Dearborn Maple Venture, LLC v. SCI Illinois Services, Inc.

ILLINOIS OFFICIAL REPORTS
Appellate Court
Dearborn Maple Venture, LLC v. SCI Illinois Services, Inc., 2012 IL App (1st) 103513Appellate Court DEARBORN MAPLE VENTURE, LLC, Plaintiff and Counterdefendant-
Caption Appellant, v. SCI ILLINOIS SERVICES, INC., Defendant and
Counterplaintiff and Third-Party Plaintiff-Appellee (JDL Development
Interests, LLC, and 1035 N. Dearborn, LLC, Third-Party Defendants-
Appellants).
District & No. First District, Second Division
Docket No. 1-10-3513
Filed April 24, 2012
Rehearing denied May 23, 2012
Modified on denial
of rehearing May 29, 2012
Held In an action arising from a three-part agreement between the parties under
(Note: This syllabus which the third-party plaintiff sold property containing its existing funeral
constitutes no part of business to third-party defendant and third-party defendant was to build
the opinion of the court a residential condominium building on part of the property, a new funeral
but has been prepared home on the rest and then convey the new funeral home to third-party
by the Reporter of plaintiff, the trial court’s holding that third-party defendant was liable for
Decisions for the an “additional sales price” pursuant to the earnest money contract based
convenience of the on the size of the condominium building was affirmed, but the calculation
reader.)
of damages was vacated and the cause was remanded for recalculation to
take into consideration a change in the gross buildable area as a result of
a zoning change.
Decision Under Appeal from the Circuit Court of Cook County, No. 07-CH-19373; the
Review Hon. Nancy J. Arnold, Judge, presiding.
Judgment Affirmed in part and vacated in part; cause remanded with directions.
Counsel on Edwards, Wildman, Palmer, LLP, of Chicago (Michael Dockterman,
Appeal Peter N. Moore, and Nellie L. Viner, of counsel), for appellants.
Valorem Law Group, LLC, of Chicago (Patrick J. Lamb and Nicole
Nehama Auerbach, of counsel), for appellee.
Panel JUSTICE CUNNINGHAM delivered the judgment of the court, with
opinion.
Justices Connors and Harris concurred in the judgment and opinion.
OPINION
¶1 Following a bench trial in the circuit court of Cook County, the trial court entered
judgment in favor of the defendant-appellee, SCI Illinois Services, Inc. (SCI), and against the
plaintiff-appellant, Dearborn Maple Venture, LLC (DMV), and the third-party defendants-
appellants, JDL Development Interests, LLC (JDL), and 1035 N. Dearborn, LLC (1035
LLC), in the amount of $1,757,703, plus costs. On appeal, DMV, JDL and 1035 LLC argue
that: (1) SCI’s first amended counterclaim against them was collaterally estopped by a prior
arbitration award; (2) SCI did not have a separate claim under the parties’ executed “Earnest
Money Contract”; (3) the trial court erred in entering judgment against 1035 LLC; and (4)
the trial court miscalculated the damages pursuant to the terms of the parties’ agreements.
For the following reasons, we affirm in part the judgment of the circuit court of Cook County
and vacate the award of damages and remand for further proceedings consistent with this
opinion.
¶2 BACKGROUND
¶3 SCI was an Illinois corporation engaged in the business of owning and operating funeral
homes. In 2000, SCI owned a parcel of real estate, along with its onsite funeral home, at
1035 North Dearborn Street in Chicago, Illinois (the property).
¶4 In October 2000, SCI decided to sell the property to a developer, JDL, on the condition
-2-
that aside from constructing a high-rise building on the property, JDL would also demolish
the existing funeral home on the property, build a new funeral home in its place and convey
the new funeral home back to SCI in fee simple. After negotiations began, the city of
Chicago rezoned the property such that the maximum “floor area ratio” (FAR) permitted to
be built on the property was reduced from an FAR of 12.0 to 5.0. In connection with this
redevelopment project, SCI’s vice president, Michael Decell (Decell), and JDL’s president
and sole owner, James Letchinger (Letchinger), executed three agreements: the
“Development Agreement,” an “Earnest Money Contract” and the “West Maple Lease
Agreement” (lease agreement).
¶5 The development agreement set forth the details of the redevelopment of the property.
Specifically, it described the redevelopment as a two-part project, which was comprised of
the construction of a new funeral home and the construction of a high-rise residential
condominium building. The development agreement specified the size of the new funeral
home, which shall be completed “within thirty (30) months after the [c]losing,” and required
the high-rise residential condominium to consist of “no greater than 77,895 square feet of
gross buildable area.” The opening paragraphs of the development agreement expressly
stated that the parties “simultaneously” executed the earnest money contract and the lease
agreement, which provided for the sale of the property from SCI to JDL and provided for the
temporary relocation of SCI’s funeral business to a nearby property, respectively. Paragraph
1(g) of the development agreement required JDL to deliver a “letter of credit” in the amount
of $3.5 million to SCI at closing, in order to ensure JDL’s “[full performance of] its
agreements set out herein and in the other agreements between the parties referred to herein.”
Paragraph 5 provided that in the event of a breach of or default on any terms of “this
[a]greement,” the face amount of the letter of credit shall become immediately due and
payable to SCI, and that JDL “shall be released from all obligations hereunder to convey [the
new funeral home] to SCI and SCI shall have no other or further claim or cause of action
against JDL under this [a]greement.” Under paragraph 9, all disputes, except equitable
claims, between the parties “arising under this [a]greement or in any other agreement or
document executed *** by the parties in connection with the transactions contemplated
hereby” shall be solved by binding arbitration. The development agreement further stated,
in paragraph 11(a), that “this [a]greement when executed and delivered, and the [d]ocuments
referred to herein, collectively constitute the entire agreement of the parties with respect to
the subject matter hereof.”
¶6 The earnest money contract set forth the terms of the sale of the property. Under
paragraph 1, SCI agreed to sell the property to JDL for $4 million and that JDL shall pay SCI
an “additional sales price” in an amount “equal to [$51.35] times the number of square feet
of gross buildable area in excess of [77,895 square feet] for which [JDL], its successors or
assigns, obtain the requisite governmental approvals and which is available to [JDL], its
successors and assigns, to build out, or which is in fact built out, at any time prior to
December 31, 2010.” The earnest money contract expressly stated that paragraph 1 “shall
survive [c]losing.”
¶7 The lease agreement was executed by JDL and SCI whereby JDL agreed to lease the
premises at 12 West Maple Street in Chicago as a temporary location for SCI to continue the
-3-
operation of its funeral business while the new funeral home was being constructed by JDL
on the property at issue.
¶8 In December 2000, near the time of closing, JDL and DMV entered into an assignment
agreement by which JDL assigned its rights and obligations under the development
agreement and earnest money contract to DMV. DMV was an Illinois limited liability
company whose sole member was Letchinger. Letchinger, in his capacity as the sole owner
for both JDL and DMV, was the only signatory to the assignment agreement. It is undisputed
that in December 2000, SCI transferred the property to DMV.
¶9 In June 2003, JDL and DMV failed to construct and convey the new funeral home back
to SCI to meet the time deadline directed by the development agreement. This failure to meet
the time deadline was allegedly as a result of the collapse of the real estate market. On July
3, 2003, SCI drew upon the entire amount of the letter of credit and, as a result, received $3.5
million. Thereafter, DMV challenged SCI’s actions and filed a demand for arbitration. It is
undisputed that on May 24, 2004, DMV transferred the property to 1035 LLC. At that time,
Letchinger held a majority ownership interest in1035 LLC and served as its sole manager.
It is also undisputed that in August 2004, the city of Chicago again rezoned the property such
that the maximum FAR permitted to be built on the property increased to an FAR of 5.8. In
2006, the development of the high-rise residential condominium was completed on the
property.
¶ 10 On April 2, 2007, SCI made a demand on JDL for the “additional sales price” under
paragraph 1 of the earnest money contract. Thereafter, JDL, DMV and 1035 LLC all refused
to make any additional payment to SCI for the purchase price of the property.
¶ 11 In October 2007,1 an arbitration hearing was held regarding SCI’s actions of drawing
upon the entire amount of the letter of credit in July 2003. The issue of SCI’s 2007 demand
for an “additional sales price” under the terms of the earnest money contract was not the
subject of the arbitration. On January 22, 2008, in a written arbitration award, the arbitrator
found that SCI was uncooperative with JDL and DMV in finding a solution to the issues
surrounding the delay of constructing the new funeral home, that SCI unreasonably and
incorrectly assumed that it did not need to provide JDL and DMV with an extension of time
for this construction, and that SCI wrongly concluded that, under the circumstances, it could
simply rescind the development agreement and take the entire $3.5 million pursuant to the
letter of credit. The arbitrator further determined that JDL and DMV’s delay in completing
construction of the new funeral home by June 2003 was a material breach of the parties’
development agreement, that the $3.5 million letter of credit did not constitute a valid and
enforceable liquidated damage for the breach committed by JDL and DMV, and that the
actual damages for the breach was $2,118,809 ($1,729,640 plus interest)–which was
measured by putting SCI in the same position it would have been in had the development
agreement never been executed, namely, by calculating what extra amount of money SCI
1
DMV, JDL and 1035 LLC represent to this court in their joint brief on appeal that the
arbitration hearing was held in October 2007, which is unclear in the record before us. However, SCI
does not dispute the accuracy of this time frame.
-4-
would have received from JDL had it sold the entire property to JDL in October 2000
without the condition that a new funeral home be built on the property and reconveyed to
SCI. Because SCI had improperly drawn upon the entire amount of $3.5 million pursuant to
the letter of credit, the arbitrator held that the excess funds of $1,950,932 ($1,381,191, plus
9% interest in the amount of $569,741), must be returned to JDL and DMV.
¶ 12 On June 30, 2008, the arbitration award was confirmed by the circuit court of Cook
County.2 On July 16, 2008, SCI paid JDL and DMV the excess funds in satisfaction of the
arbitration award.
¶ 13 On July 23, 2008, as a result of SCI’s demand for additional payment pursuant to the
“additional sales price” provision under paragraph 1 of the earnest money contract, DMV
filed a complaint against SCI, which sought a declaratory judgment from the trial court
regarding the parties’ rights and obligations under this provision.
¶ 14 On August 31, 2007, SCI filed a counterclaim against DMV, which also named JDL as
a third-party defendant. The counterclaim alleged that JDL and DMV breached the earnest
money contract by failing to pay SCI an “additional sales price” pursuant to paragraph 1 of
the earnest money contract for each square footage in the completed high-rise residential
condominium on the property that exceeded 77,895 square feet. It further alleged that the
total size of the high-rise residential condominium surpassed 77,895 square feet by at least
49,885 square feet and requested that it be awarded damages in the amount of at least
$2,561,594.75.
¶ 15 On March 24, 2009, DMV filed a first amended complaint against SCI, seeking a
declaratory judgment from the trial court that SCI’s act of claiming and receiving the $3.5
million from the letter of credit released DMV from any and all obligations to SCI; that SCI
waived any and all further claims or causes of action against DMV as a result of SCI’s
wrongful conduct in claiming and receiving the $3.5 million pursuant to the letter of credit;
and that SCI was not entitled to any additional payment from DMV or any of its successors
or assigns.
¶ 16 On October 22, 2009, SCI filed a first amended counterclaim, which additionally named
1035 LLC as a third-party defendant. The breach of contract claim (count I) in the first
amended counterclaim substantially mirrored the breach of contract claim in the original
counterclaim, except that it requested damages “in an amount in excess of $1,761,921.20.”
The first amended counterclaim added a successor liability claim (count II), which alleged
that 1035 LLC was jointly and severally liable for the “additional sales price” owed to SCI.
¶ 17 In June 2010, a bench trial was held during which several witnesses testified. In a written
opinion dated September 17, 2010, the trial court entered judgment against DMV on its first
amended complaint, entered judgment in favor of SCI and against DMV, JDL and 1035 LLC
on both counts of SCI’s first amended counterclaim, in the amount of $1,757,703, plus costs.
Specifically, the trial court found that the rights of the parties with regard to the failure of
JDL and DMV to complete the construction and conveyance of a new funeral home to SCI
by the time prescribed in the development agreement had been resolved by arbitration;
2
Case Nos. 03 CH 7330 and 03 L 7389.
-5-
however, whether SCI was still owed “the full purchase price for the entire property [was]
a separate matter” to be determined by the trial court. The trial court noted that the earnest
money contract provided for a “retroactively determined purchase price” which was
dependent on favorable zoning changes by the city of Chicago that were anticipated by the
parties. It further stated that the letter of credit provision under paragraph 5 of the
development agreement, “calling for one which by its own terms expired in August 2003,
could have no bearing on the later events expressly anticipated by the parties in their separate
[e]arnest [m]oney [c]ontract.” The trial court then found that the release provision under
paragraph 5 of the development agreement could not be construed to negate the obligation
for an additional sales price under paragraph 1 of the earnest money contract.
¶ 18 On October 22, 2010, the trial court denied JDL, DMV and 1035 LLC’s motion to
reconsider its September 17, 2010 order. On November 22, 2010, JDL, DMV and 1035 LLC
filed a notice of appeal before this court.
¶ 19 ANALYSIS
¶ 20 We determine the following issues: (1) whether the doctrine of collateral estoppel applied
to bar SCI’s first amended counterclaim against DMV, JDL and 1035 LLC; (2) whether SCI
could maintain a separate claim for an “additional sales price” under the terms of the earnest
money contract; (3) whether the trial court erred in entering judgment against 1035 LLC; and
(4) whether the trial court miscalculated the damages pursuant to the terms of the parties’
agreements.
¶ 21 We first determine whether the doctrine of collateral estoppel applied to bar SCI’s first
amended counterclaim against DMV, JDL and 1035 LLC, which we review de novo. Hope
Clinic for Women, Ltd. v. Adams, 2011 IL App (1st) 101463, ¶ 69.
¶ 22 DMV, JDL and 1035 LLC3 argue that SCI’s first amended counterclaim for an
“additional sales price” under the terms of the earnest money contract was collaterally
estopped by the arbitrator’s findings in the January 2008 arbitration award. Specifically, they
contend that the arbitration award had a preclusive effect on SCI’s claim for additional
payments because the arbitrator found that the development agreement, earnest money
contract and the lease agreement “collectively set forth the terms of the transaction pursuant
to which the [p]roperty was sold by SCI to JDL.” Thus, because the arbitrator had determined
that SCI had rescinded the development agreement, and had made SCI whole by returning
it to a position it would have occupied had SCI sold the property outright, SCI was no longer
entitled to any contractual damages under the earnest money contract. Further, they argue that
the trial court’s finding that SCI was entitled to an “additional sales price” ignored the
arbitrator’s decision and erroneously gave a windfall to SCI. Moreover, they maintain that
SCI was estopped from seeking an “additional sales price” because, in drawing upon the
letter of credit, SCI effectively “released” any further claims or causes of action against them.
¶ 23 SCI counters that DMV, JDL and 1035 LLC failed to show clearly and convincingly that
3
DMV, JDL and 1035 LLC filed joint initial and reply briefs before this court.
-6-
the prior arbitration involved the same issues as the case at bar so as to invoke the doctrine
of collateral estoppel. SCI maintains that the arbitrator did not make any findings that the
parties’ three agreements constituted one agreement, nor was there any discussion in the
arbitration award that SCI’s rescission of the development agreement effectively rescinded
all three agreements. Rather, SCI argues, the arbitrator focused exclusively on, and expressly
limited his holding to, the development agreement in determining the issues presented before
him. Specifically, SCI contends that the arbitrator’s award of damages only corresponded to
the breach of the development agreement, and that the arbitrator’s holding relating to the
development agreement had no bearing on the central questions of the case.
¶ 24 Generally, arbitration awards have the same collateral estoppel effect as court judgments.
Peregrine Financial Group, Inc. v. Martinez, 305 Ill. App. 3d 571, 578-79, 712 N.E.2d 861,
867 (1999). Collateral estoppel is an equitable doctrine that prevents a party from relitigating
an issue that had already been decided in a prior proceeding. Hope Clinic for Women, Inc.,
2011 IL App (1st) 101463, ¶ 69. “However, ‘the judgment in the first suit operates as an
estoppel only as to the point or question actually litigated and determined and not to [any]
other matters which might have been litigated and determined.’ ” (Emphasis in original.) Id.
at ¶ 70 (quoting Nowak v. St. Rita High School, 197 Ill. 2d 381, 390, 757 N.E.2d 471, 477
(2001), citing Housing Authority for La Salle County v. Young Men’s Christian Ass’n of
Ottawa, 101 Ill. 2d 246, 252, 461 N.E.2d 959, 962 (1984)). Collateral estoppel applies when
the minimum threshold of three requirements is met: “(1) the issue decided in the prior
adjudication is identical to the one presented in the current suit; (2) a final judgment on the
merits was entered in the prior adjudication; and (3) the party against whom estoppel is
asserted was a party to or was in privity with a party to the prior adjudication.” Ford Motor
Credit Co. v. Cornfield, 395 Ill. App. 3d 896, 910, 918 N.E.2d 1140, 1153 (2009). “The party
asserting the doctrine of collateral estoppel bears the ‘heavy burden’ of demonstrating with
clarity and certainty what the prior judgment determined.” Peregrine Financial Group, Inc.,
305 Ill. App. 3d at 581, 712 N.E.2d at 868. The application of this doctrine must be
“narrowly tailored to fit the precise facts and issues that were clearly determined in the prior
judgment,” and even if the minimum threshold requirements are met, a court must still
consider the equities of applying this doctrine. (Internal quotation marks omitted.) Hope
Clinic for Women, Inc., 2011 IL App (1st), ¶¶ 70-71.
¶ 25 We find the doctrine of collateral estoppel to be inapplicable to the case at bar. Based on
the record, we find that DMV, JDL and 1035 LLC failed to demonstrate with “clarity and
certainty” that the arbitration award had already determined the issue presented before
us–specifically, whether SCI was entitled to an additional payment under the terms of the
earnest money contract. The arbitration award specified three issues that the arbitrator
resolved, all of which pertained to the development agreement. Those issues were whether
JDL and DMV’s delay in building the new funeral home was a material breach of the
development agreement; whether the $3.5 million letter of credit constituted liquidated
damages for the breach committed by JDL and DMV; and what actual damages were owed
to SCI. The arbitrator expressly found that JDL and DMV materially breached the
development agreement, that SCI intentionally and voluntarily rescinded the development
agreement when it drew upon and received the entirety of the $3.5 million letter of credit,
-7-
that the letter of credit pursuant to paragraph 1(g) of the development agreement did not
constitute a valid and enforceable liquidated damage for the breach, and that the letter of
credit “was meant to ‘assure performance’ ” of the development agreement, and therefore,
SCI was owed actual damages in the amount of $1,729,640, plus interest. Based on these
express findings of the arbitrator, we cannot conclude that the issue in the case at bar was
identical to the ones presented at the arbitration. Thus, we hold that the doctrine of collateral
estoppel was inapplicable to bar SCI’s first amended counterclaim for an additional payment
under the terms of the earnest money contract.
¶ 26 Nonetheless, DMV, JDL and 1035 LLC argue that the arbitration award had a preclusive
effect on the instant cause of action because the arbitrator had also expressly found that the
three executed agreements “collectively set forth the terms of the transaction pursuant to
which the [p]roperty was sold by SCI to JDL.” They argue that the quoted language was an
express finding by the arbitrator that the three agreements constituted a single agreement and
that, as a result, SCI’s rescission of the development agreement effectively prevented it from
seeking damages under the earnest money contract because SCI had already been made
whole for the sale of the entire property. Further, they maintain that the effect of SCI’s
drawing upon the letter of credit “released” DMV, JDL and 1035 LLC from any further
claims or causes of action under any of the three executed agreements.
¶ 27 We find these arguments to be unpersuasive. First, the language relied upon by DMV,
JDL and 1035 LLC was set forth in the “general findings” section of the arbitration award,
along with background facts and circumstances under which the parties engaged in the
business transactions pertaining to the property. In other words, it was a part of the
generalized factual perspective underpinning the transaction. We find that the quoted
language in the arbitration award order which DMV, JDL and 1035 LLC rely upon to support
their argument falls short of meeting the heavy burden of clarity and certainty needed to
prevail. There is no determination by the arbitrator that the three agreements are merged into
a single agreement. See Peregrine Financial Group, Inc., 305 Ill. App. 3d at 581, 712 N.E.2d
at 868 (party asserting collateral estoppel bears the heavy burden of showing with clarity and
certainty what the prior judgment determined). Thus, we reject the contention that SCI’s
rescission of the development agreement necessarily effectuated the rescission of all three
agreements. We note this particularly in light of the arbitrator’s specific and repeated
references throughout the written arbitration award order that SCI had rescinded the
development agreement. Nowhere in the arbitration award order did the arbitrator find that
SCI rescinded the earnest money contract or the lease agreement. Second, as the trial court
correctly found, while the parties’ agreements constituted the parties’ business deal, each was
a separate agreement with its own purpose. Although the arbitrator determined actual
damages owed to SCI as a result of its rescission of the development agreement, the issue of
whether additional payment was due under the earnest money contract was a separate matter.
Further, while DMV, JDL and 1035 LLC argue that SCI had already been made whole by
the arbitration award and had been returned to its pretransaction position, singularly, this
could not and did not alter the fact that the three agreements were separate agreements.
Finally, we find that the release provision under paragraph 5 of the development agreement
referred only to claims under “this [a]greement”–the development agreement–and thus, the
-8-
effect of SCI’s drawing upon the letter of credit did not release DMV, JDL and 1035 LLC
from further claims and causes of action against them which arose from the earnest money
contract. We likewise reject various arguments in DMV, JDL and 1035 LLC’s reply brief in
support of their argument that the doctrine of collateral estoppel applies to the instant case.
A majority of those arguments was premised on the belief that the parties’ agreements were
inseparable. Therefore, we conclude that the first threshold requirement for the doctrine of
collateral estoppel had not been satisfied and we need not address the remaining two
requirements. Accordingly, the arbitration award had no preclusive effect on the instant cause
of action.
¶ 28 Next, we determine whether SCI could maintain a separate claim for an “additional sales
price” under the terms of the earnest money contract.
¶ 29 DMV, JDL and 1035 LLC argue that, even if the doctrine of collateral estoppel was
inapplicable, SCI is barred from recovering an “additional sales price” under the terms of the
earnest money contract because the trial court should have construed the parties’ three
agreements as a single agreement, the effect of which would have released all further claims
and causes of action against them. They maintain that the three agreements should be
construed as a single agreement because they were contemporaneously executed and that,
under this single agreement, SCI had released all further claims against them by invoking the
letter of credit and receiving full satisfaction of its contractual rights from the arbitration
award.
¶ 30 SCI counters that the trial court correctly found that the three agreements were separate
and did not constitute a unified agreement. Thus, SCI argues, the earnest money contract
survived SCI’s rescission of and the release effectuated under the development agreement
so that it could maintain a claim for additional payment under the earnest money contract.
¶ 31 The interpretation of a contract presents a question of law, which we review de novo.
Gallagher v. Lenart, 226 Ill. 2d 208, 219, 874 N.E.2d 43, 50 (2007). “The primary objective
in construing a contract is to give effect to the intent of the parties.” Id. at 232, 874 N.E.2d
at 58. The plain and ordinary meaning of the language of the contract is the best indication
of the parties’ intent. Id. at 233, 874 N.E.2d at 58. “Moreover, because words derive their
meaning from the context in which they are used, a contract must be construed as a whole,
viewing each part in light of the others.” Id. The parties’ intent may not “be gathered from
detached portions of a contract or from any clause or provision standing by itself.” Id. Under
Illinois contract interpretation, “instruments executed at the same time, by the same parties,
for the same purpose, and in the course of the same transaction are regarded as one contract
and will be construed together.” (Emphasis added.) Id. However, such instruments must be
construed as separate agreements when there is evidence that the parties intended for the
documents to be read separately. International Supply Co. v. Campbell, 391 Ill. App. 3d 439,
448, 907 N.E.2d 478, 486 (2009).
¶ 32 In the instant case, the trial court found that “[w]hile all three of the parties’ agreements
constituted the parties’ deal, each was a separate agreement and each had its own purpose.”
We agree with this conclusion. The opening paragraphs of the development agreement
expressly stated that, “[t]hrough various agreements,” the parties intended to provide for the
-9-
sale of the property to JDL, the temporary relocation of SCI’s funeral business to a nearby
location, the redevelopment of the property, and the conveyance of a new funeral home on
the property to SCI. The development agreement further provided that “[t]o accomplish these
purposes, simultaneously with the execution of this [a]greement, the parties have executed
and delivered” the earnest money contract for the sale of the property and the lease agreement
for the temporary relocation of SCI’s funeral business. (Emphasis added.) Based on our
review of the three agreements in their entirety, we find that although they were executed by
the parties in connection with the same business deal, each agreement set forth the specific
terms by which its separate and unique purpose would be fulfilled. Thus, we find that the
parties intended the three agreements, each with a separate purpose, to be construed as
separate agreements. In reaching this conclusion, we are mindful of the language under
paragraph 11(a) of the development agreement, which stated that “[t]his [a]greement, ***
and the [d]ocuments referred to herein, collectively constitute the entire agreement of the
parties with respect to the subject matter hereof and supersede all prior agreements and
understandings between the parties relating thereto.” DMV, JDL and 1035 LLC cite to this
specific clause as evidence that the parties intended for the three agreements to be read as a
single agreement. We reject this contention and find that, this clause, as examined in
isolation, failed to negate the clear intent of the parties for the three agreements to be
construed as separate agreements. See Gallagher, 226 Ill. 2d at 233, 874 N.E.2d at 58 (the
parties’ intent may not “be gathered from detached portions of a contract or from any clause
or provision standing by itself”). Likewise, we reject DMV, JDL and 1035 LLC’s argument
in their reply brief that the “codependency” of the three agreements on one another was
evidence that they should be construed as a single agreement, where the examples cited by
DMV, JDL and 1035 LLC only served to underscore the connection between the three
agreements as constituting the parties’ business deal with regard to the property, but did not
establish an intent by the parties to construe them as a unified contract.
¶ 33 We further find that the plain language of the agreements established the parties’ intent
that the release provision under paragraph 5 of the development agreement did not bar
recovery for an “additional sales price” under the terms of the separate earnest money
contract. The plain language of the development agreement clearly defined the term
“agreement” to include only the development agreement, while it used the term “documents”
to collectively refer to all three agreements. The release provision under paragraph 5 of the
development agreement explicitly barred further claims and causes of action against JDL
under “this [a]greement,” rather than “the documents.” Thus, it is clear and unambiguous that
the parties intended the terms of the earnest money contract to survive SCI’s rescission of
the development agreement and that the triggering of the release provision under the
development agreement had no effect on claims arising from the parties’ other agreements.
Therefore, we find that the trial court properly found that SCI could maintain a separate
claim for, and was entitled to, an “additional sales price” under the terms of the earnest
money contract.
¶ 34 We next determine whether the trial court erred in entering judgment against 1035 LLC,
which we review under a manifest weight of the evidence standard. See Westlake v. C. House
Corp., 2011 IL App (1st) 100653, ¶ 21. “A judgment is not against the manifest weight of
-10-
the evidence unless the opposite conclusion is clearly evident.” Id. A reviewing court accepts
the view of the trier of fact as long as it is reasonable and will not overturn a trial court’s
ruling merely because different conclusions could be drawn from the evidence. Id.¶ 35 DMV, JDL and 1035 LLC argue that the trial court erred in finding 1035 LLC liable to
SCI for an “additional sales price” under the terms of the earnest money contract because it
was not a party to the agreement nor was it a “successor” to either JDL or DMV, where 1035
LLC was formed in an arm’s-length commercial deal and there was no continuity of
ownership between DMV and 1035 LLC.
¶ 36 SCI counters that ample evidence was presented at trial to establish that 1035 LLC was
properly found liable for an additional payment under the earnest money contract because
it had the same ownership and management as DMV, and that 1035 LLC owned and
operated the property through the same entities as DMV. Thus, SCI maintains, 1035 LLC
was merely a continuation of DMV and the transaction between them amounted to a de facto
merger, which allowed the trial court to find 1035 LLC liable under the parties’ agreements.
¶ 37 Generally, “a corporation that purchases the assets of another corporation is not liable for
the debts or liabilities of the transferor corporation.” Vernon v. Schuster, 179 Ill. 2d 338, 344-
45, 688 N.E.2d 1172, 1175 (1997). This rule of “successor corporate nonliability” developed
partly in order to protect bonafide purchasers from unassumed liability. Id. However, four
exceptions to the general rule of successor corporate nonliability exist: “(1) where there is
an express or implied agreement of assumption; (2) where the transaction amounts to a
consolidation or merger of the purchaser or seller corporation; (3) where the purchaser is
merely a continuation of the seller; or (4) where the transaction is for the fraudulent purpose
of escaping liability for the seller’s obligations.” Id. at 345, 688 N.E.2d at 1175-76.
¶ 38 We find that the third exception to the general rule of successor corporate nonliability
applies to these facts, and thus, the trial court properly imposed liability on 1035 LLC, along
with DMV and JDL, for an “additional sales price” owed to SCI under the terms of the
earnest money contract. The “continuation exception” of the rule of successor corporate
nonliability applies “when the purchasing corporation is merely a continuation or
reincarnation of the selling corporation.” Id. at 346, 688 N.E.2d at 1176. “In other words, the
purchasing corporation maintains the same or similar management and ownership, but
merely ‘wears different clothes.’ ” Id. (quoting Bud Antle, Inc. v. Eastern Foods, Inc., 758
F.2d 1451, 1458 (11th Cir. 1985), and citing Nilsson v. Continental Machine Manufacturing
Co., 251 Ill. App. 3d 415, 418, 621 N.E.2d 1032, 1034 (1993)). The test used to determine
whether one corporate entity is a continuation of another is “whether there is a continuation
of the corporate entity of the seller–not whether there is a continuation of the seller’s
business operation.” (Emphases in original.) Vernon, 179 Ill. 2d at 346, 688 N.E.2d at 1176.
A common identity of officers, directors, ownership and stocks between the selling and
purchasing corporation is a key element of what constitutes a “continuation.” Id. at 347, 688
N.E.2d at 1176. However, “the continuity of shareholders necessary to a finding of mere
continuation does not require complete identity between the shareholders of the former and
successor corporations.” Park v. Townson & Alexander, Inc., 287 Ill. App. 3d 772, 775, 679
N.E.2d 107, 110 (1997).
-11-
¶ 39 It is undisputed that, in December 2000, JDL and DMV entered into an assignment
agreement by which JDL assigned its rights and obligations under the development
agreement and earnest money contract to DMV. Letchinger, in his capacity as sole owner for
both JDL and DMV, was the only signatory to the assignment agreement. It is also
undisputed that SCI transferred the property at issue to DMV in December 2000. In May
2004, DMV sold and transferred the property to 1035 LLC. At trial, evidence was presented
that Letchinger wholly owned DMV at the time it sold the property to 1035 LLC, that he had
approximately 60% ownership of 1035 LLC, and that J&A Holdings Corporation (J&A
Holdings)–whose sole shareholder was his wife–had 10% ownership of 1035 LLC. See
generally Steel Co. v. Morgan Marshall Industries, Inc., 278 Ill. App. 3d 241, 249, 662
N.E.2d 595, 600 (1996) (finding that a continuity of shareholders existed to impose successor
corporate liability, where, though the sole shareholder of the predecessor company was not
a shareholder of the successor company, his wife had an ownership interest in the successor
company and he acted as chief executive officer (CEO) of the successor company).
Letchinger testified that DMV was an entity which was set up as an assignee for the property
and that he later established 1035 LLC as a new entity to purchase the property from DMV.
He further testified that both DMV and 1035 LLC had a common purpose of developing the
property at issue, that he served as president of J&A Holdings in May 2004, and that all the
entities shared the same physical office and mailing address. Evidence in the record further
shows that Letchinger signed certain documents on behalf of 1035 LLC in his capacity as
“manager,” and that both 1035 LLC and DMV worked with the same architect, general
contractor and banking institutions in developing the property. Based on our review of the
record, we find that there was sufficient common identity of ownership and management for
both DMV and 1035 LLC to compel the conclusion that 1035 LLC was merely a
continuation of DMV at the time the property was sold to 1035 LLC. Thus, we find that the
“continuity exception” applies to circumvent the general rule of a successor corporation’s
nonliability. Therefore, the trial court’s conclusion that obligations and liabilities owed to
SCI under the earnest money contract should be imposed upon 1035 LLC was not against the
manifest weight of the evidence.
¶ 40 We next examine whether the trial court miscalculated the damages pursuant to the terms
of the parties’ agreements.
¶ 41 DMV, JDL and 1035 LLC argue that the trial court erred in calculating damages owed
to SCI under the terms of the earnest money contract. Specifically, they contend that the trial
court erroneously calculated the damages, and thus arrived at an artificially inflated amount,
by subtracting the FAR-based figure of 77,895 square feet from 112,124.87 square feet,
which was a gross building area that included parking areas and which was not an FAR-
based number. Rather, the trial court should have subtracted 77,895 square feet from 85,030
square feet, which was a gross buildable area that excluded parking areas, in order to arrive
at a figure that was consistent with the Chicago zoning and land use ordinance (Chicago
Municipal Code §§ 17-17-0204, 17-17-0305-B (eff. Aug. 1, 2004)).
¶ 42 SCI counters that the trial court properly used the figure of 112,124.87 square feet in
determining damages owed to it under the “additional sales price” provision of the earnest
money contract.
-12-
¶ 43 In the case at bar, it was stipulated by the parties that paragraph 1 of the earnest money
contract was clear and unambiguous. Paragraph 1 of the earnest money contract provided for
the sale of the property from SCI to JDL for $4 million, and set forth the terms of an
“additional sales price” owed to SCI in an amount “equal to [$51.35] times the number of
square feet of gross buildable area in excess of [77,895 square feet] for which [JDL], its
successors or assigns, obtain the requisite governmental approvals and which is available to
[JDL], its successors and assigns, to build out, or which is in fact built out, at any time prior
to December 31, 2010.” The record shows that John Ernst (Ernst), a commercial real estate
broker, testified at trial that the property at issue had a permissible gross buildable area of
77,895 square feet, which was calculated by multiplying the land area of the property (15,579
square feet) by an FAR of 5.0. The trial court found that 77,895 square feet was a base figure
for the “gross buildable area” used in paragraph 1 of the earnest money contract.
¶ 44 As discussed, the parties stipulated that in August 2004, the city of Chicago rezoned the
property such that the maximum FAR permitted to be built on the property increased to an
FAR of 5.8. At trial, SCI presented the testimony of an architect, David Scott (Architect
Scott), and an engineer, Gregory Lehn (Engineer Lehn), which the trial court found to be
credible. Both Architect Scott and Engineer Lehn testified that the maximum amount of
buildable area permitted by the city of Chicago, based on an increase in FAR value from 5.0
to 5.8, was 90,358.2 square feet (15,579 square feet of land area of the property x FAR 5.8).4
They testified that the figure of 90,358.2 square feet was the total amount of floor area, in
accordance with the city of Chicago’s zoning rules, that was allowed to be built by JDL and
DMV. Architect Scott testified that the developer may choose to build up to the full amount
of the allowable square footage or may choose to build only a portion of the allowable square
footage. Engineer Lehn testified that in his opinion, the total gross building area for the
residential condominium building was 112,124.87 square feet, which included the building’s
parking garage and loading dock areas. However, Engineer Lehn also testified that, after
deducting the square footage for the specified areas such as the parking garage, loading dock,
mechanical equipment shaft, storage areas, and a portion of the elevator shaft in order to
account for the city of Chicago’s zoning rules, the net FAR floor area of the residential
condominium building was 85,030 square feet. See Chicago Municipal Code § 17-17-0305-
B (eff. Aug. 1, 2004) (“[f]or the purpose of calculating floor area ratios, floor area devoted
to required loading, accessory parking and the drive aisles and circulation area associated
with such loading and parking are not to be counted as ‘floor area’ ” (emphasis in original));
Chicago Municipal Code § 17-17-0204 (eff. Aug. 1, 2004) (accessory parking is “[p]arking
provided to comply with minimum off-street parking requirements and non-required parking
that is provided exclusively to serve occupants of or visitors to a particular use, rather than
the public at-large”). Although the ordinance allowed up to 90,358.2 square feet, the
developer chose to build a smaller amount of space, 85,030 square feet, which was within
the ordinance guidelines. The allowable space could be less but could not exceed 90,358.2
square feet as allowed by the ordinance. The record reveals no contrary expert testimony to
Engineer Lehn’s testimony regarding the buildable residential condominium space of 85,030
4
Engineer Lehn rounded this figure up to the nearest whole number of 90,358 square feet.
-13-
square feet for purposes of the zoning ordinance.
¶ 45 The trial court then found that there was no issue as to the meaning of “gross buildable
area” and used the figure of 112,124.87 square feet to calculate the damages owed to SCI
pursuant to paragraph 1 of the earnest money contract. The trial court then found that SCI
was entitled to damages in the amount of $1,757,703 ((112,124.87 square feet - 77,895
square feet) x $51.35), plus costs. Based on our review of the record, we find that the trial
court erred in using the gross building area of 112,124.87 square feet to calculate the number
of square feet in excess of the 77,895 square feet of space that was built as the residential
condominium building. The 112,124.87 square feet figure was one which did not exclude the
specified areas set forth by the Chicago zoning ordinance. In fact, the plan of development
statement for the property at issue expressly stated that, in addition to the exclusions
expressed by the Chicago zoning ordinance for the purposes of FAR calculations, the floor
areas shall not include “all floor area [sic] devoted to mechanical equipment and storage
areas which exceeds 5000 square feet, and *** all floor area [sic] associated with parking
and loading areas.” In reaching this conclusion, we find particularly persuasive DMV, JDL
and 1035 LLC’s argument that the 112,124.87 square feet was the wrong value from which
to calculate SCI’s damages because it exceeded the maximum amount of buildable area
(90,358.2 square feet) permitted by the city of Chicago. Thus, the FAR-based number of
77,895 square feet should be subtracted from the FAR-based figure of 85,030 square feet,
which was the gross buildable area, rather than from a figure (112,124.87 square feet) which
was calculated without regard to the Chicago zoning ordinance’s specified areas of exclusion
and the property’s plan of development statement. As discussed, the 85,030 square feet figure
was the gross buildable area of the residential condominium building after deducting
specified areas excluded by Chicago’s zoning rules. Therefore, the trial court’s calculation
of damages was against the manifest weight of the evidence. See generally Doornbos
Heating & Air Conditioning, Inc. v. Schlenker, 403 Ill. App. 3d 468, 487, 932 N.E.2d 1073,
1091 (2010).
¶ 46 For the foregoing reasons, we affirm the portion of the trial court’s holding that DMV,
JDL and 1035 LLC were liable to SCI for an “additional sales price” pursuant to paragraph
1 of the earnest money contract, and vacate only the trial court’s calculation of damages and
remand the cause to the trial court solely for the recalculation of damages, including costs,
which is consistent with this court’s order. Specifically, the trial court is directed to calculate
the damages based on the figure arrived at by subtracting the FAR-based number of 77,895
square feet from the FAR-based number of 85,030 square feet, which was the buildable
residential space under the zoning ordinance.
¶ 47 Affirmed in part and vacated in part; cause remanded with directions.
-14-