DocketNumber： No. 96-222 C
Citation Numbers： 63 Fed. Cl. 402
Judges： Allegra
Filed Date： 12/15/2004
Status： Precedential
Modified Date： 7/20/2022
OPINION
At least since the shock of exploding fireworks caused the scales to fall on poor Helen Palsgraf, courts have applied temporal and spatial limitations on the availability of tort damages, invoking familiar doctrines such as proximate cause and foreseeability. See Palsgraf v. Long Island R. Co., 248 N.Y. 339, 162 N.E. 99 (1928). Similar principia have evolved in contract cases and, not surprisingly, have wended them way into the regulatory and decisional fabric of Federal procurement law, particularly in assessing responsibility for delays in the completion of a contract, and especially in considering the validity of liquidated damages assessed for delay.
The latter topics are the subject of this action, which springs from a contract between plaintiff, R.P. Wallace, Inc. (“R.P.Wal
I. FINDINGS OF FACT
Based on the record, including the parties’ stipulations, the court finds as follows:
On September 28, 1993, the Navy and plaintiff entered into contract number N62467-91-C-7226 (“the contract”) for various repairs to be made to Building 58 at the Naval Support Activity in New Orleans, Louisiana. Under the contract, plaintiff was responsible, inter alia, for re-roofing the building, removing an elevator penthouse, painting the interior and exterior, and replacing all the existing exterior windows with thermal break insulating glass aluminum frame units. Morton-Verges, Architects (Morton-Verges), the Navy’s architect and engineer for this project, prepared the contract’s plans and specifications, and was responsible for reviewing and commenting on all submittals made by the contractor.
Because Building 58 is a historic structure, the contract specifications called for replacement windows that conformed to the building’s historic appearance and, therefore, differed from standard office-building windows in several respects. The contract drawings provided various details regarding these windows, including specifics on their panning and muntins.
The contract required R.P. Wallace to commence performance within ten days of the award, and to finish no later than 165 days after the award (15 calendar days for the mailing of the award and the contractor’s submission of required bonds, and 150 calendar days to prosecute the work). Based upon the September 28, 1993, award date, the original completion date thus was March 12, 1994. Section 0101, ¶ 1.9 of the contract provided that “[i]f the Contractor fails to complete the work within the time specified in the contract, or any approved extension, liquidated damages shall be assessed the Contractor in the amount of $200.00 for each calendar day of delay.”
The contractor has designated both suppliers and subcontractors for window and door work. Submittals are currently being prepared for the window and door work. Lead time on windows is approximately six weeks and installation will take approximately four weeks.
Notwithstanding, as of January 3,1994 — over ninety days into the expected 165-day contract period and sixty days after the preconstruction conference — plaintiff had neither provided any of the required submittals nor performed any work at the Building 58 site. On that date, plaintiff notified the Navy that it would provide the required window submittals on January 7,1994. On January 5,1994, the Navy sent plaintiff a letter noting that “55 percent of the contract time has elapsed with no on site work” and that “it appears that you will be unable to complete [the] contract work by the contract completion date.” The letter also noted that the window submittal, as well as “many material submittals[,] remain outstanding” and warned that liquidated damages would be assessed for inexcusable delay. Despite plaintiffs prior assurances, January 7, 1994, passed without plaintiff providing the Navy with the window submittals.
On February 7, 1994, the Navy issued a cure notice to R.P. Wallace pointing out that “with only 34 days remaining before the contract completion date ... you have made only minimal progress toward completion” and listing a dozen submittals that remained outstanding.
On February 28, 1994, two weeks prior to the scheduled completion date, plaintiff finally provided its window submittal. On March 11, 1994, plaintiff sent the Navy a letter indicating that all outstanding submittals had been provided and citing, but not identifying, “several factors which have contributed to the delay in completion of the contract.” While this letter indicated that “[w]e will be addressing these factors under separate cover shortly,” there is nothing in the record indicating that such a document was ever prepared or sent to the Navy. On March 14, 1994, Morton Verges wrote the Navy indicating that while the window submittal met various of the contract’s specifications, it did not comply with the “window and trim design.” Regarding the latter requirements, the letter explained that “[p]rior to completing the construction documents we verified with a local glass company that reasonable duplication was possible. Therefore we should insist that trim panning and muntins match existing as detailed.” On March 15, 1994, the Navy wrote plaintiff, indicating that performance was now overdue and requesting that plaintiff “take all measures to mitigate potential damages and submit your ap
On March 24, 1994, Alenco, the contractor that had created the window submittal for R.P. Wallace, sent plaintiff a letter discussing the grounds for the Navy’s rejection. It advised plaintiff that it could revise the submittal to include the convex panning required by the contract, noting that it owned “two extrusion presses, which allows us to design and extrude our own profiles in house.” Alenco, however, indicated that it was impossible to build an aesthetically acceptable window using true muntins that complied with the contract’s wind resistance requirements, emphasizing “we can offer the Navy either the historic type false muntin as we have already submitted, or we can offer a true muntin. However, we can no longer offer a combination of both, nor can anyone else.” Regarding the muntins, this letter further adumbrated:
What it boils down to ... is that the Navy can have either the structural integrity offered by a bulky true muntin, or they may have the atheistic [sic] value of a false muntin, but not both! The Navy will not find another manufacturer capable of performing this feat, or able to present a test report to substantiate it.
This is the first clear evidence in the record that plaintiff was aware of the defects in the contract’s window specifications. On March 30, 1994, Alenco again wrote plaintiff, reemphasizing that true muntins of a size necessary to meet the wind resistance requirements would not be “the most pleasing to the eye.”
On March 31, 1994, plaintiff delivered another window submittal to the Navy, albeit not a full-sized sample, together with a letter from Alenco explaining why it was impossible to build the windows as specified. At this time, plaintiff requested a variance from the contract specifications regarding muntins. On April 11, 1994, the Navy notified R.P. Wallace that its request for a variance from the contract specifications for the muntins was being “referred to both the engineer of record and Public Works engineering for guidance” and reminded plaintiff that it had failed to submit a full-sized window sample with its shop drawings. On April 19, 1994, a full-sized window sample was delivered to the worksite, but could not be approved because its glass was broken.
On April 21, 1994, the Navy advised R.P. Wallace that it had approved the variance for the muntins, contingent upon the receipt and approval of a sample window. Describing the rationale for this decision, the parties have stipulated, as follows:
The Navy’s specifications for the windows were defective in that they included two incompatible requirements: (1) the windows had to meet current wind load requirements to remain intact through a hurricane, and, at the same time, (2) were required to be duplicates of the original windows they were replacing, i.e., to have full muntins between each pane of glass in a multi-pane window. The penetration of the window by true muntins would have weakened the glass to such an extent that it could not meet the wind load requirement. A solid pane for the entire window could meet the wind load requirement; however, the muntins required to maintain the wind load requirement with individual panes would have been much larger than the original muntins, rendering them unacceptable for aesthetic reasons.
On April 26, 1994, plaintiff wrote the Navy highlighting the defective specification and seeking relief from anticipated liquidated damages, asserting that “the delay encountered is as a result of defective specifications and further is clearly from unforeseeable causes beyond the control and without fault or negligence of the contractor.” In a response dated April 29, 1994, the Navy wrote that “the government is in agreement that the design is defective, and that an equitable
On May 6,1994, R.P. Wallace delivered the approved window submittal to Alenco for production. At this point, Alenco began to take steps to fabricate the windows. On May 23, 1994, plaintiff received a response from the Navy to one of its invoices in which the latter had deducted anticipated liquidated damages. That same day, plaintiff wrote the Navy asserting that the “delay is clearly and indisputably the result of a defect in contract specifications” and that it should “not be subjected to liquidated damages as a result of same.” Notwithstanding, on May 26, 1994, the Navy sent plaintiff a letter in which it expressed its intention to assess liquidated damages based upon a revised contract completion date of May 1, 1994. On June 6, 1994, Alenco received the custom extrusion dies needed to create the convex pauning, conducted tests and promptly sent samples to R.P. Wallace. For reasons unexplained, R.P. Wallace did not approve the custom panning profiles and release the windows for manufacturing until July 6,1994.
On August 19, 1994, plaintiff delivered the Navy a letter dated August 17,1994, in which it contested the deduction of liquidated damages from a prior invoice. In this letter, plaintiff asserted:
As has been well documented in writing, by both the contractor and the Navy, the delay we have encountered is a direct result of a defect in contract specifications. As a consequence of our job progress being delayed, as a result of the defective specifications, it is my understanding that we will not be subject to liquidated damages.
On August 22, 1994, the Navy notified R.P. Wallace by letter of its intent to extend the contract by 36 days in connection with the window submittals. This 36-day extension represented “the period of time between return of [the] initial submittal (16 March 1994) and approval of [R.P. Wallace’s] resubmittal (26 April 1994).” The letter invited R.P. Wallace to present information if it believed it was owed additional time for the window submittal. On August 22, 1994, plaintiff responded to the Navy's letter, again asserting that the defective specifications relieved it of “any liability for liquidated damages.”
On September 20, 1994, Alenco delivered the first of several batches of windows to the work site, at which point, following the Navy’s approval, R.P. Wallace began to install them. On October 21, 1994, the Navy executed modification no. P00004, unilaterally modifying the contract to grant plaintiff a time extension of 36 calendar days in compensation “for any and all window delays for the period between the return of the initial window submittal (16 March 1994) and approval of the resubmittal (26 April 1994).”
Following the receipt of a last batch of windows on January 9,1995, plaintiff finished installing the windows on January 11, 1995, at which time the Navy took beneficial occupancy of Building 58.
On April 24, 1996, plaintiff filed its complaint in this court, seeking $130,402 in delay damages, $50,000 in remitted liquidated damages, interest, costs, and attorney’s fees. On January 12, 1998, R.P. Wallace amended its complaint to reduce its claim for delay damages to $65,753.65. On August 15, 2001, plaintiff filed a motion for partial summary judgment. This case was transferred to the undersigned on July 24, 2002, and on October 16, 2002, the court granted, in part, plaintiffs motion for partial summary judgment. Specifically, the court held that defendant would be bound by its concession that both the contract’s painting specifications and aluminum window specifications were defective, but that genuine issues of fact precluded granting summary judgment on the issue whether the defective specifications proximately caused delay in completion of the contract.
Trial in this case was held from May 5 to 7, 2003, in New Orleans. At trial, plaintiff presented the testimony of its principal, Ronald Wallace, and one of its employees, Roland Fortenberry, describing the problems that were encountered during its performance of the contract. Defendant countered with testimony from several Navy personnel involved in the administration of the contract, all of whom emphasized deficiencies in plaintiffs performance. Both parties relied heavily on experts, who used critical path method analysis
II. DISCUSSION
Having failed to complete the renovations of Building 58 by the appointed date, plaintiff was assessed $50,000 in liquidated damages under section 01010, 111.9 of the contract. That section provided that “[i]f the Contractor fails to complete the work within the time specified in the contract, or any extension, liquidated damages shall be assessed the Contractor in the amount of $200.00 for each calendar day of delay.” Plaintiff seeks remission of these damages, as well as recovery of delay damages allegedly caused by the Navy.
A. Background Legal Principles
As a threshold matter, the court must focus on whether plaintiff’s delay in completing the contract was “excusable” within the meaning of FAR § 52.249 — 10(b), a provision incorporated into the contract. That section states that a contractor shall not be charged with damages, if “[t]he delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” See Sauer, Inc. v. Danzig, 224 F.3d 1340, 1345 (Fed.Cir.2000). Relevant examples of such causes include: “acts of the Government in either its sovereign or contractual capacity” and “delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” 48 C.F.R. § 52.249-10(b)(1). These salvific provisions, however, are triggered only if “[t]he Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay.” Id; see generally, Decker & Co. v. West, 76 F.3d 1573, 1581 (Fed.Cir. 1996) (describing the operation of these provisions). To the extent plaintiff can show the existence of excusable delay beyond that previously allowed by the Navy, it is entitled to the remission of liquidated damages, and potentially the recovery of delay damages.
The excusable delay provisions of FAR § 52.249-10 are silent as to how a contractor should demonstrate the existence and extent of such delay. Nonetheless, the decisional law is well-settled that-
When a contractor is seeking extensions of contract time, for changes and excusable delay, which will reheve it from the consequences of having failed to complete the work within the time allowed for performance, it has the burden of establishing by a preponderance of the evidence not only the existence of an excusable cause of delay but also the extent to which completion of the contract work as a whole was delayed thereby.
Morganti Nat’l, Inc. v. United States, 49 Fed.Cl. 110, 132-33 (2001) (quoting Santa Fe, Inc., VABCA No.1943, 84-2 BCA ¶ 17,341, at 86,410, 1984 WL 13360 (1984)), aff'd, 36 Fed. Appx. 452 (Fed.Cir.2002).
Thornier issues are posed by concurrent or sequential delays — the first occurring
A more heated debate surrounds the treatment of sequential delays, the law on which has aptly been described as “unsettled.” PCL Constr. Servs., 53 Fed.Cl. at 486. One constellation of eases, often identified with Acme Process Equipment, Co. v. United States, 171 Ct.Cl. 324, 347 F.2d 509 (1965), rev’d on other grounds, 385 U.S. 138, 87 S.Ct. 350, 17 L.Ed.2d 249 (1966), follows the so-called “rule against apportionment,” and holds that “ ‘where delays are caused by both parties to the contract the court will not attempt to apportion them, but will simply hold that the provisions of the contract with reference to liquidated damages will be annulled.’” Id. at 535 (quoting Schmoll v. United States, 91 Ct.Cl. 1, 28, 1940 WL 4133 (1940)). As its mainstay for this rule, Acme drew on United States v. United Engineering & Constructing Co., 234 U.S. 236, 242, 49 Ct.Cl. 689, 34 S.Ct. 843, 58 L.Ed. 1294 (1914). In the latter case, work on a pumping station was delayed beyond the completion time initially set by the contract solely because of the government’s fault. To complete the work, the parties executed two contract amendments, neither of which fixed the time for completing the work nor mentioned liquidated damages. Nonetheless, the government assessed liquidated damages against the contractor, contending that after the government’s delay, it had further delayed completion of the contract. The Supreme Court concluded that the contractor could not be held liable for liquidated damages under the original contract, reasoning that “when the contractor has agreed to do a piece of work within a given time, and the parties have stipulated fixed sum as liquidated damages ... in order to enforce such payment the other party must not prevent the performance of the contract within the stipulated time; and that where such is the case, and thereafter the work is completed, though delayed by the fault of the contractor, the rule of the original contract cannot be insisted upon, and liquidated damages measured thereby are waived.” Id.
Decisions broadly applying the “rule against apportionment” frequently quote this passage from United Engineering,
The Supreme Court affirmed the Court of Claims. It held that the liquidated damages clause was enforceable, despite the delay caused by the government, reasoning-
The fact that the government’s action caused some of the delay presents no legal ground for denying it compensation for loss suffered through the fault of the contractor. Since the contractor agreed to pay at a specific rate for each day’s delay not caused by the government, it was clearly the intention that it should pay for some days’ delay at that rate, even if it were relieved from paying for other delays, because of the government’s action.
Id. at 488, 43 S.Ct. 420. The Court observed that the contractor’s attempt to nullify the liquidated damages clause placed undue weight on the chronology of the delays, noting that “[i]f it had appeared that the first 61 days’ delay had been due wholly to the contractor’s fault, and the government had caused the last 60 days’ delay, there could hardly be a contention that the provision for liquidated damages should not apply.” Id. at 488-89, 43 S.Ct. 420. It then distinguished United Engineering, holding that “[t]he question there was one of construction” of the supplemental agreements, based upon which construction, the Court there had concluded that “the provision for liquidated damages [was] not applicable.” Id. at 489, 43 S.Ct. 420. “Here,” the Court indicated by way of contradistinction, “the question is not properly one of construction.” Id.
Robinson thus teaches that the mere existence of sequential delay does not require a court to annul a liquidated damages provision and that United Engineering only requires annulment where, due to government delay, the contract documents in question no longer provide a valid reference date from which to calculate liquidated damages.
In yet another curious twist, the Federal Circuit, in Sauer, recently applied the apportionment rule to a case involving sequential delay, but without citing Robinson. The court upheld a decision of the Armed Services Board of Contract Appeals that had apportioned delay in reviewing whether liquidated damages assessed against the contractor should be remitted. The Board had reached this result despite specifically finding the government responsible for certain days of delay, yet the Federal Circuit refused to annul the liquidated damages provision at issue. Instead, like the Board, it applied the apportionment rule, affirming the Board’s decision to award the government liquidated damages for certain days of delay caused by the contractor, while attributing other days of delay to the government. 224 F.3d at 1347. This result, the court believed, flowed from the basic rule that “a party asserting that liquidated damages were improperly assessed bears the burden of showing the extent of the excusable delay to which it is entitled.” Id. Finally, upholding the distinction between sequential and concurrent delay, the Federal Circuit distinguished several cases refusing to allow liquidated damages in the case of concurrent delay as being “inapposite” and “inapplicable.” Id.
In PCL Services, 53 Fed.Cl. at 487, this court criticized the panel in Sauer for failing to follow prior precedent, notably, United Engineering. The exegesis above, however, reveals that criticism to be unwarranted and misdirected: Sauer was correctly decided, consistent not only with the Supreme Court’s opinion in Robinson, but that of the Court of Claims, as well. The same
It remains to apply these principles to the facts found here, focusing initially on the remission of liquidated damages and, ultimately, to the extent necessary, on the claimed delay damages.
B. Is Plaintiff Entitled to a Remission of Liquidated Damages?
Although not listed in FAR § 52.249-10, defective specifications plainly can give rise to excusable delay. See United States v. Spearin, 248 U.S. 132, 135-36, 54 Ct.Cl. 187, 39 S.Ct. 59, 63 L.Ed. 166 (1918) (discussing the rule at common law); Franklin Pavkov Constr. Co. v. Roche, 279 F.3d 989, 994-95 (Fed.Cir.2002); J.D. Hedin Constr. Co. v. United States, 171 Ct.Cl. 70, 347 F.2d 235, 241 (1965), overruled on other grounds by Wilner v. United States, 24 F.3d 1397 (Fed.Cir.1994) (en banc). R.P. Wallace contends that the Navy’s defective window specifications delayed and disrupted its performance, entitling it to remission of all the liquidated damages asserted against it. While defendant does not contest that the defective specifications were harmful, it vigorously asserts that, on the record before the court, plaintiff has not shown that it is entitled to more than the 36 days of excusable delay already granted in modification P00005 of the contract. Tracking the approach employed by the experts who testified in this matter, in analyzing these assertions, the court will examine three distinct periods in the contract’s performance — the first leading up to the approval of the window submittal, the second while the approved windows were being fabricated, and the last primarily involving the installation of the windows.
The first period in question — the submittal phase — began with the award of the contract and ended with the Navy’s approval of the second window submittal on April 21, 1994, a period of approximately 210 days. For this period, plaintiff provided evidence that it was delayed in finding a window manufacturer because the contract originally called for a window that was essentially unavailable and could not be manufactured — one in which the historical type of true muntins specified could not reasonably accommodate the wind resistance requirement. Plaintiffs owner, Mr. Wallace, testified that, over a period of several weeks, he and his staff conducted an extensive search for the windows specified in the contract, contacting a number of window
While plaintiff, particularly through its expert, asserts that the impact of the defective specifications during this period was somewhat greater, there is considerable evidence to the contrary. For one thing, plaintiff has admitted that, around the same time it was searching for a window supplier, contract performance was delayed for thirty days due to the death of Mr. Wallace’s grandmother, an event for which plaintiff applied for, but did not receive, a contract extension. In addition, according to minutes of a meeting-held on December 9, 1993, plaintiff that day represented that it had designated suppliers and subcontractors for the windows, that submittals for the windows were being prepared and that time for the preparation and installation of the windows was approximately six and four weeks, respectively. This suggest that by December 9,' 1993, plaintiff had already made contact with Alenco, even though the window submittal was not provided until months later.
The second period in question — the window fabrication and delivery phase — began with the approval of the window submittal and ended with the delivery of the majority of the windows approximately 110 days later, on September 20, 1994. Plaintiff does not seriously argue that the defective specifications directly delayed the fabrication of the windows — indeed, the record indicates that the lion’s share of the manufacturing delay was attributable to fabricating the convex aluminum panning on the windows, a feature of the original specifications that was not defective. Rather, R.P. Wallace contends that once its efforts to meet the original window specifications led it to Alenco and the specifications then were determined to be defective, it was inalterably committed to Alenco and “stuck” with whatever delivery schedule the latter could provide.
As such, for the fabrication period, plaintiff plainly has neither shown that the delay in completing the work was “beyond [its] control,” nor that the “delays” experienced by Alenco in delivering the windows were “from unforeseeable causes beyond the control and •without the fault or negligence of both the Contractor and the subcontractors or suppliers.” 48 C.F.R. § 52.249-10(b)(l)(xi); see also Cibinic & Nash, at 547 (“If the contractor can prevent an event from occurring, it is not beyond its control.”). Rather, donning rose-colored glasses, plaintiff seems to operate now, as it did then, on the assumption that once the original design of the windows was found to be defective, both it and the Navy were “stuck” with whatever schedule Alenco could provide. That sticky assumption is counterfactual, particularly given the apportionment rule, discussed above, under which the government’s initial delay did not absolve plaintiff from having to obtain the windows in a timely manner, so as to minimize further delay in the completion of the contract. Indeed, in analogous circumstances, various decisions have held contractors liable for delays occasioned by their failure to replace a subcontractor or supplier
Because it builds upon the supposed foundational delays encountered in the fabrication phase, plaintiffs ease is weakest for the final period involved here — the installation phase — which began with the arrival of the windows and ended approximately 16 weeks later, on January 11,1995, when the windows were completely installed. While plaintiff initially estimated that it could install all 74 replacement windows in 28 days, it actually took 113 days, or 85 days longer. Again, plaintiff does not assert that the defective specifications directly caused this delay. Rather, it contends that: (i) it had originally anticipated installing the windows while it reroofed the building; (ii) by the time the windows were received, that task had been completed; and (iii) as a result, there were fewer individuals on site to assist with the installation of the windows. But, this assertion makes no sense for several reasons.
First, the record reveals no critical path relationship between the roofing and window installation tasks, as plaintiff used different subcontractors for each of these purposes.
Finally, a point about notice. As to all the claims in question, defendant argues that plaintiff failed to comply with that portion of FAR § 52.249-10 which requires the contractor to notify the contracting officer in writing within 10 days from the beginning of any excusable delay, stating the cause of that delay. Research reveals no ease that has really interpreted this provision. In general, however, the courts have held that such notice provisions should “not be applied too technically and illiberally where the Government is quite aware of the operative facts.” Hoel-Steffen Constr. Co. v. United States, 197 Ct.Cl. 561, 456 F.2d 760, 768 (1972); see also Copco Steel & Eng’g Co. v. United States, 169 Ct.Cl. 601, 341 F.2d 590, 598 (1965); Miller Elevator Co., Inc. v. United States, 30 Fed.Cl. 662, 699 (1994). Consistent with this view, the court believes that for this provision to be triggered, the contractor must know the cause of the delay sufficiently to be able to assert that it is “unforeseeable,” “beyond [its] control,” and “without [its] fault or negligence” within the meaning of the regulation. To require notice sooner would be to put a contractor in the untenable position of seeking an extension before it could demonstrate or document its entitlement thereto. Such an interpretation of the regulations makes no sense.
Under the court’s interpretation of the notice clause, plaintiff appears to have provided timely notice to the contracting officer for the delay associated with the submittal phase. It did not ascertain the reasons for the delay it had been experiencing in obtaining a window conforming to the specifications until approximately March 24, 1994, when Alenco explained the problem. Plaintiff then apprised the Navy of all the facts relating to this delay no later than seven days later, on March 31, 1994. To be sure, plaintiff did not formally request relief from the liquidated damages until April 26, 1994, but, in the court’s view, by that time the Navy was fully aware of the operative facts regarding the specification problem. Accordingly, in the court’s view, the notice requirement of FAR § 52.249-10 was met in the case of the 21 additional days delay the court has found to be excusable.
The situation, however, is far different as to plaintiffs claims with respect to the fabrication and installation periods. According to plaintiff, it knew that it would be unable to install the windows on a timely basis as early as April 21, 1994, when it authorized Aenco to proceed with the fabrication of the aluminum panning and the fabrication of the windows. At this time, plaintiff knew that the windows would be fabricated in approximately 22 weeks, rather than the originally-projected six to eight weeks. Yet, it did not notify the Navy of this until August 19,1994, when a letter dated August 17, 1994, was provided to Lt. Turner — even though on May 26,1994, Lt. Turner had indicated the Navy’s intention to assess liquidated damages based on the assumption that the fabrication and installation of the windows would take eight weeks and 31 days respectively. Moreover, the August 17,1994, letter did not reveal that fabrication delays were continuing and could cause additional delays in the installation of the windows. Unlike the situation with the defective specifications, then, plaintiffs failure to alert the Navy to the problems being experienced in fabricating and installing windows prejudiced the Navy by preventing it from reviewing the situation and taking appropriate steps to minimize the projected delays. As such, plaintiffs failure to provide proper notice as to the delays being encountered in fabricating and installing the windows provides a second, independent basis upon which to deny any further excusable delay for these phases of the project. See Decker & Co., 76 F.3d at 1581 (contractor not entitled to extension where timely notice of delays being experienced by subcontractors not provided).
The court need not tarry in respect of the remaining issue here — whether plaintiff is entitled to delay damages for the 21 days that the court has concluded constitute a further period of excusable delay. In fact, such damages are not awardable for at least two reasons. First, there is clear indication that during the three-week period in which plaintiff had difficulty in identifying a window supplier, there was concurrent delay. Among other things, during the fall of 1993, when plaintiff encountered the delay in question, it failed to meet a number of contract deadlines, including that for submitting at least a dozen administrative and material submittals. Moreover, it also appears that during this same period, delay occurred because of the death of Mr. Wallace’s grandmother. Accordingly, plaintiff cannot recover damages for this period because “prosecution of the work as a whole would have been delayed regardless of the government’s act.” Essex Electro Engineers, 224 F.3d at 1295 (internal quotations omitted). Second, to cinch matters, plaintiff, at trial, failed to provide evidence from which this court can authenticate and validate its allegedly recoverable expenses. Instead, plaintiff was satisfied to rely on attachments to its complaint and various analyses conducted by defendant rejecting the lion’s share of its claimed expenses. In the court’s view, such evidence is inadequate to establish a basis for recovery.
III. CONCLUSION
Based on the foregoing, the court finds that plaintiff is entitled to remission of liquidated damages for 21 days, which, at $200 per day, amounts to a recovery of $4,200. While the court recognizes that this may be somewhat a Pyrrhic victory, the short of it is that, in all other respects, plaintiffs claims simply are unsupported by the record or the law. The Clerk shall enter an appropriate judgment. No costs.
IT IS SO ORDERED.
. A nutshell on window parts is in order: "Panning” is trim material used in window replacements to cover up the original trim. "Muntins” are short or light strips of wood or metal separating and holding panes of glass in windows. "False" muntins provide the familiar cross-hatch of "true” muntins, but do not support the glass and instead are usually placed on the inside of the window. Muntins are to be distinguished from "mullions,” which are the major structural vertical or horizontal wood or metal members between window units or sliding glass doors.
. Emphasizing that the muntins had to be capable of bearing this pressure, paragraph 2.1 of the window specifications incorporated, by reference, American Architectural Manufacturers Association publication 101, section 1.5.2 of which states that "structural members shall be designed to withstand the full design load for the project site.”
. The record indicates that this provision was added to the specifications because Building 58 was occupied and the Navy wanted to minimize the disruption occasioned by the window installation.
. The contract also incorporated, by reference, the liquidated damages provisions of section 52.212-5 of the 1984 version of the FAR. In
. By January 5, 2003, R.P. Wallace had made the paint submittals required by the contract. In its complaint, R.P. Wallace averred that the solicitation’s paint and vinyl siding specifications, which the Navy admitted were defective, had also contributed to its performance delays. At trial, however, plaintiff essentially abandoned this claim and the court thus does not delve into factual details regarding these issues.
. The administrative submittals on this list were: schedule of prices, construction schedule, submittal register, list of contractor personnel and vehicles, and subcontractor statements of acknowledgment. The material submittals on this list were: unit masonry, preformed vinyl siding, aluminum windows, glazing, metal support systems and wall insulation, gypsum board and painting resubmittal.
. This letter limned the difficulties that plaintiff had encountered in finding a window supplier in the following terms:
We struggled with producing the window submittal for subject contract. Our struggles were tied directly to the fact that we were dealing with a defective specification, a condition not immediately known to us. We had several window suppliers who passed on becoming involved in this contract by simply stating they could not meet the specifications. Then finally, our supplier, Alenco, made it clear to us the problem was not in meeting the specifications, but, in fact, the problem is the specification is defective. Much time and effort had gone into producing a window submittal and when it was learned by us, that our problem was tied directly to a defective specification, this was of course, brought to the attention of the Navy.
. The aforementioned May 26, 1994, letter from the Navy to R.P. Wallace, provided the following fuller explanation for the 36-day extension:
The amount of the time extension due the contractor for the defective window specifications was computed as the time between when the first and second window submittals were returned. It is reasonable to assume that had the government specified the proper windows, the first window submittal would have been approved. Therefore, the government began to delay the contractor the day the first window submittal was disapproved until the day the second window submittal was approved*408 (conditionally). The first window submittal was returned to the contractor on 16 March 1994, and the second window submittal was returned to the contractor on 21 April 1994. This is a difference of 36 days. Adding 36 days to the current contract completion date of 26 March 1994 results in a new estimated contract completion date of 1 May 1994.
. Although plaintiff had originally projected that it would take 28 days to complete the window installation, it actually took 113 days to complete this task.
. The Court of Claims once described the critical path method as
an efficient way of organizing and scheduling a complex project which consists of numerous interrelated small projects. Each subproject is identified and classified as to the duration and precedent of the work ... The data is then analyzed, usually by computer, to determine the most efficient schedule for the entire project. Many subprojects may be performed at any time within a given period without any effect on the completion of the entire project. However, some items of work are given no leeway and must be performed on schedule; otherwise, the entire project will be delayed. These latter items of work are on the "critical path.” A delay, or acceleration, of work along the critical path will affect the entire project.
Haney v. United States, 230 Ct.Cl. 148, 676 F.2d 584, 595 (1982); see also Manuel Bros., Inc. v. United States, 55 Fed.Cl. 8, 49 n. 8 (2002).
. In Sauer, the Federal Circuit likewise opined that "a party asserting that liquidated damages were improperly assessed bears the burden of showing the extent of the excusable delay to which it is entitled." 224 F.3d at 1347; see also Aptus Co. v. United States, 61 Fed.Cl. 638, 647 (2004); PCL Constr. Servs., Inc. v. United States, 53 Fed.Cl. 479, 484 (2002); CJP Contractors, Inc. v. United States, 45 Fed.Cl. 343, 372 (1999).
. The rule stated in Essex Electro Engineers has a rich provenance, dating at least to Newport News Shipbuilding & Dry Dock Co. v. United States, 79 Ct.Cl. 25, 1934 WL 2021 (1934). There, the Court of Claims declined to find defendant liable for delays on the ground that plaintiff could not establish causation, stating "[i]f, as the plaintiff contends, the work was delayed because of the failure of the Government to furnish certain parts, ... such delay ran concurrently with other delays for which the defendant was not responsible and did not result to any appreciable extent in delaying the final completion” of the project. Id at 36, 1934 WL 2021; see also Tuller Constr. Co. v. United States, 118 Ct.Cl. 509, 526, 1951 WL 5364 (1951); Coath & Goss, Inc. v. United States, 101 Ct.Cl. 702, 714-15, 1944 WL 3694 (1944); CEMS, Inc. v. United States, 59 Fed.Cl. 168, 232 (2003).
. See, e.g., Acme, 347 F.2d at 535; Commerce Int’l Co. v. United States, 167 Ct.Cl. 529, 338 F.2d 81, 90 (1964); Vogt Bros. Mfg. Co. v. United States, 160 Ct.Cl. 687, 709 (1963); Schmoll, 91
. In finding United Engineering inapposite, the Court of Claims explained:
The contention by the plaintiff that he is not chargeable with any liquidated damages can not be sustained. The case of United Engineering Co., 234 U.S. 236[, 49 Ct.Cl. 689, 34 S.Ct. 843, 58 L.Ed. 1294], is not applicable to the instant case. The contract provides a definite period from which the liquidated damages are to be computed, and in case of delays by the Government or suspensions, in the circumstances stated above, it is provided that one day be added to the contractor’s time for each day of delay. These delays being ascertained, the time of completion is as definitely fixed as if written in the contract itself. The theory that the entire liquidated damage clause is defeated by a provision intended to protect and save it, and at the same time to accord to the contractor some relief, is not to be adopted where the contract shows plainly that its intent is to furnish the means of definitely ascertaining the period during which the contractor should be charged with the agreed damages.
57 Ct.Cl. 7, 24, 1921 WL 1263 (1921).
. The earliest Court of Claims decision to construe United Engineering, New York Continental Jewell Filtration Co. v. United States, 55 Ct.Cl. 288, 1920 WL 642 (1920) recognized the limita
It is well settled that in cases where delays have been caused by both parties to a contract and the completion of the contract has thereby been extended beyond the time fixedf,] the obligation for liquidated damages is annulled, and it can not be revived, and any recovery for subsequent delays must be for actual loss proved to have been sustained.
Id. (emphasis added).
. In this court's view, the welter of confusion on this issue stems not only from a general failure to interpret United Engineering in light of Robinson, but also from several decisions that use the terms "concurrent” and "sequential” interchangeably. Typically, these cases erroneously rely upon decisions applying the nonapportionment rule to concurrent delays for support in applying the same rule to a sequential delay. See, e.g., Commerce Int'l Co., 338 F.2d at 89-90 n. 11 (citing eight cases for the proposition that "there can be no delay where the defendant’s delay is concurrent,” five of which dealt only with sequential delays).
. Notably, early decisions, such as United Engineering, holding liquidated damage clauses unenforceable, often expressed a general hesitancy to enforce such clauses. See DJ Mfg. Corp. v. United States, 86 F.3d 1130, 1134-35 (Fed.Cir.1996) (discussing this point). As reflected in the current Restatement on Contracts, that view no longer finds currency in the law. Compare Rest. Contracts § 339(1) (indicating that liquidated damage provisions were "unenforceable” unless certain limiting conditions were met) with Rest. (Second) Contracts § 356(1) (indicating that such provisions are enforceable unless violative of "public policy” and a "penalty”).
. Consistent with this interpretation of the facts, in early January of 1994, one of plaintiff’s employees, Mr. Fortenberry, notified the Navy that the window submittals would be received by January 7, 1994. Moreover, in the March 24, 1994, letter that Alenco sent to plaintiff, it suggested that it had been involved with the project as early as the bidding process.
. When asked why it took five months to manufacture the windows, Mr. Wallace responded ”[w]ell, you know, this was out of our hands. We’ve now got it in Alenco's hands." Plaintiff’s expert, Mr. Ostrowski, similarly testified that, during the fabrication and delivery phase-
It is my opinion then that because of the special nature of those windows the full delivery time — fabrication and delivery time was out of the control of the contractor. They were at the mercy of whatever it would take to get these special windows made. They came in some 22 weeks after the approval had been granted from the government for those windows. That whole time I attribute to the government due to the special nature of the windows.
. Mr. Wallace testified that once the window submittal was approved, he did not go to another window manufacturer, because "Alenco was the only game in town.” While this may have been true prior to the time the defective muntin specification was discovered and corrected, there is no indication that such was the case after the specifications were changed. Nor is there any indication that plaintiff even tried at that point to obtain either a different supplier or a better schedule from Alenco. On this point, the court credits defendant’s expert, Mr. Weathers, who, when asked if plaintiff should have stayed with Alenco when advised that it would take 22 weeks to fabricate the windows, testified:
I would have expected that there would be some research done, perhaps a question to the architect who he designed around, if he had any suppliers in mind, whether the Navy could, but at that I point I would certainly think that it would be given consideration to go elsewhere.
Mr. Weathers further testified that it would have been reasonable for R.P. Wallace to contact other suppliers to see what schedule they could produce.
. At various points, plaintiff seems to contend that the delay in the fabrication phase was excusable because the window for the project required special panning that Alenco was required to design and extrude. But, as noted, this panning requirement was fully disclosed in the initial specifications, which also plainly stated that contractor was required to "[djesign windows to accommodate hardware, glass, weatherstripping, and accessories to be furnished,” thereby revealing that the windows were not off-the-shelf items. As such, it was for plaintiff to determine, during the bidding process, whether it could acquire the windows in enough time to perform the contract on a timely basis. Its failure to do so is not attributable to defendant. See In re Appeal of Cole Constr. Co., Inc. 96-2 B.C.A. ¶ 28,579, 1996 WL 571623 (1996) (noting, in comparable circumstances, the contractor "had a choice to enter the contract, or not to enter the contract, based on the information presented by the contract terms proffered"). Moreover, the delay in extruding the aluminum panning was "foreseeable” at the time of the contracting and, for that reason alone, does not give rise to excusable delay under FAR § 52.249-10. See Cibinic & Nash, at 550; Fox Constr., Inc v. General Servs. Admin, 93-3 B.C.A. ¶ 26,193, 1993 WL 216760 (1993) (defective specification not cause of delay where delay due to contractor’s failure to consider nondefective contract requirements); see also Carnegie Steel Co. v. United States, 240 U.S. 156, 165, 36 S.Ct. 342, 60 L.Ed. 576 (1916) (delay caused by simple inability to perform on time is not excusable).
. See also, e.g., Appeal of JTL, Inc., 98-2 B.C.A. ¶ 29,873, 1998 WL 391909 (1998) (noting that, under comparable excusable delay provisions, the risk of an untimely performance by a subcontractor is on the contractor); Appeal of Granite Constr. Co., 89-2 B.C.A. ¶ 21,683, 1989 WL 29822 (1989) (“manufacturing backlog has been consistently denied by the courts and boards as an excuse for delay or non-performance”); Appeal of Occupacia Const., 88-2 B.C.A. ¶ 20,820, 1988 WL 61535 (1988) (denying relief under a clause similarly worded to FAR § 52.249-10 based on a backlog by a manufacturer); Northern Virginia Elec. Co. Inc., 80-1 B.C.A. ¶ 14,239, 1979 WL 2369 (1979) (same).
. On this point, Mr. Wallace testified that the workers at the site were not cross-trained, indicating further that "we had a subcontractor that did the window installation, and, as I recall, ... they did just that, the window installation.”
. The record suggests that plaintiff may have misunderstood this requirement, but not owing to any fault on the part of the Navy. Apparently, at some point around September 20, 1994, R.P. Wallace provided the Navy with a window replacement schedule. On September 30, 1994, the Navy responded to this schedule noting that "[n]o mention is made to completing one window area entirely before proceeding onward.” Apparently misinterpreting the latter statement, on October 4, 1994, plaintiff submitted a revised schedule that stated “[e]ach window to be completed prior to moving to next window.” Testimony indicates that when this confusion was identified, the Navy verified that plaintiff need not replace only one window at a time.
. It should be noted that the record does not support the claim made by Mr. Ostrowski that the majority of the delay in the installation of the windows occurred not because of a shortage staff, but because two smaller batches, totaling 9 to 12 windows, were not delivered until November 18, 1994, and January 10, 1995, respectively. Even were this claim true, plaintiff did not show that the delay in receiving these last windows was attributable to defendant. — indeed, it appears that at least some of these windows were broken when originally shipped. At all events, it is notable that Mr. Wallace, from whom Mr. Ostrowski drew his factual information, did not himself