Reede Construction, Inc. v. South Dakota Department of Transportation , 2017 S.D. LEXIS 130 ( 2017 )

#27863-a-DG
2017 S.D. 63IN THE SUPREME COURT
OF THE
STATE OF SOUTH DAKOTA
****
REEDE CONSTRUCTION, INC., Plaintiff, Counterclaim
Defendant and Appellee,
v.
SOUTH DAKOTA DEPARTMENT
OF TRANSPORTATION, Defendant, Counterclaimant
and Appellant.
****
APPEAL FROM THE CIRCUIT COURT OF
THE SECOND JUDICIAL CIRCUIT
MINNEHAHA COUNTY, SOUTH DAKOTA
****
THE HONORABLE JOHN PEKAS
Judge
****
RONALD G. SCHMIDT of
Gunderson, Palmer, Nelson
& Ashmore, LLP
Rapid City, South Dakota Attorneys for plaintiff, counter
claim defendant and appellee.
JUSTIN T. CLARKE of
Davenport, Evans, Hurwitz
& Smith LLP
Sioux Falls, South Dakota
and
EDWIN E. EVANS of
Evans, Haigh & Hinton, LLP
Sioux Falls, South Dakota Attorneys for defendant,
counterclaimant and appellant.
****
CONSIDERED ON BRIEFS
ON FEBRUARY 13, 2017
OPINION FILED 11/01/17
#27863
GILBERTSON, Chief Justice
[¶1.] The South Dakota Department of Transportation (DOT) contracted
with Reede Construction Inc. (Reede) to perform highway construction work in
Sioux Falls. DOT refused to issue a letter of acceptance after requesting numerous
repairs, many of which Reede never performed. Reede eventually left the job and
demanded payment for the repairs it had completed. Reede sued, and DOT
counterclaimed. At trial, the jury returned a verdict awarding no damages to either
party. DOT filed a motion for a new trial, arguing insufficient evidence supported
the jury’s verdict. The circuit court denied the motion, and DOT appeals. We
affirm.
Facts and Procedural History
[¶2.] In March 2006, DOT contracted with Reede to perform work on a
portion of Interstate 29 and Highway 42 in Minnehaha County, South Dakota.
DOT set June 29, 2007, as the completion date. On April 12, 2006, Reede sent a
letter to DOT proposing a modified concrete mix design. DOT approved, appending
a special provision to the contract allowing for a contractor-furnished mix design
“sufficiently workable and finishable for all uses intended[.]” Use of the new mix
design would “not relieve [Reede] from the responsibility for furnishing a concrete
mix that meets specification and workability requirements.”
[¶3.] In late 2006 and early 2007, DOT identified various defects in the
pavement and concrete. On February 1, 2007, DOT sent a preliminary punch list of
items requiring repairs to Reede. The punch list identified numerous instances of
-1-
#27863
cracking and joint spalling. 1 In late April 2007, DOT observed additional cracking
and distress in the concrete. A DOT employee noted in an email that he “[had not]
seen anything quite like this before in new pavement.” Reede responded in early
May that it would repair the cracks it had identified prior to the roads being opened
to traffic. Further, Reede would do so at its own expense. However, Reede
requested reimbursement for repairs resulting from “damage caused by
unforeseeable events beyond the control of the contractor,” e.g., damage caused by
traffic. DOT agreed to compensate Reede for some of these repairs. DOT claimed,
though, that some of the damage stemmed from the concrete mix design and that
Reede had contractually assumed responsibility for costs associated with pavement
performance. Reede disagreed with DOT’s interpretation of the contract, arguing
that while it bore responsibility for the concrete mix design used in the pavement, it
could not be held responsible for performance of the pavement itself.
[¶4.] In June 2007, concerns arose regarding surface finish, transverse and
longitudinal cracking, joint spalling, and other “spider web like cracking.” In late
June, DOT contacted Reede to again request repairs while denying that “acts of God
or others contributed to the pavement failure.” DOT also contacted Reede in July
regarding the need to remove panels on I-29 “due to poor consolidation and
unacceptable finish.” DOT further requested Reede provide DOT “a written
position on the cause of the above noted conditions and the course proposed to
correct these issues.”
1. Joint spalling refers to the breaking off, chipping, cracking, or fraying of
concrete at the joint.
-2-
#27863
[¶5.] In November 2007, Reede sent DOT a letter containing the
observations of James LaFrenz, a concrete expert Reede had hired, regarding the
condition of the project. DOT reviewed LaFrenz’s letter and determined it needed
to conduct further analysis. DOT informed Reede that once it finished its
examination, DOT would issue a work order detailing repairs that needed
completing before Reede could receive final acceptance.
[¶6.] On February 28, 2008, DOT sent Reede a letter listing issues still
outstanding on the project, including the need for concrete pavement repairs. Reede
responded it would make additional inspections of the concrete. In July 2008, DOT
sent Reede a work order requesting pavement repairs. DOT received no response.
In September, DOT requested a written statement detailing what Reede intended to
do. On February 6, 2009, Reede wrote back that it “recogniz[ed] the request to
complete the concrete repairs” and “intend[ed] . . . to execute the work needed to
complete the work requested.” However, Reede again requested reimbursement for
any such repairs. DOT responded that Reede would need to file a formal claim, and
DOT reiterated its position that any costs for repairs should be borne by Reede.
[¶7.] In March 2009, Reede sued DOT, claiming breach of contract, quantum
meruit, and unjust enrichment. DOT counterclaimed for breach of contract and
breach of implied warranty of workmanship. The parties conducted extensive
discovery. On November 9, 2015, a ten-day jury trial commenced. Both sides
offered numerous exhibits, and the jury heard extensive testimony, including from
experts. The jury returned a verdict awarding no damages to either party. On
February 17, 2016, DOT filed a motion for a new trial. On April 11, the circuit court
-3-
#27863
indicated orally that it would deny the motion. On April 13, the court issued its
order denying DOT’s motion for a new trial.
[¶8.] DOT appeals, arguing the circuit court abused its discretion by not
granting DOT’s motion for a new trial. Reede responds that DOT failed to preserve
the issue for review by failing to make a motion for a judgment as a matter of law.
Analysis and Decision
[¶9.] At issue is whether a motion for a judgment as a matter of law must be
made before a motion for a new trial based on insufficient evidence to justify the
verdict. See generally 9B Arthur R. Miller, Federal Practice and Procedure § 2531
(3d ed.), Westlaw (database updated April 2017). DOT argued in its motion for a
new trial that insufficient evidence supported the jury’s verdict. DOT again makes
this argument on appeal. However, Reede contends DOT failed to preserve its right
to appeal on this issue, citing SDCL 15-6-59(f) and SDCL 15-6-50(a)(1)–(2). SDCL
15-6-59(f) provides:
A motion for a new trial shall not be necessary as a prerequisite
to obtain appellate review as to matters specified in subdivisions
15-6-59(a)(6) and (7), and all such matters may be reviewed on
an appeal from the judgment, regardless of whether a motion for
a new trial has been made, provided such matter has been
submitted to the trial court as prescribed in § 15-26A-8.
SDCL 15-6-59(a)(6) provides that a new trial may be granted if there is insufficient
evidence to justify the verdict. SDCL 15-26A-8 provides that a claim of insufficiency
of the evidence is preserved on appeal “without necessity for an application for a
new trial” so long as the appellant made a timely motion for directed verdict,
request for findings, or “other apt motion, offer, or objection[.]” SDCL 15-6-50(a)(1)
provides that a motion for a judgment as a matter of law tests whether “there is no
-4-
#27863
legally sufficient evidentiary basis for a reasonable jury to find for that party on
that issue[.]” SDCL 15-6-50(a)(2) governs when a motion for a judgment as a
matter of law can be made.
[¶10.] Reede argues that to preserve appellate review, SDCL 15-6-59(f) and
15-26A-8 require a timely motion for judgment as a matter of law or other apt
motion be made. According to Reede, “[a] motion for a new trial is not included
within the intent of SDCL §§ 15-6-59(f) and 15-26A-8,” citing Bedney v. Heidt, 1998
S.D. 50, ¶ 16, 578 N.W.2d 570, 573 (“The methods described in SDCL 15-26A-8 do
not include a motion for new trial.”). Reede contends that although DOT made a
motion for a new trial pursuant to SDCL 15-6-59(a)(6), a motion for a new trial is
not an apt motion that preserves DOT’s right to appeal.
[¶11.] However, this argument misconstrues the purpose of SDCL 15-6-59(f).
SDCL 15-6-59(f) simply provides an avenue by which a party can obtain appellate
review for insufficiency of the evidence absent a motion for a new trial. See Pearson
v. Adams, 279 N.W.2d 674, 676-77 (S.D. 1979) (denying review of insufficiency
question because appellant failed to make both a timely motion for a new trial or
“other apt motion”); Unitherm Food Sys., Inc. v. Swift-Eckrich, Inc., 546 U.S. 394,
396, 126 S. Ct. 980, 983, 163 L. Ed. 2d 974 (2006) (holding that failure to make a
renewed motion for judgment as a matter of law pursuant to Rule 50(b) or a motion
for a new trial under Rule 59 precluded trial court’s review of sufficiency of the
evidence challenge). DOT correctly observes that in this case, SDCL 15-6-59(f) and
15-26A-8 “are inapplicable because DOT filed a motion for a new trial.” Indeed,
Reede cites cases supporting this very proposition. See, e.g., Bedney, 1998 S.D. 50,
-5-
#27863
¶¶ 12-17, 578 N.W.2d at 572-73 (holding that failure by circuit court to grant a
motion for a new trial within twenty days pursuant to SDCL 15-6-59(b) meant that
preservation of the issue on appeal required another apt motion under SDCL 15-6-
59(f)); In re Appeals of Bottcher, 78 S.D. 360, 362, 102 N.W.2d 623, 624 (S.D. 1960)
(“Insufficiency of the evidence to justify the decision is one of the causes for granting
a new trial . . . and on appeal from the order made on such application this court
may then inquire into its propriety on that ground.”). 2
[¶12.] Nevertheless, under the facts of this case, DOT’s failure to make a
motion for a judgment as a matter of law forecloses our review of DOT’s claims on
appeal. DOT argues that the evidence was insufficient to support the jury’s verdict
because the “overwhelming evidence presented at trial proved Reede breached the
2. Courts disagree about whether a post-verdict motion for a new trial pursuant
to Rule 59, absent a Rule 50 motion for a judgment as a matter of law,
preserves the issue of insufficiency on appeal. Some courts with statutes
similar to South Dakota’s have said that a motion for a new trial due to
insufficient evidence actually tests the weight of the evidence. See, e.g.,
Kafader v. Baumann, 290 P.3d 236, 239 (Idaho Ct. App. 2012) (“When a
motion for a new trial is based on the ground of insufficient evidence to
justify the verdict, the trial court must weigh the evidence presented at trial
and grant the motion only where the verdict is not in accord with its
assessment of the clear weight of the evidence.”); Gisvold v. Windbreak, Inc.,
730 N.W.2d 597, 598 (N.D. 2007) (“[Trial court] may set aside a jury verdict
when, in considering and weighing all the evidence, the court’s judgment tells
it the verdict is wrong because it is manifestly against the weight of the
evidence.”). This test differs from the one employed in the context of a motion
for a judgment as a matter of law, suggesting that a motion for a new trial
examines a different question. See Miller, supra ¶ 9 § 2531. Nevertheless,
other courts have said that failure to make a motion for a judgment as a
matter of law precludes a motion for a new trial that is based on insufficient
evidence. See, e.g., Union Carbide Chem. & Plastics Tech. Corp. v. Shell Oil
Co., 308 F.3d 1167, 1184 n.7 (Fed. Cir. 2002); Yohannon v. Keene Corp.,
924 F.2d 1255, 1262-63 (3d Cir. 1991); Chambers v. Smith, 198 S.E.2d 806,
809 (W. Va. 1973).
-6-
#27863
parties’ contract” and that such breach caused at least some of DOT’s damages.
DOT’s insufficiency claim thus requires us to make a judgment as a matter of law
on issues of contract interpretation, breach, and causation. However, when asked
at trial whether it wished to make a motion for a judgment as a matter of law, DOT
declined. It claimed issues of fact existed on the question of breach.
[¶13.] Having gambled on the verdict and lost, DOT now attempts to fashion
its request for a judgment as a matter of law as a motion for a new trial. See ING
Global v. United Parcel Serv. Oasis Supply Corp., 757 F.3d 92, 96-97 (2d Cir. 2014)
(finding that a party’s Rule 59(e) motion to alter or amend the judgment “was
substantively identical to judgment as a matter of law under Rule 50, as it sought to
have the jury’s verdict on attorney’s fees set aside and to have judgment entered in
its favor on that issue”); Pediatrix Screening, Inc. v. TeleChem Int’l, Inc., 602 F.3d
541, 552 (3d Cir. 2010) (Jordan, J., dissenting) (“[Appellant] cannot circumvent its
obligation to file a Rule 50 motion by styling its post-trial motion as a [Rule 59]
motion to amend . . . when what it really argues for is judgment as a matter of law
due to insufficient evidence.”). Further, none of the exceptions to foreclosure of
sufficiency questions applied by courts elsewhere apply in this case. See Yohannon
v. Keene Corp., 924 F.2d 1255, 1262 n.7 (3d Cir. 1991) (observing that courts excuse
the failure to make a proper motion for a judgment as a matter of law when it would
prevent a manifest injustice, when no evidence supports the jury’s verdict, or when
the motion can be reinterpreted as a different motion).
[¶14.] Both DOT and Reede testified as to their interpretations of the
contract, and both parties presented expert witnesses on the issues of causation
-7-
#27863
with respect to damage to the road. Moreover, because the jury returned a general
verdict, this Court cannot conclusively determine whether the jury based its verdict
on any number of defenses offered by Reede. This Court has said that it will
“presume a general verdict is based on one or all of the presented theories.”
Gettysburg Sch. Dist. 53-1 v. Helms & Assocs., 2008 S.D. 35, ¶ 16, 751 N.W.2d 266,
273, overruled on other grounds by Casper Lodging, LLC v. Akers, 2015 S.D. 80,
871 N.W.2d 477. “In a civil case, if a general verdict is handed down and the jury
could have decided the case on two theories, one proper and one improper, the
reviewing court will assume that it was decided on the proper theory.” Lenards v.
DeBoer, 2015 S.D. 49, ¶ 14, 865 N.W.2d 867, 871 (quoting Thomas v. Sully Cty.,
2001 S.D. 73, ¶ 7, 629 N.W.2d 590, 592). Without determining as a matter of law
whether Reede breached the contract or that such breach necessarily caused DOT
damages, we cannot say the jury’s verdict was unsupported by any valid legal
theory or evidence. Therefore, the “motion [could] not properly be granted by the
[circuit] court, or upheld on appeal[.]” See ING Global, 757 F.3d at 97.
[¶15.] Affirmed.
[¶16.] ZINTER, SEVERSON, and KERN, Justices, and WILBUR, Retired
Justice, concur.
-8-