 2009. (T. at 20-21, 487-
493). Moderalli claims that while it disputed Trimat's claim that the job hadn't been
finished, Moderalli Excavating offered to fix whatever issues remained and asked
permission to begin work. Id.{¶25} Moderalli testified that throughout the month of April, 2009, he sent
numerous messages to Trimat indicating that he had equipment and workers on site
ready to complete whatever remaining work Trimat felt was required. (T. at 20-21, 487-
493).
{¶26} On May 1, 2009, Trimat terminated Moderalli Excavating.
{¶27} As a result of such termination, Moderalli initiated the instant litigation to
preserve and enforce its lien rights against Fidelity and Trimat.
{¶28} Plaintiff Moderalli Excavating, Inc. filed a Complaint against Defendants
Trimat Construction, Inc. and Fidelity and Deposit Company of Maryland on claims of
(1) Breach of Contract- Nonpayment of Invoices; (2) Breach of Contract- Extra Work
and Delays; (3) Breach of Contract- Improper Termination of Contract; (4) Claim Against
Lien Bond; (5) Claim Against Payment Bond; and (6) Prompt Payment Act. The case
deals with a subcontract between Trimat, the general contractor, and Moderalli, the
subcontractor, for the construction of a landfill cap for the Village of Newcomerstown,
Ohio.
{¶29} Trimat filed an Answer and Counterclaim against Moderalli Excavating,
alleging causes of action for (1) Breach of Contract; (2) Indemnification; and (3) Unjust
Enrichment.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 7
{¶30} Fidelity filed an Answer but failed to appear or defend at trial.
{¶31} At the conclusion of the trial, the jury returned unanimous verdicts in favor
of Plaintiff Moderalli and against Defendants Trimat and Fidelity on all claims.
{¶32} A number of post-trial motions were filed by all parties following the trial.
The trial court overturned the unanimous jury verdict in favor of Plaintiff Moderalli on its
Wrongful Termination claim and reduced the jury's unanimous damages award of
$903,308.75 in favor of Moderalli on its Breach of Contract claim to $751,010.89.
Further, the trial court denied Plaintiff’s Motion for Verification of Joint and Several
Liability, Motion for Award on Plaintiff’s Verdict on Prompt Payment and Motion for
Attorneys Fees.
{¶33} Appellant Moderalli now appeals these decisions, raising the following
Assignments of Error:
ASSIGNMENTS OF ERROR
{¶34} “I. THE TRIAL COURT ERRONEOUSLY DENIED PLAINTIFF’S CLAIM
FOR 18% INTEREST AND ATTORNEY FEES AND COSTS UNDER OHIO'S PROMPT
PAYMENT ACT, O.R.C. 4113.61. THIS DECISION WAS CONTRARY TO THE JURY
VERDICT FOR PLAINTIFF, THE MANDATORY LANGUAGE OF THE STATUTE, AND
WAS FURTHER AGAINST THE MANIFEST WEIGHT OF THE EVIDENCE.
{¶35} “II. THE TRIAL COURT WRONGFULLY REFUSED TO CERTIFY ALL
JUDGMENTS AS JOINT AND SEVERAL AS BETWEEN TRIMAT CONSTRUCTION,
INC. AND ITS SURETY, FIDELITY AND DEPOSIT COMPANY OF MARYLAND. SAID
ERROR IS CONTRARY TO LAW AND FURTHER AGAINST THE MANIFEST WEIGHT
OF THE EVIDENCE.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 8
{¶36} “III. THE TRIAL COURT ERRED IN GRANTING DEFENDANTS' MOTION
FOR JUDGMENT NOTWITHSTANDING THE VERDICT AS SAID MOTION WAS
FILED OUTSIDE OF THE STATUTORY WINDOW FOR SUCH MOTIONS EXPLICITLY
IMPOSED BY OHIO CIVIL RULE 50(B).
{¶37} “IV. THE TRIAL COURT'S DECISION TO SET ASIDE THE UNANIMOUS
JURY VERDICT IN FAVOR OF PLAINTIFF MODERALLI EXCAVATING, INC. ON ITS
IMPROPER TERMINATION CLAIM WAS NOT ONLY CONTRARY TO THE MANIFEST
WEIGHT OF THE EVIDENCE, IT WAS AN IMPERMISSIBLE USURPING OF THE
JURY'S DECISION ON THE FACTUAL ISSUE OF TRIMAT'S BAD FAITH.
{¶38} “V. THE REDUCTION OF THE JURY'S UNANIMOUS AWARD OF
$903,308.75 IN DAMAGES TO PLAINTIFF MODERALLI EXCAVATING, INC. ON ITS
BREACH OF CONTRACT CLAIM WAS NOT ONLY PREDICATED ON THE TRIAL
COURT'S ERRONEOUS REVERSAL OF THE JURY'S DECISION ON THE
WRONGFUL TERMINATION CLAIM, BUT WAS FURTHER MATHEMATICALLY
UNSOUND, AGAINST THE MANIFEST WEIGHT OF THE EVIDENCE AND
CONTRARY TO OHIO LAW.”
I.
{¶39} In its First Assignment of Error, Appellant claims that the trial court
decision in denying its claim for 18% interest along with attorney fees and costs under
R.C. §4113.61 was against the manifest weight of the evidence. We disagree.
{¶40} Revised Code §4113.61, also known as the Prompt Payment Act,
provides in part:
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 9
{¶41} “(A)(1) If a subcontractor or materialman submits an application or request
for payment or an invoice for materials to a contractor in sufficient time to allow the
contractor to include the application, request, or invoice in his own pay request
submitted to an owner, the contractor, within ten calendar days after receipt of payment
from the owner for improvement to property, shall pay to the: (a) Subcontractor, an
amount that is equal to the percentage of completion of the subcontractor's contract
allowed by the owner for the amount of labor or work performed.
{¶42} “*** If the contractor fails to comply with division (A)(1) of this section, the
contractor shall pay the subcontractor or materialman, in addition to the payment due,
interest in the amount of eighteen per cent per annum of the payment due, beginning on
the eleventh day following the receipt of payment from the owner and ending on the
date of full payment of the payment due plus interest to the subcontractor or
materialman.
{¶43} “*** If a contractor receives any final retainage from the owner for
improvements to property, the contractor shall pay from that retainage each
subcontractor and materialman his proportion of the retainage, within ten calendar days
after receipt of the retainage from the owner, or within the time period provided in a
contract, invoice, or purchase order between the contractor and the subcontractor or
materialman, whichever time period is shorter, provided that the contractor has
determined that the subcontractor's or materialman's work, labor, and materials have
been satisfactorily performed or furnished and that the owner has approved the
subcontractor's or materialman's work, labor, and materials.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 10
{¶44} “If the contractor fails to pay a subcontractor or materialman within the
appropriate time period, the contractor shall pay the subcontractor or materialman, in
addition to the retainage due, interest in the amount of eighteen per cent per annum of
the retainage due, beginning on the eleventh day following the receipt of the retainage
from the owner and ending on the date of full payment of the retainage due plus interest
to the subcontractor or materialman.”
{¶45} As set forth above, R.C. §4113.61, requires a contractor to timely pay its
subcontractor undisputed amounts under the parties' contract and sets forth penalties
for noncompliance. Masiongale Elec.-Mechanical, Inc. v. Constr. One, Inc., 102 Ohio
St.3d 1, 2004-Ohio-1748. Under the Act, a subcontractor “includes any person who
undertakes to construct, alter, erect, improve, repair, demolish, remove, dig, or drill any
part of any improvement under a contract with any person other than the owner, part
owner, or lessee.” R.C. §4113.61(F)(1); R.C. §1311.01(D).
{¶46} Therefore, pursuant to R.C. §4113.61(A)(1), if a subcontractor makes a
timely request for payment, a contractor must pay the subcontractor in proportion to the
work completed within ten calendar days of receiving payment from the owner. A
contractor, however, is permitted to withhold “amounts that may be necessary to resolve
disputed liens or claims involving the work or labor performed or material furnished by
the subcontractor.”
{¶47} The purpose for the act is to provide an incentive for general contractors
to promptly pay subcontractors. Intercargo Ins. Co. v. Mun. Pipe Contractors, Inc. 127
Ohio Misc.2d 48, 2003-Ohio-7363.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 11
{¶48} Failure to comply with these provisions obligates a contractor to pay
interest on the overdue payment at a rate of 18 percent per annum. R.C.
§4113.61(A)(1) and (B)(1). A subcontractor also may file a civil action to recover the
amount due and the statutory interest. R.C. §4113.61(B)(1). If the court determines that
the contractor has not complied with the prompt-payment statute, the court must award
the subcontractor the statutorily prescribed interest. Id. In addition, the prevailing party
is entitled to recover reasonable attorney fees, unless such an award would be
inequitable, together with court costs. R.C. §4113.61(B)(1) and (B)(3).
{¶49} Courts have interpreted that language to mean that prejudgment interest
is not warranted under R.C. §4113.61 where the contractor, in good faith, withholds
amounts when there is a disputed claim. See Consortium Communications v. Cleveland
Telecommunications, Inc., 10th Dist. No. 97APG08-1090. Thus, if the contractor does
not assert a good faith basis to withhold the money, then the subcontractor is entitled to
prejudgment interest. Moreover, where a “contractor has not complied with the prompt-
payment statute, the court must award the subcontractor the statutorily prescribed
interest. * * * In addition, the prevailing party is entitled to recover reasonable attorney
fees, unless such an award would be inequitable, together with court costs.”
Masiongale, 102 Ohio St.3d at 4. Furthermore, R.C. §4113.61(B)(3) states that “[t]he
court shall not award attorney fees under * * * this section if the court determines,
following a hearing on the payment of attorney fees, that the payment of attorney fees to
the prevailing party would be inequitable.”
{¶50} A “prevailing party” is one in whose favor the decision or verdict is
rendered and judgment entered. See Collins v. York, 1st Dist. No. C-000125, quoting
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 12
Hagemeyer v. Sadowski (1993), 86 Ohio App.3d 563, 566; Keal v. Day, 164 Ohio
App.3d 21, 2005-Ohio-5551, at ¶8 (for purposes of a contract providing for reasonable
attorney fees for the prevailing party in any dispute over the contract, the term
“prevailing party” means “one in whose favor the decision or verdict is rendered and
judgment entered”).
{¶51} This Court may not reverse a judgment as against the manifest weight of
the evidence if there is some competent, credible evidence to support the verdict. C.E.
Morris Co. v. Foley Construction Co. (1978), 54 Ohio St.2d 279, 376 N.E.2d 578,
syllabus.
{¶52} In the instant case, Appellant did not request that written interrogatories be
submitted to the jury, an option available pursuant to Civ.R. 49(B). The purpose of
interrogatories is to test the reasoning used by the jury in reaching its decision, so that
the reasoning does not conflict with the verdict.
{¶53} Here, based on the evidence presented, the jury could have found in favor
of Appellant on the Prompt Payment Act claim but not award Appellant any amount of
damages if it also found that Trimat asserted a good faith basis for withholding the
money. Without interrogatories, there is nothing before this Court to indicate why the
jury found as it did. Pursuant to the two-issue rule, a general verdict, untested by
interrogatories, may stand when one or more alternative grounds are properly submitted
to the jury. McCarthy v. Kasperak (1981), 3 Ohio App.3d 206, 208, 3 OBR 234, 236-
237, 444 N.E.2d 472, 475, citing Sites v. Haverstick (1873), 23 Ohio St. 626.
{¶54} Further, Appellant did not object to the verdict form when it was submitted
to the jury or when the jury’s verdict was read. A party may not sit in silence while the
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 13
jury is discharged and then attack the verdict as defective. See Greynolds v. Kurman
(1993), 91 Ohio App.3d 389, 395. We find appellant waived its objection to the jury's
alleged omission by failing to object before the jury was discharged. Schweisberger v.
Weiner, Stark App. No. (Dec. 12, 1995) 1994 CA 00291, 1995 CA 00367.
{¶55} Without interrogatories being submitted to the jury, neither this Court nor
the trial court could know upon what factors the jury based its decision. There is no
evidence to support Appellant's theory that the jury failed to consider all elements of
damages.
{¶56} Appellant’s First Assignment of Error is overruled.
II.
{¶57} In its Second Assignment of Error, Appellant argues that the trial court
erred in failing to grant its post-trial motion to certify all judgments as joint and several
as between Trimat Construction and Fidelity and Deposit Company of Maryland. We
disagree.
{¶58} After the jury reached its verdicts in this case, Appellant filed a post-
judgment motion requesting that the trial court certify that Fidelity and Deposit Company
of Maryland is liable to the extent of the award against Trimat Construction, Inc.
{¶59} Upon review, this Court does not find anywhere in the record where the
issue of joint and several liability was presented to the jury for determination.
{¶60} Appellant cites no case law to support a post-trial determination as to joint
and several liability between the parties when the verdicts themselves are silent as to
same.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 14
{¶61} Without making a determination as to the status of the principal-agent
relationship and any attendant liability as between Trimat and Fidelity and Deposit
Company of Maryland, this Court finds that the trial court did not err in failing to certify
the judgments as joint, and several as such were not raised as an issue at trial.
{¶62} Appellant’s Second Assignment of Error is overruled.
III.
{¶63} In its Third Assignment of Error, Appellant claims that Appellee’s Motion
for Judgment Notwithstanding the Verdict was not timely filed and therefore the trial
court lacked jurisdiction to grant same. We agree.
{¶64} Civ.R. 50(B) Motion for judgment notwithstanding the verdict, provides:
{¶65} “Whether or not a motion to direct a verdict has been made or overruled
and not later than fourteen days after entry of judgment, a party may move to have the
verdict and any judgment entered thereon set aside and to have judgment entered in
accordance with his motion; or if a verdict was not returned such party, within fourteen
days after the jury has been discharged, may move for judgment in accordance with his
motion. A motion for a new trial may be joined with this motion, or a new trial may be
prayed for in the alternative. If a verdict was returned, the court may allow the judgment
to stand or may reopen the judgment. If the judgment is reopened, the court shall either
order a new trial or direct the entry of judgment, but no judgment shall be rendered by
the court on the ground that the verdict is against the weight of the evidence. If no
verdict was returned, the court may direct the entry of judgment or may order a new
trial.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 15
{¶66} The standard for granting a motion for JNOV under Civ.R. 50(B) is the
same used for granting a Civ.R. 50(A) directed verdict. Texler v. D.O. Summers
Cleaners & Shirt Laundry Co. (1998), 81 Ohio St.3d 677, 679, 693 N.E.2d 271; Wagner
v. Roche Laboratories (1996), 77 Ohio St.3d 116, 121, 671 N.E.2d 252, 256, at fn. 2. In
other words, as long as substantial competent evidence supports the non-moving party,
and reasonable minds could reach different conclusions about that evidence, the motion
must be denied. See Strother v. Hutchinson (1981), 67 Ohio St.2d 282, 284-285, 423
N.E.2d 467; Posin v. A.B.C. Motor Court Hotel, Inc. (1976), 45 Ohio St.2d 271, 275, 344
N.E.2d 334.
{¶67} In reviewing a motion for JNOV, courts do not consider the weight of the
evidence or the witness credibility; rather, courts consider the much narrower legal
question of whether sufficient evidence exists to support the verdict. See Fink,
Greenbaum & Wilson, Guide to the Ohio Rules of Civil Procedure (2001 Ed.) 50-8, § 50-
5. Because this is a question of law, appellate courts conduct a de novo review.
Randolph v. Fetty, Lawrence App. No. 02CA9, 2003-Ohio-598, at ¶ 6; Krannitz v. Harris
(Jan. 19, 2001), Pike App. No. 00CA649; Neal v. Blair (Jun. 10, 1999), Lawrence App.
No. 98CA37.
{¶68} In the case sub judice, Appellant argues that Appellee failed to file its
JNOV motion within the requisite fourteen (14) days as provided by the rule.
{¶69} Upon review, we find that Appellee’s JNOV motion was filed on November
9, 2012. It is therefore clear that Appellee did not file its motion within fourteen days of
the trial court’s original October 24, 2012, Judgment Entry. However, it was filed within
fourteen days of the Nunc Pro Tunc Judgment Entry filed on October 28, 2012. The
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 16
Nunc Pro Tunc Entry in this case was filed to include the “there is no just reason for
delay” language pursuant to Civ.R. 54.
{¶70} We must therefore determine whether the Nunc Pro Tunc entry in this
matter extended the time for filing of the JNOV motion.
{¶71} Appellee cites a number of cases that address when a nunc pro tunc order
extends the time for the deadline for the filing of an appeal. However, we are dealing
with the time for the filing of a JNOV motion, not an appeal. Civ.R. 6(B) specifically
states:
{¶72} “When by these rules or by a notice given thereunder or by order of court
an act is required or allowed to be done at or within a specified time, the court for cause
shown may at any time in its discretion (1) with or without motion or notice order the
period enlarged if request therefore is made before the expiration of the period originally
prescribed or as extended by a previous order, or (2) upon motion made after the
expiration of the specified period permit the act to be done where the failure to act was
the result of excusable neglect; but it may not extend the time for taking any action
under Civ.R. 50(B), Civ.R. 59(B), Civ.R. 59(D), and Civ.R. 60(B), except to the extent
and under the conditions stated in them.” (emphasis added).
{¶73} Further, even under an “appeal” analysis, under Ohio law, a “nunc pro
tunc order is entered as of the date of the original judgment, however if there is a
modification which affects the parties’ rights, appeal may be perfected from the actual
date of the nunc pro tunc order.” Perfection Stove Co. v. Scherer (1929), 120 Ohio St.
445. We do not find that simply adding the Civ.R. 54 language, the rights of any party
was modified.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 17
{¶74} We therefore find Appellee’s Motion for Judgment Notwithstanding the
Verdict was not timely filed and Appellant’s Motion to Strike pursuant to Civ.R. 12(F)
should have been granted.
{¶75} Appellant’s Third Assignment of Error is sustained.
IV.
{¶76} In its Fourth Assignment of Error, Appellant argues that the trial court
erred in granting Appellee’s JNOV motion as to Appellant’s claim for improper
termination.
{¶77} Based on our disposition of Assignment of Error III finding that Appellee’s
JNOV motion was not timely filed, we find this Assignment of Error to be well-taken and
sustain same.
V.
{¶78} In its Fifth and final Assignment of Error, Appellant argues that the trial
court erred in reducing the jury’s unanimous damage award. We agree.
{¶79} Here, the jury returned a damage award of $903,308.75 on Appellant’s
breach of contract claim. The trial court, in its Decision on Post-Verdict Motions, stated:
{¶80} “… reasonable minds could not conclude that the Plaintiff is entitled to
damages in the amount of $903,308.75 for its Breach of Contract Claim. Upon review of
the Court file, the Court concludes that an award of $903,308.75 represents full
compensation under the contract as if the contract had been fully performed. The Court
concludes Moderalli Excavating did not fully perform under the contract, which makes a
damages award of $903,308.75, inappropriate.”
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 18
{¶81} The trial court then went on to determine that the evidence showed that
the landfill project was only 83.14% complete when Moderalli was terminated by Trimat
and, therefore, the award should be reduced to 83.14% of $903,308.75, or $751,010.89.
{¶82} The assessment of damages is usually entirely within the discretion of the
jury, and the court is disallowed to alter a jury's decision. Menda ex rel. Justin v.
Springfield Radiologists, Inc., Clark App. No.2001–CA–91, 2002–Ohio–6785. However,
“a remittitur is proper if the jury's award is so excessive as to appear to be the result of
passion or prejudice, or if the amount awarded is against the manifest weight of the
evidence.” Id.{¶83} In Dardinger v. Anthem Blue Cross & Blue Shield, 98 Ohio St.3d 77, 2002-
Ohio-7113, 781 N.E.2d 121, the Supreme Court stated:
{¶84} “The court in Chester Park Co. v. Schulte (1929), 120 Ohio St. 273, 166
N.E. 186, paragraph three of the syllabus, set forth the four criteria necessary for a court
to order a remittitur: (1) unliquidated damages are assessed by a jury, (2) the verdict is
not influenced by passion or prejudice, (3) the award is excessive, and (4) the plaintiff
agrees to the reduction in damages.”
{¶85} In this case, the trial court did not engage in a remittitur analysis prior to
reducing the jury’s damage award and more importantly, the plaintiff did not agree to a
reduction in damages.
{¶86} Further, we have previously found that the trial court did not have the
authority to consider Appellee’s Motion for Judgment Notwithstanding the Verdict, or in
the Alternative, for a New Trial, as same was not timely filed.
{¶87} Appellant’s Fifth Assignment of Error is sustained.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 19
Cross-Appeal
{¶88} Appellee Fidelity and Deposit Company of Maryland also set forth the
following “Cross Assignments of Error” in their brief:
{¶89} “I. THE TRIAL JUDGE ERRED AS A MATTER OF LAW BY FAILING TO
REDUCE THE JUDGMENT AGAINST TRIMAT CONSTRUCTION, INC. ("TRIMAT")
ON GARY MODERALLI EXCAVATING, INC.'S ("MODERALLI") BREACH OF
SUBCONTRACT CLAIM BY THE EXTRA EXPENSES INCURRED BY TRIMAT IN
EXTENDING THE CAP TO COVER ALL OF THE WASTE AS REQUIRED BY
TRIMAT'S CONTRACT WITH THE VILLAGE OF NEWCOMERSTOWN AND IN
COMPLETING THE PROJECT AS ALLEGED IN TRIMAT'S COUNTERCLAIMS.
{¶90} “II. AFTER THE TRIAL JUDGE CORRECTLY HELD THAT TRIMAT HAD
PROPERLY TERMINATED MODERALLI' S SUBCONTRACT AS PROVIDED BY THE
TEXT OF ARTICLE VIII, ¶8.I, THE TRIAL COURT ERRED IN FAILING TO ORDER A
NEW TRIAL ON THE AMOUNT OF DAMAGES, IF ANY, TRIMAT AND MODERALLI
ARE ENTITLED TO RECOVER FROM EACH OTHER UNDER ¶8.1, THE
TERMINATION CLAUSE OF MODERALLI'S SUBCONTRACT.”
{¶91} The subject and application of cross-assignments of error and cross-
appeals are addressed in App.R. 3(C) and the attendant staff note. Cross-assignments
of error are asserted for the purpose of preserving the relief granted in the trial court's
judgment generally for reasons not advanced by the trial court, to further guard against
reversal, and/or to obtain rulings on interlocutory orders, in the event the case is not
affirmed. Cross-appeals are asserted for the purpose of obtaining different relief than
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 20
that granted by the trial court. App.R. 3(C). Rzeszotarski v. Sanborn (June 7, 1996),
11th Dist. No. 95–G–1906
{¶92} Here, Appellee's cross-assignments are in the nature of assignments in a
cross-appeal rather than cross-assignments because they essentially assert errors at
trial. Since no separate notice of appeal was filed with respect to such assignments, we
find such assignments are not properly before us.1
{¶93} Under App.R. 12(A)(2), when assignments of error are not submitted in
proper form, the appellate court is under no obligation to review them. Further, because
we have not ordered a new trial in this matter, these issues are moot because any
determination that this Court would make would have no legal effect on the actual
controversy.
By: Wise, J.
Gwin, P. J., concurs.
Hoffman, J., concurs in part and dissents in part.
___________________________________
___________________________________
___________________________________
JUDGES
JWW/d 0326
1
Appellee Trimat Construction filed a Notice of Appeal in this matter on March 23, 2012,
Case No. 12 AP 03 0023, which was consolidated with the instant appeal. Trimat,
however, never filed a brief or appeared in this matter.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 21
Hoffman, J., concurring in part and dissenting in part
{¶94} I concur I the majority’s analysis and disposition of Appellant’s third, fourth
and fifth assignments of error. I further concur in its analysis and disposition of
Appellees/Cross-Appellants’ “Cross-Assignments of Error.”
{¶95} I find the issue relative to Fidelity’s potential joint liability raised in
Moderalli’s second assignment of error troubling. Trimat did not file a reply brief to
Moderalli’s appellant’s brief. Despite the fact only Moderalli’s second assignment of
error affected Fidelity, Fidelity, nevertheless, responded on Trimat’s behalf to
Moderalli’s other assignments of error. And Fidelity attempted to assert two “Cross-
Assignments of Error” on behalf of Trimat. If Fidelity owes no obligation as surety on
the judgment against Trimat, why has it defended, and indeed pursued additional
affirmative relief from the judgment on Trimat’s part? Wouldn’t it be in Trimat’s best
interest that Fidelity, as surety, be determined to be jointly and severally liable to satisfy
any judgment against it, whether it be jury’s original verdict; the trial court’s judgment
reducing the verdict; or the judgment increased under the prompt pay act claim? I
question if there exists a potential or actual conflict of interest between Fidelity and
Trimat at this juncture.
{¶96} The majority indicates, upon review, it does not find anywhere in the
record where the issue of joint and several liability was presented to the jury for
determination. I agree.
{¶97} However, the record does reflect the jury was instructed as follows:
{¶98} In this case Fidelity agreed to serve as the surety for Trimat. Based on
this surety principal relationship Fidelity agreed to pay certain debt, default and
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 22
monetary damages related to the project in the event Trimat was unable to pay. Under
Ohio law a surety may only be liable to the extent that its agent or principal is liable.
{¶99} Consequently, if you find that Trimat did not wrongfully terminate the
subcontract or breach the subcontract or breach the subcontract then you must find that
Fidelity is not liable for monetary damages to Moderalli under either bond. (Trp. at 1431,
lines 1-11).
{¶100} That instruction is consistent with the position Fidelity took both during and
post trial.
{¶101} Fidelity agreed to act as surety for Trimat on both the payment bond and
the surety bond. “A surety is primarily and jointly liable with the principal debtor. His
obligation is created concurrently with that of the principal debtor.” St. Paul Fire &
Marine Ins. Co. v. Indus. Comm. 30 Ohio St.3d 17, 20 (1987).
{¶102} During the examination of Newcomerstown Mayor Guy, Moderalli read
from the bond document which states, in pertinent part, the principal [Trimat] “…shall
pay all lawful claims of subcontractors, material suppliers and laborers for labor
performed and materials furnished… We [Fidelity] agreeing and assenting that this
undertaking shall be for the benefit of any material suppliers or laborer having just claim
as well as the obligee herein.” (Trp. at 386-390).
{¶103} At that point, Fidelity stipulated they provided a [surety] bond (Trp. at 393-
395) and the trial court assured Moderalli the bond, the attested account, surety “…all
are going to be exhibits in this case.” (Trp. 393-395).
{¶104} In response to Moderalli’s motion for directed verdict against Fidelity and
Trimat, Fidelity’s counsel, Mr. Withee, stated:
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 23
{¶105} “Just very simply, Your Honor, it goes to the heart of the case. Surety is
not liable unless Trimat has been found to have breached its obligations. There’s been
no finding. There is clearly evidence on both sides of that issue. Thus, as a
fundamental matter there can be no liability on the surety bond at this point.”
{¶106} Trp. at (1390-91).
{¶107} Shortly thereafter, Mr. Withee reiterated:
{¶108} “Your Honor, to begin with it’s the same argument as the last one. The
bond is there as security should Trimat be found to be responsible. It’s not a strict
liability situation where a bond is given and automatically must be paid. There must be
a reason to be paying on that bond. That has not been established, or at the very least
there is highly contentious evidences to whether or not that money - - whether or not
Trimat actually did breach.”
{¶109} (Trp. at 1392-93).
{¶110} And finally, in its post-trial Motion for Judgment Notwithstanding the
Verdict filed November 9, 2011, Fidelity states with regard to the verdicts in favor of
Moderalli on the payment and surety bonds, “… Fidelity, as Surety, is only liable to the
extent Trimat is found liable.”
{¶111} Both the surety bond, Exhibit SSS, and the payment bond, Exhibit PPP,
expressly state Fidelity binds itself with Trimat jointly and severally. The jury having
found in favor of Moderalli and against Trimat, I believe Fidelity’s joint and several
liability is established pursuant to the terms of the bonds and its counsel representations
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 24
as a matter of law.2 Accordingly, I respectfully dissent from the majority’s decision to
overrule Moderalli’s second assignment of error.
{¶112} I also respectfully dissent, in part, from the majority’s decision to overrule
Moderalli’s first assignment of error regarding the trial court’s failure to award damages
under Ohio’s Prompt Payment Act.
{¶113} The majority cites the Masiongale Elec. & Intercargo Inc. Co., case which
interpreted R.C. 4113.61(B)(1) and (3) as requiring the court to award the subcontractor
the statutorily prescribed interest, if the court determines the contractor has not
complied with the Prompt Payment Act. However, the majority further notes courts
have interpreted the statute to mean the statutory interest award is not warranted where
the contractor (Trimat), in good faith, withhold amounts when there is a disputed claim.
{¶114} The trial court concluded, in its Decision filed February 23, 2012, “…
Trimat withheld the payments due Moderalli Excavating in good faith based upon a
disputed claim.” (Decision, at p.7, #6). My problem with the trial court’s conclusion is
that this issue had already been submitted to and decided by the jury.
{¶115} The trial court instructed the jury:
2
The jury verdicts in favor of Moderalli on its breach of contract, wrongful termination
and prompt payment act claims name only Trimat as defendant. I have been unable to
find in the record the unexecuted verdict forms to be completed had the jury found
against Moderalli on those claims. I can only surmise there were not separate verdict
forms finding either for or against Moderalli on the claims as they pertained specifically
to Fidelity. I do so, in part, because their absence would be consistent with the trial
court’s instruction noted, supra, concerning Fidelity’s status as surety for Trimat. I do so,
also in part, based upon the trial court’s reading of the second possible verdict form
relative to the breach of contract (read as an example of the verdict forms on the
various counts) which only lists a verdict in favor of Trimat, not Fidelity. In a similar vein,
the verdict in favor of Moderalli against Fidelity on the surety bond showing an award of
$0 in monetary damages is not necessarily inconsistent with the jury instruction Fidelity
is liable as a matter of Ohio law to the extent the agent or principal (Trimat) is liable.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 25
{¶116} Ladies and gentlemen, Moderalli claims that Trimat violated the Ohio law
known as the Prompt Payment Act, and that’s again at Revised Code 4113.61, by
failing to timely release and pay to Moderalli moneys Trimat received from the village by
the preponderance of the evidence; that Moderalli properly submitted and application for
request for payment to Trimat and Trimat filed to timely release the requested moneys
to Moderalli within 10 calendar days after receipt of application or request for payment;
and Trimat failed to have any proper justification for refusing to release the moneys to
Moderalli.
{¶117} Under the Ohio Prompt Payment Act contractors are permitted to withhold
moneys necessary to resolve disputed claims involving work or labor provided by a
subcontractor.
{¶118} Trimat is entitled to withhold moneys from Moderalli under the Ohio
Prompt Payment Act if Trimat can assert a good faith basis to withhold the moneys
related to disputed claims regarding work or labor performed by Moderalli. Such good
faith basis need not be truth but made only in good faith related to the disputed work or
labor provided by Moderalli.
{¶119} Trp. 1431-1432, lines 12-8.
{¶120} This instruction clearly placed before the jury the issue of Trimat’s good
faith in withholding prompt payment. The jury clearly and unanimously responded by
finding for Moderalli and against Trimat on its Prompt Payment Act claim.3 Having
submitted this claim to the jury with the consent of the parties, I find the trial court
usurped the jury’s authority by later finding Trimat acted in good faith. Given the jury’s
3
The verdict form further reflects the jury awarded $0 in damages.
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 26
verdict, I find the trial court erred in failing to award the statutorily mandated interest
award. However, I do not find the trial court’s decision to deny attorney fees for the
successful prosecution of this claim was an abuse of its discretion. Accordingly, I
concur in part and dissent in part from the majority’s decision to overrule Modarelli’s first
assignment of error.
________________________________
HON. WILLIAM B. HOFFMAN
Tuscarawas County, Case Nos. 2012 AP 03 0022 and 2012 AP 03 0023 27
IN THE COURT OF APPEALS FOR TUSCARAWAS COUNTY, OHIO
FIFTH APPELLATE DISTRICT
GARY MODERALLI EXCAVATING, INC. :
:
Plaintiff-Appellant :
:
-vs- : JUDGMENT ENTRY
:
TRIMAT CONSTRUCTION, INC., et al. :
:
Defendants-Appellees : Case Nos, 2012 AP 03 0022 and
: 2012 AP 03 0023
For the reasons stated in our accompanying Memorandum-Opinion, the
judgment of the Court of Common Pleas of Tuscarawas County, Ohio, is affirmed in
part, reversed in part, and remanded for further proceedings consistent with this
opinion.
Costs to be split equally among the parties.
___________________________________
___________________________________
___________________________________
JUDGES