Coastal Environmental Group, Inc.

ARMED SERVICES BOARD OF CONTRACT APPEALS
Appeal of -- )
)
Coastal Environmental Group, Inc. ) ASBCA No. 60410
)
Under Contract No. N40085-I3-C-6541 )
APPEARANCES FOR THE APPELLANT: John M. Manfredonia, Esq.
James Petersen, Esq.
Manfredonia Law Offices, LLC
Cresskill, NJ
APPEARANCES FOR THE GOVERNMENT: Ronald J. Borro, Esq.
Navy Chief Trial Attorney
Matthew D. Bordelon, Esq.
Robert R. Kiepura, Esq.
Trial Attorneys
OPINION BY ADMINISTRATIVE JUDGE MCILMAIL
FINDINGS OF FACT
On September 23, 2013, the parties contracted for appellant to make repairs to
the Security Boat Marina at Naval Weapons Station Earle, Leonardo, New Jersey (R4,
tab 5 at 204, 206). Specifically, the work consisted of work to three in-water features;
namely, a "short wall," a "long wall;' and a buoy (id. at 233-34, ,r 6; tr. 3/46). The
contract incorporated by reference Federal Acquisition Regulation (FAR) 52.249-10,
DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984), which provides:
(a) If the Contractor refuses or fails to prosecute the
work or any separable part, with the diligence that will
insure its completion within the time specified in this
contract including any extension, or fails to complete the
work within this time, the Government may, by written
notice to the Contractor, terminate the right to proceed
with the work (or the separable part of the work) that has
been delayed.
(R4, tab 5 at 209) The contract provided 13 5 days from the date of award to complete
the work; that is, through February 5, 2014 (see id. at 203).
 Unless otherwise indicated, the following events all occurred in 2015. On
January 8, the government ordered appellant to stop work, stating that "no work shall
commence until you receive further notice from the Government" (app. supp. R4,
tab 66 at 1-2 ). On July 31, in Modification No. 5, the parties agreed ( 1) to an increase
in the contract price; (2) that "[i]n conjunction with the work specified in the subject
contract," appellant would "[r]epair additional damage to the wave screen ... that
occurred since contract award"; and (3) that the contract completion date would be
November 26, 2015 (R4, tab 7 at 381-82). The modification included the following
"Contractor's release":
Acceptance of this modification by the contractor
constitutes an accord and satisfaction and represents
payment in full for both time and money and for any and
all costs, impact effect, and for delays and disruptions
arising out of, or incidental to, the work as herein revised.
(Id. at 382,, 5 (emphasis added)) 1
On September 15, the government requested that appellant provide an updated
project schedule by the following day (R4, tab 20 at 428). Two days later, on
September 17, the government told appellant that it "must contact this office in writing
by 4:00 p.m. today if you plan to meet the terms of your contract by the scheduled
completion date" (id. at 427-28). The government stated further that "[i]fthe
requested information is not provided today or if you have determined that you are no
longer able to meet the obligations within your contract, the Government intends to
move forward and terminate your contract for default" (id. at 428). Minutes before the
4:00 p.m. deadline, appellant provided to the government a project schedule that
indicated (among other things) that it would take three days to complete the
mobilization of equipment and materials to the site, and that if mobilization were
complete by September 30, appellant would complete the contract work on
November 26, 58 days later (see id. at 429, lines 22-23, 60).
On October 5, the government complained to appellant that appellant had not
"completed or met one single item" on its September 17, 2015 schedule (R4, tab 22
at 434 ). Appellant responded on the same day, acknowledging that it was "behind
schedule" and that it had not yet mobilized to the site, explaining that that it had
"intentions of mobilizing within the next two weeks" (id. at 433). Appellant explained
that "whaler systems ... are waiting to be delivered onsite," that "additional sheet
1
Prior to the execution of Modification No. 5, the parties had bilaterally executed
Modification Nos. 2 through 4 which collectively had extended the contract
completion date to December 30, 2014. Each of those modifications included
the same release language as in No. 5. (App. supp. R4, tabs 10-12)
2
piles ... are awaiting confirmation oflead time and delivery," and that "[m]iscellaneous
steel and timber capping shall be provided by the Subcontractor" (id.). Appellant
further stated that it was "working to confirm exact dates in order to provide an
updated schedule" to the government (id. (emphasis added)). By October 8, 2015,
appellant had not mobilized its equipment and materials to the site (see tr. 3/169-70).
On October 8, with 50 days remaining before the November 26 contract
completion deadline, the contracting officer terminated the contract for default, citing
"continued lack of progress thereby endangering completion as required by the
contract" (R4, tab 25). Appellant appealed to the Board on January 8, 2016.
Appellant is a New York corporation that dissolved on June 29, 2016 (tr. 3/110, 114).
The project manager of a maritime construction company that appellant had
planned to hire to perform the onsite work testified at the hearing of the appeal that the
company was prepared to perform the work and complete it by November 26, 2015,
working only 8 hours per day, but that~ "ifthere was any kind of need to escalate, we
had 24 hours a day to work" (tr. 4/13-14). The project manager provided a breakdown
of how the work would have progressed, including that most of the work would have
progressed simultaneously (tr. 4/20-21, 29, 33).
DECISION
Appellant wants the termination for default converted to one for the
convenience of the government. The government says that the Board does not possess
jurisdiction to entertain the appeal because appellant is a New York corporation that
has been dissolved since June 29, 2016 (see gov't br. at 25). We look to the law of the
state of incorporation to answer that question. See TPS, Inc., ASBCA No. 52421,
01-1 BCA ,i 31,375 at 154,916. Under New York law, "[t]he dissolution ofa
corporation shall not affect any remedy available to or against such corporation ... for
any right or claim existing ... before such dissolution." N.Y. Bus. Corp. Law§ 1006(b)
(McKinney 2018). The "right or claim" here, appellant's challenge to the government's
termination of its contract, arose on the date of that termination: October 8, 2015. The
subsequent dissolution of appellant does not affect appellant's capacity to appeal from
the termination of the contract, or our jurisdiction to entertain that appeal.
Regarding the termination of the contract for default for failure to make progress
("continued lack of progress," as the contracting officer put it), the question is whether the
government has demonstrated that on October 8, 2015 (the termination date), it was
reasonable to conclude that there was no reasonable likelihood that appellant would
complete the project by November 26, 2015 (the contract completion date). See
Securiforce International America, LLC v. United States, 879 F.3d 1354, 1364 (Fed. Cir.
2018); Empire Energy Management Systems, Inc. v. Roche, 362 F.3d 1343, 1357 (Fed. Cir.
2004); Nelson, Inc., ASBCA Nos. 57201, 58166, 16-1 BCA ,i 36,195 at 176,588 (involving
3
FAR 52.249-IO(a)). On September 17, 2015, appellant provided the government a project
schedule indicating that it would take 3 days to mobilize, and 58 days to complete the work
once mobilization was complete. By October 8, only 50 days remained before the
November 26 contract completion date, and appellant had not begun mobilization.
Moreover, on October 5, only three days before the October 8 termination of the contract,
appellant told the government that a new project schedule was forthcoming, and that it
intended to mobilize within "the next two weeks." Those events indicated that, as of
I October 8, 2015, (1) appellant's September 17 schedule projecting contract completion by
the November 26 contract completion date was no longer operative; (2) the earliest
appellant could complete the work (and only if it commenced mobilization immediately;
that is, by October 9) was December 9, 2015, 13 days after the contract completion date;
and (3) appellant might not complete mobilization until October 19 (14 days after its
October5 communication), in which case it would not complete the work until
December 16, 2015, 20 days after the contract completion date. Those facts made it
reasonable to conclude on October 8, 2015, that there was no reasonable likelihood
appellant would to complete the project by November 26, 2015 (the contract completion
date). Cf Empire Energy, 362 F.3d at 1357-58 (affirming denial of appeal from
termination of contract for default for failure to make progress where contractor was
154 days from contract completion with only 106 days to complete on time).
Appellant says that it could have completed the work on time, pointing to the
testimony of the project manager of the maritime construction company that appellant
had planned to hire, who testified that the work could have been completed by
November 26, 2015, working only one shift per day, or through acceleration, if
necessary. That post-termination evidence does not change our conclusion; the issue is
whether it was reasonable to conclude on October 8, 2015, that there was no reasonable
likelihood that appellant would complete work within the time remaining. See
Securiforce, 879 F.3d at 1364; McDonnell Douglas Corp. v. United States, 323 F.3d
1006, 1017 (Fed. Cir. 2003) ("Limiting the inquiry to the time of the termination action
reduces the potential for hindsight bias."). Appellant points to no evidence that the
government was aware on October 8, 2015, of any plan to complete the work between
then and November 26, 2015, even through acceleration. Indeed, what appellant had
told the government by then indicated that appellant needed at least 13 days more than
remained to complete the work. Consequently, the termination for default is justified.
Now it's up to appellant to demonstrate that its default was excusable. See
Joseph Sottolano, ASBCA Nos. 59081, 60043, 16-1BCA136,315 at 177,065.
Appellant says that the real contract completion date is June 15, 2016, because the
government stopped work from January 8 through July 29, 2015, when the parties
entered Modification No. 5 (app. br. at 12-13, 19 n.3). Modification No. 5, without
saying so, lifted the government's January 8, 2015 stop-work order by setting a new
4
contract completion date. 2 However, in the modification's "Contractor's release,"
appellant waived any pre-modification causes of government-caused delay. Appellant
says that the release is limited by the phrase "the work as herein revised" to the
additional repairs to the wave screen that are specified in the modification (app. hr.
at 14 ), but the release doesn't use a phrase, for example, like "the revisions to the work
herein" that might have limited its application to the work introduced by the
modification. Compare Ingalls Shipbuilding Div., Litton Sys., Inc., ASBCA
No. 17579, 78-1 BCA 1 13,038 at 63,663 (release stating "in full and final settlement
of all claims arising out of this modification .. .including all claims for delays and
disruption resulting from, caused by, or incident to such modifications or change
orders" was "for the particular modifications ... referenced"). Rather, the "work"
referenced in the release is the same "work specified in the subject contract"
referenced elsewhere in Modification No. 5. The modification revises the "work
specified in the subject contract" by adding to that work the repairs to the wave screen
referenced (as the release describes) "herein"; that is, in the modification. The release
then, applies to "any and all... delays and disruptions arising out of or incidental to"
the "work specified in the subject contract"; that is, to all the contract work, including
delays arising out of, or incidental to, the government's January 8, 2015 stop-work
order. Cf Great America Construction Co., ASBCA Nos. 60437, 60501, 16-1 BCA
1 36,460 at 177,678 (release "from all liability and from all existing and future claims
and demands that it may have under this contract, insofar as it pertains to the contract"
was a general release that barred all claims). Indeed, with Modification No. 5, the
parties wiped the slate clean and started anew. See Colonial Manufacturing Co.,
ASBCA No. 18703, 75-1BCA111,026 at 52,500. Appellant has not demonstrated
that its default was excusable.
CONCLUSION
The appeal is denied.
Dated: July 17, 2018
--:~
:iM~MAIL
Administrative Judge
Armed Services Board
of Contract Appeals
(Signatures continued)
2
Appellant admits that in its view, "Modification P00005 meant that the Navy's stop
work order had been lifted" (app. br. at 5,126).
5
I concur
~CKLEFORD
Administrative Judge
~/
Administrative Judge
Acting Chairman Vice Chairman
Armed Services Board Armed Services Board
of Contract Appeals of Contract Appeals
I certify that the foregoing is a true copy of the Opinion and Decision of the
Armed Services Board of Contract Appeals in ASBCA No. 60410, Appeal of Coastal
Environmental Group, Inc., rendered in conformance with the Board's Charter.
Dated:
I JEFFREY D. GARDIN
Recorder, Armed Services
Board of Contract Appeals
6