Premier Land Development v. Joseph Kishfy Bel Air Tile Company, Inc. v. Joseph Kishfy

January 11, 2023
Supreme Court
Premier Land Development :
v. : No. 2021-72-Appeal.
(PC 12-341)
Joseph Kishfy et al. :
Bel Air Tile Company, Inc., et al. :
v. : No. 2021-73-Appeal.
(PM 12-1218)
Joseph Kishfy. :
NOTICE: This opinion is subject to formal revision
before publication in the Rhode Island Reporter. Readers
are requested to notify the Opinion Analyst, Supreme
Court of Rhode Island, 250 Benefit Street, Providence,
Rhode Island 02903, at Telephone (401) 222-3258 or
Email: opinionanalyst@courts.ri.gov, of any
typographical or other formal errors in order that
corrections may be made before the opinion is published.
Supreme Court
Premier Land Development :
v. : No. 2021-72-Appeal.
(PC 12-341)
Joseph Kishfy et al. :
Bel Air Tile Company, Inc., et al. :
v. : No. 2021-73-Appeal.
(PM 12-1218)
Joseph Kishfy. :
Present: Suttell, C.J., Goldberg, Robinson, Lynch Prata, and Long, JJ.
OPINION
Justice Goldberg, for the Court. This case came before the Supreme Court
on October 4, 2022, pursuant to an order directing the parties to appear and show
cause why the issues raised in this appeal should not be summarily decided. The
defendant, Joseph Kishfy (defendant), appeals from a final judgment1 entered in
1
The underlying cases, PC 12-341 and PM 12-1218, were consolidated by order of
the Superior Court on January 5, 2018.
-1-
favor of Premier Land Development (plaintiff), arising from a construction contract.2
After considering the parties’ written and oral submissions and reviewing the record,
we are satisfied that cause has not been shown and that this case may be decided
without further briefing or argument. For the reasons stated herein, we affirm the
judgment of the Superior Court.
Facts and Travel
In August 2011, defendant entered into a purchase-and-sales agreement with
Robert Lanni (Lanni) for property located at 15 Paddock Drive, Lincoln, Rhode
Island, for $630,000.00. The defendant agreed to purchase the property “as is,” and
waived all inspections and contingencies, except for radon gas testing. The
defendant himself inspected the property prior to executing the purchase-and-sales
agreement. The defendant testified that the property was structurally complete on
the exterior, with the exception of a rear deck, while the interior of the property was
lacking a kitchen and most flooring, apart from some flooring in the family room.3
A real estate closing was held on August 17, 2011. On the date of the closing,
defendant also entered into a separate contract, designated as an “Amendment to
Purchase and Sales/Construction Agreement” (construction contract) with Lanni and
2
Although, there is a suggestion by defendant that this property constituted new
construction.
3
This property was an existing home, built in 1995.
-2-
plaintiff, which Lanni signed as the owner of the property, and David Corsetti signed
as the contractor.4 This transaction terminated Lanni’s connection to this case. In
the construction contract, defendant agreed to pay plaintiff the sum of $150,000.00
for improvements to the residence at 15 Paddock Drive. Payment was to occur in
three installments, to be mutually agreed upon by the parties, with a project
completion date of no later than October 28, 2011. A time-is-of-the-essence clause
was included in the agreement.
The construction contract contained an itemized list of improvements to be
made to the property, for a total project cost of $150,000.00. The work performed
by plaintiff was to be guaranteed for one year from the date of completion and the
construction contract outlined the allowances for the improvements to be made on
the home. If the amount spent was lower than the allowance granted to defendant,
he would receive a credit; and he would pay the difference if the amount paid was
greater than the allowance.5
Work commenced in August 2011; defendant paid plaintiff $40,000.00 as an
initial deposit. A handwritten note on the check indicated that it was a “1st draw to
4
The parties filed a stipulation that David Corsetti, at all material times, was doing
business as Premier Land Development.
5
The labor to install the kitchen and vanities, and all plumbing and hardware, was
included in the $630,000.00 sale price of the property, and not the construction
contract.
-3-
David Corsetti.” A second check in the amount of $11,000.00 was tendered to
plaintiff on November 11, 2011. The defendant made no further payments to
plaintiff.
As work progressed, there were numerous change orders to the originally
agreed-upon design of the home, all at defendant’s behest. According to plaintiff,
defendant changed the entire layout of the kitchen, which required its subcontractors
to install a new gas line and rewire the electrical lines in the kitchen. The plaintiff
informed defendant that changing the layout of the kitchen would be an extra cost
under the construction contract. Included in the changes to the kitchen layout,
defendant added a room, which required a subcontractor to “build it, frame it, board,
plaster, [and] electric” the space, all of which was an extra cost. The defendant also
requested an elaborate, small, mosaic-like tile back-splash that required extensive
labor, and led to a delay in procuring the tile because defendant purchased tile from
a store different than the one set forth in the construction contract. The plaintiff
again informed defendant that these requested changes were above and beyond the
scope of the construction contract and would constitute additional charges.
The defendant additionally requested a change in the design of the floor in
rooms on the second floor, deviating from the original pattern. The plaintiff
authorized subcontractors to perform this additional labor, which represented an
-4-
extra cost. The defendant also sought changes to certain lighting, replacement of
existing plugs and switches, and construction of framing for a chandelier.
In addition to an increase in costs, the changes to the design of the home
impeded delivery of materials, resulting in delays in the progress of the work. The
owner of Bel-Air Tile Company, Inc., a subcontractor, testified that he was required
to return to the project on multiple occasions because the necessary tiles were not on
site. He further testified that he did not receive certain tiles from defendant until
November 30, 2011, well after the scheduled completion date of October 30, 2011.
The defendant e-mailed Corsetti on December 5, 2011, regarding the delay in
the completion of the work and questioned when the renovations would be
completed. Mr. Corsetti responded that same day reminding defendant that he had
assumed the role of quasi-contractor, had completely retrofitted the original design
of the house, and that his delay in obtaining and delivering the tile had led to the
delay in completion. Mr. Corsetti also informed defendant that plaintiff was owed
a substantial amount of money, the balance of which needed to be addressed. He e-
mailed defendant on December 11, 2011, with an itemized account of the work that
had been completed at that point. There was no response. In the face of defendant’s
silence and his failure to satisfy the outstanding invoice, plaintiff and its
subcontractors ceased work at the property. These consolidated actions ensued.
-5-
In PC 12-341, plaintiff filed an action against defendant and his wife, Paula
Kishfy, alleging one count of breach of contract, one count of unjust enrichment,
and one count of breach of the implied covenant of good faith and fair dealing. The
defendants’ answer denied the allegations of the complaint, and included
counterclaims for breach of contract, negligence, and fraud.
In the second case, PM 12-1218, plaintiff’s subcontractors, Bel-Air Tile
Company, Inc., Continental Engineering & Service Company, Inc., Desimone
Electric, Inc., Moran Home Improvement, and Valley Plumbing & Heating, LLC,
filed a complaint against defendant, each seeking enforcement of a mechanics’ lien,
and collectively alleging a count of unjust enrichment. By order entered on January
5, 2018, these actions were consolidated for trial.
After a jury-waived trial in October 2018, judgment was entered for plaintiff
in the amount of $58,618.00 plus interest.6 The trial justice found that Paula Kishfy
was not a party to the construction contract and had no liability for the breach of
contract. The defendant’s counterclaims were dismissed. The defendant timely
appealed to this Court and asserts that the trial justice erred in her decision,
specifically: (1) in applying the doctrine of merger by deed; (2) in calculating
damages; (3) in allocating responsibility for the bearing wall; (4) in finding that the
6
The trial justice also awarded plaintiff attorneys’ fees but denied an award of costs.
-6-
implied warranty of habitability did not apply; and (5) in finding that the
subcontractors’ mechanics’ liens were assignable to plaintiff.
Standard of Review
“It is well established that the factual findings of a trial justice sitting without
a jury are accorded great weight and will not be disturbed unless the record shows
that the findings clearly are wrong or the trial justice overlooked or misconceived
material evidence.” Wellington Condominium Association v. Wellington Cove
Condominium Association, 68 A.3d 594, 599 (R.I. 2013) (quoting Hernandez v. JS
Pallet Co., 41 A.3d 978, 982 (R.I. 2012)). “If, as we review the record, it becomes
clear to us that the record indicates that competent evidence supports the trial
justice’s findings, we shall not substitute our view of the evidence for [that of the
trial justice] even though a contrary conclusion could have been reached.” Id.(quoting Hernandez, 41 A.3d at 982).
Analysis
Merger by Deed
First, defendant asserts that the trial justice was mistaken in applying the
doctrine of merger by deed because he was contracting with two separate parties,
as the purchase-and-sales agreement governed the transfer of property from Lanni
to defendant, and the construction contract outlined the scope of work to be
performed by plaintiff for defendant.
-7-
“The doctrine of merger by deed provides that once a warranty deed is
accepted it becomes the final statement of the agreement between the parties and
nullifies all provisions of the purchase-and-sale agreement.” Lizotte v. Mitchell, 771
A.2d 884, 887 (R.I. 2001) (quoting Haronian v. Quattrocchi, 653 A.2d 729, 730
(R.I. 1995)). In Lizotte, this Court held that plaintiffs waived all conditions of the
sale when they closed on a property knowing that the lot had not been surveyed and
that they had not obtained a building permit. Id. The warranty deed “became the
final statement of the agreement between the parties, and any purported contract
claims were barred by the doctrine of merger by deed.” Id. at 887-88. In the case
at bar, defendant purchased the home “as is” when he accepted the warranty deed
and waived all contract claims based on the purchase-and-sales agreement.
Although we agree with defendant that there are two separate contracts in this
case, any error by the trial justice in applying the doctrine of merger was harmless
because the trial justice found that defendant materially breached the construction
contract. We will not “set[] aside a verdict or * * * vacat[e], modify[], or otherwise
disturb[] a judgment or order” because of “error or defect in any ruling or order or
in anything done or omitted by the court * * * unless refusal to take such action
appears to the court inconsistent with substantial justice.” Super. R. Civ. P. 61. It
is well settled that a “party’s material breach of contract justifies the nonbreaching
party’s subsequent nonperformance of its contractual obligations.” Machado v.
-8-
Narragansett Bay Insurance Company, 252 A.3d 1206, 1210 (R.I. 2021) (quoting
Women’s Development Corporation v. City of Central Falls, 764 A.2d 151, 158
(R.I. 2001)).
The trial justice in the case at bar found that defendant “materially breached
the [c]onstruction [c]ontract through [his] nonpayment for the original work as well
as the increase in the scope of work.” The trial justice arrived at this conclusion
after a thorough review of testimony and exhibits, finding that the testimony of the
subcontractors and plaintiff was credible, and that plaintiff was justified in stopping
work on the project, due to defendant’s failure to pay. She declared that defendant’s
increase in the scope of work, his failure to make timely delivery of materials, and
nonpayment for the work carried out by plaintiff justified the cessation of work.
“[W]hether a party materially breached his or her contractual duties is a question of
fact.” Machado, 252 A.3d at 1210 (quoting Parker v. Byrne, 996 A.2d 627, 632
(R.I. 2010)). Accordingly, we decline to disturb the findings of the trial justice.
Damages
The defendant contends that the trial justice mistakenly calculated the
damages amounting to $58,618.00. He alleges that the correct starting point for
damages was $69,743.85 (the amount invoiced by the subcontractors), with the
$51,000 paid by defendant to plaintiff to be subtracted from this amount. The
defendant acknowledges that plaintiff may be entitled to a sum for construction
-9-
oversight, but he asserts that plaintiff failed to provide any concrete evidence to
determine this amount.
“The amount of damages sustained from a breach of contract must be proven
with a reasonable degree of certainty * * *.” Management Capital, L.L.C. v. F.A.F.,
Inc., 209 A.3d 1162, 1179 (R.I. 2019) (quoting Marketing Design Source, Inc. v.
Pranda North America, Inc., 799 A.2d 267, 273 (R.I. 2002)). A plaintiff, however,
“will not be denied recovery merely because the damages are difficult to ascertain,”
as long as they “prove damages with reasonable certainty.” Id. (quoting Sophie F.
Bronowski Mulligan Irrevocable Trust v. Bridges, 44 A.3d 116, 120 (R.I. 2012)).
“The existence of damages, including their certainty, is a question for the factfinder
to decide.” Id. (quoting Fogarty v. Palumbo, 163 A.3d 526, 537 (R.I. 2017)).
The trial justice found the testimony of the subcontractors and invoices
submitted for the expanded work completed on the project totaling $41,118.00,
copies of checks provided by plaintiff, as well as plaintiff’s testimony and its claims
of expenses, to be credible. The two checks tendered by defendant totaled
$51,000.00, an amount less than the invoices submitted by the subcontractors, and
far short of the agreed-upon $150,000.00 in the construction contract. In addition to
the $51,000.00 paid to plaintiff, defendant was credited with $81,500.00 for
payments made directly to suppliers and others, leaving a balance of $17,500.00 on
the construction contract. The plaintiff credibly established that defendant owes
- 10 -
$41,118.00 for the expanded scope of work and $17,500.00 on the construction
contract. Therefore, we are satisfied that the trial justice was correct in awarding
damages of $58,618.00 to plaintiff.
Bearing Wall
Next, defendant argues that the trial justice erred in denying his claim that
plaintiff breached the contract by failing to “support [the] basement bearing wall per
engineering specs.” The defendant contends that plaintiff cannot sue for breach of
contract and then argue that a provision working against plaintiff (the bearing wall
provision) should not apply. The defendant further contends that he is entitled to an
offset in the amount of $16,550.00 to cover the cost of remediating the bearing wall.
We disagree.
The defendant materially breached the construction contract by failing to
fulfill his payment obligations and expanding the scope of work without
renumeration. Because of defendant’s material breach of the construction contract,
plaintiff was no longer required to perform. See Machado, 252 A.3d at 1210. Thus,
we hold that the trial justice properly attributed responsibility for the remediation of
the bearing wall to defendant.
Implied Warranty of Habitability
The defendant next asserts that the trial justice erred in finding that the implied
warranty of habitability did not apply to the work on this property. This Court has
- 11 -
held that, “when a builder-vendor sells a new house or one that is under construction,
‘he [or she] implicitly warrants that the construction has been or will be done in a
workmanlike manner and that the dwelling will be reasonably fit for human
habitation.’” Nichols v. R.R. Beaufort & Associates, Inc., 727 A.2d 174, 177 (R.I.
1999) (quoting Padula v. J.J. Deb-Cin Homes, Inc., 111 R.I. 29, 32, 298 A.2d 529,
531 (1973)). We have, however, “refused to extend the application of these implied
warranties to protect used-home buyers in a suit against a vendor who was not also
the builder of the house.” Id. That principle controls our resolution of this issue.
Our review of the record reveals that plaintiff was neither the builder nor seller
of the property at 15 Paddock Drive. The defendant was aware that the home was
not new construction. The defendant cites Casavant v. Campopiano, 114 R.I. 24,
26, 327 A.2d 831, 833 (1974), which applied the warranty of habitability where,
after the home was completed, the builder leased the premises for a year to a third
party before selling it to the buyer, and also Nichols, 727 A.2d at 180, in which this
Court held that the implied warranty of habitability applied to subsequent purchasers
in their action against the original builder. These cases are not persuasive because
plaintiff in the case at bar was tasked with completing the renovations to an existing
structure. We are satisfied that the trial justice correctly concluded that the implied
warranty of habitability had no application to the case at bar.
- 12 -
Assignability of Mechanics’ Liens
Lastly, defendant argues that the subcontractor’s mechanics’ liens were
improperly transferred to plaintiff because, he contends, mechanics’ liens are not
assignable under Rhode Island law. “The purpose of the mechanics’ lien law is to
‘afford a liberal remedy to all who have contributed labor or material towards adding
to the value of the property to which the lien attaches.’” Alpha Omega Construction,
Inc. v. Proprietors of Swan Point Cemetery, 962 A.2d 733, 738 (R.I. 2008) (quoting
Gem Plumbing & Heating Co. v. Rossi, 867 A.2d 796, 803 (R.I. 2005)). Mechanics’
liens are often utilized “because the subcontractor ‘has not been paid by the general
contractor with whom the owner has made an agreement for the overall performance
of improvement to his land.’” Id. (quoting Faraone v. Faraone, 413 A.2d 90, 92
(R.I. 1980)).
This Court held in McDonald v. Kelly, 14 R.I. 335 (1884), that mechanics’
liens are assignable unless a statute declares otherwise. McDonald, 14 R.I. at 337-
38. The defendant attempts to distinguish this case from McDonald by arguing that
McDonald concerned an assignment to do the work, and not an assignment of rights
under a mechanics’ lien. According to defendant, because the work was not assigned
to plaintiff, there is no assignment of record, and G.L. 1956 § 34-28-4.1 prohibits
plaintiff from taking advantage of the mechanics’ lien statute, and the
subcontractors’ mechanics’ liens are not assignable to plaintiff. Prior to 2015, §
- 13 -
34-28-4.1 required general contractors, not subcontractors, to serve notice of intent
to file a lien within ten days of commencing work or delivering materials, or else
lose all rights under the mechanics’ lien statute.7 Section 34-28-4.1, as enacted by
P.L. 2006, ch. 630, § 2. The defendant submits that plaintiff’s failure to comply with
§ 34-28-4.1 by not filing a general contractor’s lien defeats any mechanics’ liens
rights. We disagree.
Although we have yet to address this issue, several treatises and other states
have found mechanics’ liens to be assignable, notably Hunt Truck Sales & Service,
Inc. v. Holopak Village, 363 So. 2d 27 (Fla. Dist. Ct. App. 1978), which held that
“[a] mechanic’s lien or a prospective mechanic’s lien may be assigned[.]” Hunt
Truck Sales & Service, 363 So. 2d at 27; see also 56 C.J.S. Mechanics’ Liens § 270
(Nov. 2022 Update). We know of no prohibition against the assignment of a
subcontractor’s mechanics’ lien to the general contractor. Subcontractors have an
expectation of payment for work performed under a contract with the general
contractor, with whom they are in privity.
Here, the subcontractors perfected their liens in accordance with G.L. 1956 §
34-28-4, and were paid by plaintiff, to its credit. The defendant cannot avoid
7
Section 34-28-4.1 was amended in 2015, substituting “any time prior to
commencing work or delivery of materials” for “within ten (10) business days of
commencing work or delivery of materials[.]” Section 34-28-4.1, as amended by
P.L. 2015, ch. 258, § 1 and P.L. 2015, ch. 279, § 1.
- 14 -
payment under these circumstances. We therefore conclude that the trial justice
correctly found that the assignment of the subcontractors’ mechanics’ liens was
proper.
Conclusion
For the reasons set forth in this opinion, we affirm the judgment of the
Superior Court. The papers in this case may be returned to the Superior Court.
- 15 -
STATE OF RHODE ISLAND
SUPREME COURT – CLERK’S OFFICE
Licht Judicial Complex
250 Benefit Street
Providence, RI 02903
OPINION COVER SHEET
Premier Land Development v. Joseph Kishfy et al.
Title of Case
Bel Air Tile Company, Inc., et al. v. Joseph Kishfy.
No. 2021-72-Appeal.
(PC 12-341)
Case Number
No. 2021-73-Appeal.
(PM 12-1218)
Date Opinion Filed January 11, 2023
Suttell, C.J., Goldberg, Robinson, Lynch Prata, and
Justices
Long, JJ.
Written By Associate Justice Maureen McKenna Goldberg
Source of Appeal Providence County Superior Court
Judicial Officer from Lower Court Associate Justice Sarah Taft-Carter
For Plaintiff:
John O. Mancini, Esq.
Attorney(s) on Appeal
For Defendant:
Barry J. Kusinitz, Esq.
SU-CMS-02A (revised November 2022)