Korte-Fusco Joint Venture

ARMED SERVICES BOARD OF CONTRACT APPEALS
Appeal of -- )
)
Korte-Fusco Joint Venture ) ASBCA No. 59767
)
Under Contract No. W912QR-11-C-0037 )
APPEARANCE FOR THE APPELLANT: Kirk J. McCormick, Esq.
Hinckley, Allen & Snyder LLP
Boston, MA
APPEARANCES FOR THE GOVERNMENT: Thomas H. Gourlay, Jr., Esq.
Engineer Chief Trial Attorney
Jennifer M. Payton, Esq.
Engineer Trial Attorney
U.S. Army Engineer District, Louisville
OPINION BY ADMINISTRATIVE JUDGE O'CONNELL
ON THE GOVERNMENT'S MOTION FOR SUMMARY JUDGMENT
This appeal involves a delay claim on a U.S. Army Corps of Engineers (Corps)
construction project. The Corps has filed a motion for summary judgment in which it
contends that a bilateral modification executed after the alleged delays shields the
government from any liability. Because this modification does not clearly release the
claim at issue, the government is not entitled to judgment as a matter of law and we deny
the motion.
STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE MOTION
The following facts are undisputed, unless otherwise noted. 1
1. On 31 August 2011, a contracting officer with the Louisville District of the
Corps executed a contract with appellant, Korte-Fusco Joint Venture (KFJV), for the
design and construction of a project that included a new 400 member Armed Forces
training building and two segmental retaining walls (R4, tab 3 ). Due to a bid protest, the
contracting officer waited until 29 November 2011 to issue the notice to proceed (R4,
tab 4; B. Korte aff. ii 8).
1
Both parties have submitted a statement of undisputed material facts. While appellant
has submitted a detailed response to the government's statement, the government
has not responded to appellant's submission. Under Board Rule 7(c)(2), the Board
may accept as true a fact properly proposed and supported by one party unless the
other party properly responds and establishes that it is in dispute.
2. On 16 May 2012, KFJV entered into a subcontract with NCI-CT, Inc. (NCI),
for work that included construction of the retaining walls (R4, tab 9). According to
appellant, "NCI is prosecuting this Appeal in the name of KFJV with the consent,
cooperation, and authorization of KF JV" ( app. br. at 1 n. l ).
3. NCI first submitted the retaining walls as a construction submittal to KFJV on
31May2012 (R4, tab 6). The government provides a long history of the approval
process in its statement of undisputed facts but for present purposes it suffices to say that
after a series of disapprovals and re-submittals, the Corps did not approve the retaining
walls until more than 13 months after the initial submittal, on 9 July 2013 (R4, tab 64).
4. On 21 August 2013, the parties attended a "Red Zone" meeting, a meeting
contemplated by the contract to occur 60 days before the beneficial occupancy date to
discuss the closeout process (R4, tab 3 at GR4-277, ~ 1.52). The minutes of this meeting
quote a Corps employee as stating that "a pending weather mod and time extension will
be executed" (B. Korte aff., ex. 4 at 2 of 8, ~ 19).
5. Attached to the Red Zone meeting minutes is a "Change Request Register."
This register lists 17 change requests, including request no. 5, which is also identified as
"Ref No R00004" and is listed as a negotiated change of 72 days. Under the heading
"Necessity for Change" it states: "l. Contractor is due an increase in the performance
time due to bid protest of over 3 months delaying the contract start, and several adverse
weather days during the construction period." (B. Korte aff., ex. 4)
6. On 13 September 2013, KFJV and the contracting officer executed bilateral
Modification No. A00004, which extended the time for contract completion by 72 days
but left the contract price unchanged (R4, tab 67). In block 14, Description of
Amendment/Modification. the modification states as follows:
Reference No: R00004
Case 005 - Time Extension
(Id. at 1) In a continuation of block 14, the second page of the modification contains the
following relevant language:
A. SCOPE OF WORK
Case 005 -Time Extension
Performance time is increased 72 calendar days to 702
calendar days. Time extension includes all delays incurred by
the contract up to the date of issuance of this modification.
2
D. CHANGE IN CONTRACT PRICE
Total contract price is unchanged.
E. CHANGE IN CONTRACT TIME
... [I]t is understood and agreed that the contract performance
time is hereby extended 72 calendar days to and including
8 November 2013, at no additional cost to the Government.
F. CLOSING STATEMENT
It is understood and agreed that pursuant to the above, the
contract time is extended the number of calendar days stated,
and the contract price is unchanged as indicated above, which
reflects all credits due to the Government and all debits due
the Contractor.
It is further understood and agreed that this adjustment
constitutes compensation in full on behalf of the Contractor
and its Subcontractors and Suppliers for all costs and markups
directly or indirectly attributable for the change ordered, for
all delays related thereto, for all extended overhead costs, and
for performance of the change within the time frame stated.
7. On 12 May 2014, KFJV submitted the certified claim at issue in this appeal
(R4, tab 73). KFJV sought $1,971,209.19, including $1,753,424.96 for NCI, and a
389-day time extension as a result of Corps delays in approving the retaining wall
submittals (id. at GR4-2533).
8. Prior to execution of Modification No. A00004, NCI informed KFJV on three
occasions that it wanted additional money (R4, tabs 16, 26, 66). KFJV agrees that one of
these documents, an email from NCI dated 27 November 2012 (R4, tab 26), relates to the
retaining wall approval process but points out that this email ended with NCI stating that
it could not "calculate the magnitude of the delay value" until it had a confirmed start
date and experienced the severity of the winter. KFJV disputes any suggestion that the
issues raised in the emails contained at Rule 4, tabs 16 and 66, have any relationship to
approval of the submittals (app. statement of genuine issues`` 14, 62).
3
DECISION
Standard ofReview for Summary Judgment Motions
Pursuant to Board Rule 7(c)(2), the Board looks to Rule 56 of the Federal Rules of
Civil Procedure for guidance in deciding motions for summary judgment. Under
FED. R. C1v. P. 56(a), the Board may grant summary judgment ifthere is no genuine
dispute as to any material fact. In considering such a motion, the evidence of the
nonmovant is to be believed, and all justifiable inferences are to be drawn in its favor.
Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 255 (1986).
Standards Governing Accord and Satisfaction and Releases
Accord and satisfaction occur "when some performance different from that which
was claimed as due is rendered and such substituted performance is accepted by the
claimant as full satisfaction of his claim." Bell BC! Co. v. United States, 570 F.3d 1337,
1340-41 (Fed. Cir. 2009) (quoting Cmty. Heating & Plumbing Co. v. Kelso,
987 F.2d 1575, 1581 (Fed. Cir. 1993)). To prove accord and satisfaction, the government
must show "(l) proper subject matter; (2) competent parties; (3) a meeting of the minds
of the parties; and (4) consideration." Id. at 1341 (quoting O'Connor v. United States,
308 F.3d 1233, 1240 (Fed. Cir. 2002)). In this case, like in Bell BC!, there is no dispute
regarding proper subject matter or competent parties. KFN contends, however, that
there was no meeting of the minds with respect to releasing NCI's delay claim. It also
contends that there was no consideration for KFJV's release.
A release is contractual in nature and must be interpreted in the same manner as
any other contract term or provision. Bell BC!, 570 F.3d at 1341 (citing Metric
Constructors, Inc. v. United States, 314 F.3d 578, 579 (Fed. Cir. 2002)). To resolve this
dispute we must first examine whether the modification is ambiguous; ifthe terms are
unambiguous, we cannot consider extrinsic evidence. McAbee Constr., Inc. v. United
States, 97 F.3d 1431, 1435 (Fed. Cir. 1996). If the modification is ambiguous, requiring
the weighing of extrinsic evidence, the matter generally is not amenable to summary
resolution. Beta Sys., Inc. v. United States, 838 F.2d 1179, 1183 (Fed. Cir. 1988). II
The Government Has Not Carried Its Burden
The government contends that the doctrine of accord and satisfaction bars NCI's
delay claim because Modification No. A00004 contains language that specifically
releases claims for delay. The government relies on the sentence in the modification that
states "Time extension includes all delays incurred by the contract up to the date of
issuance of this modification.'' The government also relies on the sentence that states "It
is further understood and agreed that this adjustment constitutes compensation in full...for
all costs and markups directly or indirectly attributable for the change ordered, for all
delays related thereto." (SOF ii 6)
4
We agree that these sentences, in isolation, could be read to provide for a broad
release of delay claims, at least through the date of the modification. However, when
interpreting a contract, the Board must consider the document as a whole and interpret it
so as to harmonize and give reasonable meaning to all of its parts. NVT Technologies,
Inc. v. United States, 370 F.3d 1153, 1159 (Fed. Cir. 2004). Thus, we must consider all
of the language in the modification at issue.
To begin, close examination of the second sentence that the government relies
upon indicates that the release given may not be as broad as the government contends.
This sentence provides ··It is further understood and agreed that this adjustment
constitutes compensation in full. .. for all costs and markups directly or indirectly
attributable for the change ordered, for all delays related thereto" (emphasis added).
This language at least suggests that KFJV's release is only for the particular "change
ordered" and is not a more general release. The modification does not describe the
"change ordered," although it does cite to "Reference No: R00004" and "Case 005 -
Time Extension." But this does not improve our understanding because the modification
also fails to tell us what Reference No: R00004 and Case 005 mean. While the
government reads this modification to provide for a broad release, we do not believe this
question can be answered without knowing the definition of Reference No. R00004 and
Case 005. Because this question cannot be answered within the four comers of the
document, we hold that the modification is ambiguous. See Edward R. Marden Corp. v.
United States, 803 F.2d 701, 705 (Fed. Cir. 1986) (''if a contract is reasonably susceptible
of more than one interpretation, it is ambiguous'').
Resolution of this issue would require the weighing of extrinsic evidence, which
we will not do on summary judgment. KF JV has submitted extrinsic evidence that, if
nothing else, convinces us that there is a genuine issue for trial. It has submitted
affidavits from Brent and Todd Korte of Korte Construction Company, backed by
documentary evidence, that tell a plausible story that Modification No. A00004 was
intended only to address delays due to the bid protest and weather delays. In their
affidavits, the Kartes discuss much of the history recited in our statement of facts,
namely, that: 1) there was a delay due to a bid protest at the start of the project; 2) the
minutes for the Red Zone meeting state that there was a pending modification for a time
extension; 3) the Change Request Register attached to those meeting minutes states that a
modification for a 72-day time extension had been negotiated due to a bid protest delay at
the start of the project and weather delays; and 4) about three weeks after that meeting,
the parties executed Modification No. A00004, which provided for a 72-day extension
and contained the same or similar descriptive language contained in the Change Request
Register (SOF iii! 1, 4-6; B. Korte aff. iii! 7, 8, 12-17). Both Kartes testified that they
understood A00004 to address the bid protest and weather delays, not any delays relating
to the retaining walls (B. Korte aff. ii 19; T. Korte aff. ii 9). The affidavits and the
attached documentation reinforce our conclusion that there is a material dispute of fact
with respect to whether the parties' intended to resolve NCI's delay claim.
5
The government has not attempted to define or explain "Reference No: R00004"
and "Case 005." In its reply brief, the government changes tactics and asks us to rule, in
limine, that KFJV waived any right to a time extension for delay up to 8 November 2013.
Waiver consists of a voluntary and intentional relinquishment of a known right.
Cherokee Nation v. United States, 355 F.2d 945, 950 (Ct. Cl. 1966). But, as we have
already held, the language of Modification No. A00004 is ambiguous with respect to the
rights KFJV gave up. Thus, the government's waiver argument is no better suited for
summary resolution than its accord and satisfaction argument.
Finally, we have considered the government's contention that at the time it signed
Modification No. A00004, KFJV was aware that NCI would, or was at least
contemplating, the submission of a claim with respect to approval delays. However, this
does not change our analysis on the government's motion for summary judgment. NCI's
notice that it could or would submit a claim is, at best for the government, a piece of
extrinsic evidence that could be considered in determining the intent of the parties when
they executed this modification. The governmenf s demonstration that NCI raised the
possibility of submitting a claim for these approval delays does not alter our conclusion
that the modification is ambiguous and that there are disputed facts as to whether there
was a meeting of the minds.
CONCLUSION
For the foregoing reasons, the government's motion is denied.
Dated: 5 November 2015
SfvLLl '11 o'G~
MICHAEL N. O'CONNELL
Administrative Judge
Armed Services Board
of Contract Appeals
(Signatures continued)
6
I concur I concur
ER RICHARD SHACKLEFORD
Administrative Judge Administrative Judge
Acting Chairman Vice Chairman
Armed Services Board Armed Services Board
of Contract Appeals of Contract Appeals
I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 59767, Appeal of
Korte-Fusco Joint Venture, rendered in conformance with the Board's Charter.
Dated:
JEFFREY D. GARDIN
Recorder, Armed Services
Board of Contract Appeals
7