Aries Construction Corporation v. United States

In the United States Court of Federal Claims
No. 22-166C
(Filed: February 21, 2023)
FOR PUBLICATION
***************************************
ARIES CONSTRUCTION *
CORPORATION, *
*
Plaintiff, *
*
v. *
*
THE UNITED STATES, *
*
Defendant. *
*
***************************************
Tara M. Patterson, Tiffany & Bosco, P.A., Phoenix, AZ, for Plaintiff. With her
was William Morris Fischbach, III, Tiffany & Bosco, P.A., Phoenix, AZ.
Daniel F. Roland, Trial Attorney, Commercial Litigation Branch, Civil
Division, United States Department of Justice, Washington, D.C., for Defendant.
With him on briefs were Brian M. Boynton, Principal Deputy Assistant Attorney
General, Patricia M. McCarthy, Director, and Elizabeth M. Hosford, Assistant
Director, United States Department of Justice, Washington, D.C., and Karen D.
Glasgow, Field Solicitor, San Francisco Field Office, Office of the Solicitor,
Department of the Interior, San Francisco, CA.
OPINION AND ORDER
Plaintiff Aries Construction Corp. alleges that it contracted with the United
States National Park Service (“NPS”) for installation of a water pipeline system. See
Compl. (ECF 1). Plaintiff claims that NPS both breached the contract and breached
the duty of good faith and fair dealing when administering the contract. The
government has moved to dismiss the latter cause of action for lack of jurisdiction
and failure to state a claim. See Partial Mot. to Dismiss (“Mot.”) at 1 (ECF 9). The
parties have fully briefed the issue and I have heard oral argument.1 For the reasons
discussed below, the motion to dismiss is DENIED.2
1 Resp. to Mot. to Dismiss (“Resp.”) (ECF 18); Reply to Resp. to Mot. to Dismiss (“Reply”) (ECF 20);
Certified Transcript (“Tr.”) (ECF 24).
2 Plaintiff requested a stay if Defendant’s motion were granted. Because Defendant’s motion is denied,
Plaintiff’s request for a stay is moot.
BACKGROUND
The Complaint alleges the following facts.3 Plaintiff and NPS entered a
contract, governed by the Contract Disputes Act (41 U.S.C. § 7101–04) (“CDA”), for
water pipeline construction. See Compl. ¶¶ 2–4 (ECF 1). When Plaintiff began work,
it “encountered unexpected hard rock requiring additional equipment and labor to
remove it … resulting in delays.” Id. ¶¶ 8; 16–17. Plaintiff informed NPS officials,
including the contracting officer, of the unexpected conditions. Id. ¶¶ 9–11. NPS
instructed Plaintiff to proceed and Plaintiff incurred additional expenses. Id. ¶¶ 9,
12, 17–18. But when Plaintiff submitted CDA claims to the contracting officer for
money covering the additional work, the claims were denied. Id. ¶¶ 13–14, 15, 19; see
also Pl.’s Ex. E (ECF 1-5); Pl.’s Ex. G (ECF 1-7).
Plaintiff alleges that denial of the CDA claims breached the contract (Count I)
and the duty of good faith and fair dealing (Count II).4 Defendant has moved to
dismiss Count II, arguing that Plaintiff (1) failed to present a breach of the duty of
good faith and fair dealing to the contracting officer, and (2) has not alleged sufficient
facts to state a claim on which relief can be granted. See Mot. at 1; see also RCFC
12(b)(1), (6).
DISCUSSION
I. Legal Standards
The “plaintiff bears the burden of establishing subject-matter jurisdiction by a
preponderance of the evidence.” Inter-Tribal Council of Arizona, Inc. v. United States,
956 F.3d 1328, 1337 (Fed. Cir. 2020) (quoting M. Maropakis Carpentry, Inc. v. United
States, 609 F.3d 1323, 1327 (Fed. Cir. 2010)). When reviewing a motion to dismiss for
lack of subject-matter jurisdiction under RCFC 12(b)(1), this Court “accepts as true
all uncontroverted factual allegations in the complaint, and construes them in the
light most favorable to the plaintiff.” Estes Exp. Lines v. United States, 739 F.3d 689,
692 (Fed. Cir. 2014) (citing Cedars–Sinai Med. Ctr. v. Watkins, 11 F.3d 1573, 1583–
84 (Fed. Cir. 1993)). If a court determines that it does not have jurisdiction, it “is
bound to dismiss as soon as it is aware of the deficiency.” Dico, Inc. v. United States,
33 Fed. Cl. 1, 4 (1993), aff’d, 48 F.3d 1199 (Fed. Cir. 1995); see RCFC 12(h)(3).
3 Any facts — as distinct from legal conclusions — pleaded in a complaint must be “accepted as true.”
Ashcroft v. Iqbal, 556 U.S. 662, 678 (2009).
4 Plaintiff also alleges that NPS breached the contract by denying two other CDA claims intended to
correct allegedly defective contractual specifications. See Compl. at ¶¶ 20–34; see also Pl.’s Ex. I (ECF
1–9); Pl.’s Ex. K (ECF 1–11). Those CDA claims are not at issue in the present motion. See Compl. at
¶¶ 35–40.
-2-
To survive a motion to dismiss under RCFC 12(b)(6), a complaint in this Court
must contain well-pleaded factual allegations “sufficient ..., [when] accepted as true,
to ‘state a claim to relief that is plausible on its face.’” Ashcroft v. Iqbal, 556 U.S. 662,
678 (2009) (quoting Bell Atl. Corp. v. Twombly, 550 U.S. 544, 570 (2007)). “A claim
has facial plausibility when the plaintiff pleads factual content that allows the court
to draw the reasonable inference that the defendant is liable for the misconduct
alleged.” Id. A court considers whether to make that inference in light of “its judicial
experience and common sense.” Id. at 679. The inference must be stronger than “a
sheer possibility that a defendant has acted unlawfully.” Id. at 678. But the inference
does not need to be probable. Rather, “a well-pleaded complaint may proceed even if
it strikes a savvy judge that actual proof of those facts is improbable.” Twombly, 550
U.S. at 556. The court “must draw all reasonable inferences in favor of the claimant.”
Call Henry, Inc. v. United States, 855 F.3d 1348, 1354 (Fed. Cir. 2017) (citing
Bell/Heery v. United States, 739 F.3d 1324, 1330 (Fed. Cir. 2014)). And “Rule 12(b)(6)
does not countenance ... dismissals based on a judge’s disbelief of a complaint’s factual
allegations.” Neitzke v. Williams, 490 U.S. 319, 327 (1989) (quoted in Twombly, 550
U.S. at 556).
II. Merits
I conclude that this Court has jurisdiction because Plaintiff gave the
contracting officer sufficient notice of a good faith and fair dealing claim. I further
conclude that Plaintiff has stated a plausible claim for breach of the duty of good faith
and fair dealing.
A. Jurisdiction
Before suing in this Court on a claim governed by the CDA, a contractor must
present that same claim to the contracting officer and obtain the contracting officer’s
final decision. 41 U.S.C. §§ 7103(a), 7104(b). That presentment requirement is
jurisdictional; this Court cannot hear a claim under the CDA if it is unmet. Tolliver
Grp., Inc. v. United States, 20 F.4th 771, 775 (Fed. Cir. 2021); James M. Ellett Constr.
Co. v. United States, 93 F.3d 1537, 1541–42 (Fed. Cir. 1996); W.M. Schlosser Co. v.
United States, 705 F.2d 1336, 1338–39 (Fed. Cir. 1983). Defendant argues, in essence,
that Plaintiff’s claim for breach of the duty of good faith and fair dealing is too
different from Plaintiff’s CDA claim to the contracting officer for this Court to have
jurisdiction.
For a CDA claim to the contracting officer to be “the same” as a claim in this
Court, the claims must be based on the same basic theory, arise from same operative
facts, and seek the same relief. Scott Timber v. United States, 333 F.3d 1358, 1365
(Fed. Cir. 2003). By the same token, this Court “treat[s] requests as involving
-3-
separate claims if they ... assert grounds that are materially different from each other
factually or legally.” See K-Con Bldg. Sys., Inc. v. United States, 778 F.3d 1000, 1005
(Fed. Cir. 2015). Defendant does not appear to dispute that Plaintiff presented the
same operative facts to the contracting officer and sought the same relief. See Reply
at 2 n.2. The question, rather, is whether Plaintiff presented the same basic legal
theory to the contracting officer.
The Federal Circuit has made clear that CDA presentment does not require
claims in this Court to follow “the exact language or structure of the original
administrative CDA claim.” Scott Timber, 333 F.3d at 1365. When a claim in this
Court “arise[s] from the same operative facts [and] claim[s] essentially the same
relief” as the CDA claim to the contracting officer, this Court has jurisdiction even if
the contractor “assert[s] differing legal theories for that recovery,” so long as the
contractor put the contracting officer on notice of the basis of the claim. Id. If the
contracting officer was on notice of the factual and legal substance, the contractor
may assert a “slightly different legal theor[y]” when he sues. Id. at 1366; see also
Kellogg Brown & Root Servs., Inc. v. United States, 115 Fed. Cl. 46, 54 (2014) (“[T]his
court must examine the operative facts and relief sought in the two CDA claims, not
the legal labels placed on those claims, to determine whether those two CDA claims
are the same.”). For example, in Scott Timber this Court had jurisdiction where the
original CDA claim “contended that the [government] lacked authority under the
contracts” to take certain actions, and the complaint in this Court “elaborated on
those broad original CDA claims and identified specific contract provisions that the
government allegedly breached.” Tolliver Grp., 20 F.4th at 777 (discussing Scott
Timber).
That brings us to Plaintiff’s claim for breach of the duty of good faith and fair
dealing. To prevail, Plaintiff must show that “a specific promise” in the contract was
“undermined” by the government. Dobyns v. United States, 915 F.3d 733, 739 (Fed.
Cir. 2019). The promise must be grounded in the terms of the contract, id., because
“what that duty entails depends in part on what that contract promises (or
disclaims).” Precision Pine & Timber, Inc. v. United States, 596 F.3d 817, 830 (Fed.
Cir. 2010). Plaintiff must also show “subterfuge[]” or “evasion[],” such as “evasion of
the spirit of the bargain, lack of diligence and slacking off, willful rendering of
imperfect performance, abuse of a power to specify terms, [or] interference with or
failure to cooperate in the other party’s performance.” Dotcom Assocs. I, LLC v.
United States, 112 Fed. Cl. 594, 596 (2013) (quoting Restatement (Second) of
Contracts § 205). Against the government, such claims “typically involve some
variation on the old bait-and-switch” or “government action ... specifically designed
-4-
to reappropriate the benefits the other party expected to obtain from the
transaction[.]” Precision Pine, 596 F.3d at 829.
Thus, a claim for breach of good faith and fair dealing must include (1) a
specific promise that was undermined, plus some combination of (2) subterfuge,
evasion, or dishonesty, and (3) reappropriation of a reasonably expected benefit. If
Plaintiff presented such facts to the contracting officer with a claim for money, then
the contracting officer had sufficient notice of a good faith and fair dealing claim, even
if the current legal packaging is “slightly different.” Scott Timber, 333 F.3d at 1365.
Drawing all inferences in favor of Plaintiff, as I must at this stage, Estes Exp.
Lines, 739 F.3d at 692, I find that Plaintiff adequately presented the claim.5 Plaintiff’s
CDA claims to the contracting officer requested an equitable adjustment on the
ground that NPS officials had asked Plaintiff to perform additional work to overcome
unexpected obstacles at the job site. A contractor is entitled to an equitable
adjustment for a constructive change to the contract when it shows “(1) that it
performed work beyond the contract’s requirements, and (2) that the additional work
was ordered, expressly or impliedly, by the government.” BGT Holdings LLC v.
United States, 984 F.3d 1003, 1012 (Fed. Cir. 2020); Kiewit Infrastructure W. Co. v.
United States, 972 F.3d 1322, 1329 (Fed. Cir. 2020); see Aydin Corp. v. Widnall, 61
F.3d 1571, 1577 (Fed. Cir. 1995) (“Where it requires a constructive change in a
contract, the Government must fairly compensate the contractor for the costs of the
change [through an equitable adjustment].”). The contracting officer was therefore on
notice that if he denied an equitable adjustment to which Plaintiff was entitled,
Plaintiff could allege that the government had reappropriated the contract’s promised
benefits. That, in turn, meant the contracting officer was on notice of the facts and
general legal basis that could support a claim for breach of the duty of good faith and
fair dealing. Tolliver Grp., 20 F.4th at 777; see also Lee’s Ford Dock, Inc. v. Sec’y of
the Army, 865 F.3d 1361, 1370 (Fed. Cir. 2017) (CDA claims contractor presented to
the contracting officer must “support[] its later-asserted ... claim”); RMA Eng’g
S.A.R.L. v. United States, 140 Fed. Cl. 191, 221 (2018) (to give the contracting officer
notice of a good faith and fair dealing claim, contractor must have presented “the
operative facts of a claim for breach of the duty of good faith and fair dealing”).6
5 The contracting officer denied Plaintiff’s requests because he did not believe Plaintiff had followed
the contractual procedure for obtaining approval for more work. Pl.’s Ex. E; Pl.’s Ex. G. The
government has not moved to dismiss on that basis, though. I resolve the jurisdictional question of
presentment without reaching the merits question of whether the contract permits Plaintiff’s equitable
adjustment.
6 A recent decision of this Court concluded that a CDA claim for an equitable adjustment was not
sufficient to establish jurisdiction over a claim for breach of the duty of good faith and fair dealing.
David Boland, Inc. v. United States, No. 22-131C, 2022 WL 9655097, at *5 (Fed. Cl. Oct. 17, 2022).
-5-
The government objects that the contracting officer was never given the
opportunity to consider whether his denial of the CDA claim breached the duty of
good faith and fair dealing. Obviously Plaintiff could not have presented a claim about
future events. The government proposes that Plaintiff should have submitted yet
another CDA claim to the contracting officer, identical to the original but for an
additional allegation that the contracting officer’s decision breached the duty of good
faith and fair dealing. Tr. at 28.
That makes little sense. The point of CDA presentment is to give the
contracting officer sufficient notice to “receive and pass judgment on the contractor’s
entire claim.” Scott Timber, 333 F.3d at 1366; see also Cont. Cleaning Maint., Inc. v.
United States, 811 F.2d 586, 592 (Fed. Cir. 1987). Expecting the contracting officer to
be aware of the legal consequences of his own decisions is perfectly consistent with
that purpose.
More fundamentally, the government’s argument proves too much. A CDA
claim for an equitable adjustment based on a constructive change is not a claim for
breach of contract: It is a claim pursuant to contractual rights. See Reflectone, Inc. v.
Dalton, 60 F.3d 1572, 1577 (Fed. Cir. 1995) (requests for equitable adjustment are “a
written demand for payment as a matter of right”); Crown Coat Front Co. v. United
States, 386 U.S. 503, 511 (1967) (constructive changes “are not breaches of contract
[but instead] give rise to claims for equitable adjustments”). A breach of contract does
not occur until the claim for an equitable adjustment is wrongly denied. See Crown
Coat Front, 386 U.S. at 511; BGT Holdings, 984 F.3d at 1010 (failure to provide an
equitable adjustment can constitute breach of contract); W. Contracting Corp. v.
United States, 144 Ct. Cl. 318, 333 (1958) (“The refusal of the contracting officer, upon
demand by plaintiff, to make an equitable adjustment constituted a breach of
contract.”). A CDA claim for an equitable adjustment and a suit for breach of contract
are thus no less distinct than equitable adjustment and a suit for breach of the duty
of good faith and fair dealing. That means that if the government were right,
contractors denied equitable adjustments could not sue for breach of contract in this
Court until they presented their contracting officers with a second CDA claim alleging
that denial of an equitable adjustment breached the contract.
The cases are distinguishable. The plaintiff in David Boland “appeared to concede at oral argument”
that its request to the contracting officer “did not include the operative facts underlying a breach of
the duty of good faith and fair dealing.” Id. In this case, Plaintiff informed the contracting officer that
NPS officials had told it to begin the additional work. See Ex. F. The David Boland Court did reason
that a single claim to the contracting officer is insufficient to establish jurisdiction over claims arising
from the contracting officer’s alleged bad faith. David Boland, 2022 WL 9655097 at *5. But I
respectfully part ways from my learned colleague on that question for the reasons set out in this Order.
-6-
That has never been the law. Lawsuits for breach of contract after denial of a
single CDA claim for an equitable adjustment are common. See, e.g., BGT Holdings,
984 F.3d at 1010; Sarro & Assocs., Inc. v. United States, 152 Fed. Cl. 44, 53 (2021)
(suit for breach of contract based on denial of equitable adjustment); Senate Builders
& Constr. Managers, Inc. v. United States, 131 Fed. Cl. 719 (2017) (same). When a
contractor presents a contracting officer with a CDA claim for an equitable
adjustment based on particular facts, this Court has jurisdiction over claims that the
contracting officer’s denial breached the contract. And if that rule permits lawsuits
for breach of contract after denial of an equitable adjustment, it is hard to see why it
would not also permit lawsuits for breach of the duty of good faith and fair dealing.7
The government provides no basis on which to distinguish the causes of action.
The government relies on the Federal Circuit’s decisions in Reliance Insurance
Co. v. United States, 931 F.2d 863 (Fed. Cir. 1991), and Renda Marine, Inc. v. United
States, 71 Fed. Cl. 378 (2006). Mot. at 7. In both cases, the Federal Circuit held that
CDA claims for equitable adjustments did not adequately present claims for breach
of the duty of good faith and fair dealing. Reliance Insurance, 931 F.2d at 866; Renda
Marine, 71 Fed. Cl. at 392. The government argues that these cases show that
equitable adjustment and good faith and fair dealing are not merely “slightly different
legal theories” as Scott Timber allows, but are in fact completely distinct theories that
must be presented individually. See Scott Timber, 333 F.3d at 1366.
Those cases are distinguishable, however, because the facts giving rise to the
contractors’ good faith and fair dealing claims were separate from the CDA
complaints to the contracting officers. See Reliance, 931 F.2d at 865; Renda Marine,
71 Fed. Cl. at 385. In Reliance, the government issued more than 200 change orders
that resulted in delays, which the contractor alleged constituted bad faith and a
breach of the contract. Reliance, 931 F.2d at 865. In Renda Marine, the government’s
refusal to provide written instructions gave rise to the allegation of bad faith. Renda
Marine, 71 Fed. Cl. at 385. Because the facts underlying the alleged breaches
preceded the contractor’s claim to the contracting officer, the contractors in both cases
had everything they needed to present the contracting officer with their claims for
breach of the duty of good faith and fair dealing in a CDA claim. Reliance and Renda
Marine thus stand for the proposition that a contractor should include breach of the
7 For similar reasons, the government is wrong to argue that Plaintiff’s CDA claim for an equitable
adjustment and its complaint for breach of the duty of good faith and fair dealing are different claims
because they have different elements. Mot. to Dismiss at 6–7. The government is comparing apples
and oranges: Bringing an alleged contractual entitlement to the contracting officer’s attention is not
the same as claiming a breach. What matters is that once the contracting officer is on notice of the
contractor’s alleged entitlement, the contractor can characterize the denial in different legal ways.
-7-
duty of good faith and fair dealing in a CDA claim to the contracting officer when the
available facts support it.
But the rule of Reliance and Renda Marine is not the one applicable here,
where the contracting officer’s denial of the CDA claim itself supplied the last element
of claims for breach of contract and for breach of the duty of good faith and fair
dealing. When a CDA claim contains everything needed to put the contracting officer
on notice except for the contracting officer’s own denial, the contractor can pursue
different theories in this Court for why the denial was wrongful. The government’s
reading of those cases would chain contractors to the legal theories in their CDA
claims, contrary to the direction of Scott Timber. See 333 F.3d at 1365.
I conclude that Plaintiff gave the contracting officer notice of facts sufficient to
put him on notice that denial of the CDA claim could breach the duty of good faith
and fair dealing. This Court therefore has jurisdiction.
B. Failure to State a Claim
As explained above, whether Plaintiff has stated a claim upon which relief can
be granted depends on whether the well-pleaded facts in the complaint, taken as true,
permit a plausible inference that the government is liable. Iqbal, 556 U.S. at 678. To
plead a claim for breach of the duty of good faith and fair dealing, Plaintiff must allege
(1) a specific promise that was undermined, Dobyns, 915 F.3d at 739, plus some
combination of (2) subterfuge, evasion, or dishonesty, Dotcom, 112 Fed. Cl. at 596,
and (3) reappropriation of a reasonably expected benefit, Precision Pine, 596 F.3d at
829. I conclude that Plaintiff has adequately alleged those elements.
The government argues that Plaintiff has failed to point to a specific promise
that the government undermined. Mot. at 2. But if NPS directed Plaintiff to perform
additional work, then denied payment when Plaintiff submitted a CDA claim — as
Plaintiff alleges, Compl. ¶¶ 9, 17 — the government may have evaded its obligation
to pay for constructive changes in the contract. See Dotcom, 112 Fed. Cl. at 596. For
much the same reasons that the facts Plaintiff presented to the contracting officer
were sufficient notice, those facts — plus the contracting officer’s denial — state a
claim for breach of the duty of good faith and fair dealing.
The government also argues that the Plaintiff’s good faith and fair dealing
claim should be dismissed as redundant because Plaintiff’s complaint also includes a
count for breach of contract based on the same facts. See Reply 3 n.3. Redundancy in
a complaint’s causes of action, of course, is not ordinarily a basis for dismissal. This
Court’s Rules expressly permit “alternative statements” of claims, or even
inconsistent theories for relief. See RCFC 8(d)(2), (3). Defendant’s only authority for
dismissal of claims for breach of the duty of good faith and fair dealing that overlap
-8-
with claims for breach of contract — CFS International Capital Corp. v. United States
— applied New York law, which does not govern in this case. See 118 Fed. Cl. 694,
701 (2014).8 I therefore see no basis to depart from the usual rules of pleading.
CONCLUSION
For the foregoing reasons, Defendant’s Motion to Dismiss is DENIED.
IT IS SO ORDERED.
s/ Stephen S. Schwartz
STEPHEN S. SCHWARTZ
Judge
8 One case appears to apply CFS International more broadly, but without acknowledging the earlier
case’s basis in New York law. Hamilton Square, LLC v. United States, 160 Fed. Cl. 617, 629 (2022). A
Federal Circuit decision dismissed a good faith and fair dealing claim as redundant because “the
contract itself provide[d] other avenues of relief for [plaintiff] that preempt the need to invoke the
doctrine of good faith and fair dealing.” BGT Holdings, 984 F.3d at 1016. The government points to no
similar provision applicable here.
-9-