Mickelsen v. Craigco, Inc.

HOWE, Associate Chief Justice:

Plaintiff Garry W. Mickelsen brought this action to foreclose a mechanic’s lien which he had recorded against the River Oaks subdivision owned by defendant Cra-igco, Inc. Defendant Sherwood & Roberts, Inc., which was the beneficiary of a trust deed on the subdivision, moved for summary judgment on three grounds: (1) that plaintiffs foreclosure action had not been timely commenced; (2) that plaintiffs recorded notice of lien was invalid because it had not been properly verified; and (3) that no work had been done in the subdivision and no materials had been furnished as required by Utah Code Ann. § 38-1-5 (1988) prior to the recording of Sherwood & Roberts’ trust deed so as to give plaintiffs mechanic’s lien priority over the trust deed. The trial court granted summary judgment in favor of Sherwood & Roberts on the first ground. Plaintiff appeals.

In July 1978, Craigco began development of the subdivision. In October 1978, a boundary survey was made by a surveyor, who set more than twenty stakes in the ground. Later, there was additional surveying and setting of over two hundred stakes to mark the center line of proposed roads as well as water, sewer, and storm sewer lines. In April 1979, plaintiff dug six test holes for soil and water studies. Plaintiff claims that before the end of 1979, the proposed roads were rough cut, the land was “cleared and grubbed,” and an old dairy barn and corrals were demolished and removed from the property. On December 28, 1979, Sherwood & Roberts made a loan to Craigco which was secured by a trust deed on the property which was recorded on that date.

During 1980 and up to about August 28, 1981, plaintiff furnished labor and materials to install the water lines, sewer lines, and storm sewer lines. Three times during the course of his work, plaintiff, at the request of Craigco, suspended work for thirty days or more. The periods of suspension of work were August 22 through October 2, 1980; November 1, 1980, through January 2, 1981; and March 13 through July 26, 1981. On September 30, 1981, plaintiff recorded a notice of mechanic’s lien on the property to secure the payment of over $62,000 which was then past due. On April 29, 1982, he commenced the instant action to foreclose that lien.

On motion for summary judgment by Sherwood & Roberts, it contended and the trial court agreed that plaintiff was required to bring any foreclosure action within twelve months after the suspension of any work and therefore plaintiff had no valid lien for work done by him prior to March 13,1981, and any lien for work done after that date was junior to the trust deed.

Utah Code Ann. § 38-1-11 (1988) provides in part:

Actions to enforce the liens herein provided for must be begun within twelve months after the completion of the original contract, or the suspension of work thereunder for a period of thirty days.

We do not subscribe to the trial court’s interpretation of section 38-1-11 because it runs contrary to this Court’s decision in Totorica v. Thomas, 16 Utah 2d 175, 397 P.2d 984 (1965). In that case, we interpreted the literal conjunctive language of the statute “that the action must be commenced within twelve months after the completion of the original contract, or the suspension of work thereunder for a period of thirty days” as affording the lien claimant a choice. That is to say, “a lien claimant may bring an action within twelve months after the completion of his contract, or, if he wishes, bring it within twelve months after there has been a suspension of work for a period of thirty days.” Totorica, 16 Utah 2d at 178, 397 P.2d at 986-87.

The rationale for our decision in Totorica is that the mechanic’s lien law was enacted for the benefit of those who perform the labor and supply the materials and that the lien claimant’s remedy should not be limited without a clear mandate from the legislature requiring such an effect. We therefore conclude that plaintiff commenced his action to foreclose his lien within the time afforded by section 38-1-11.

Defendant next contends that the notice of lien filed by plaintiff was invalid since he admittedly did not make an oral averment as to the truthfulness of its contents to the notary public before whom he appeared. Utah Code Ann. § 38-1-7 (1974) required at the time the notice of lien here was recorded, on September 30, 1981, that the contents of the claim “must be verified by the oath of [the claimant] or of some other person.”¹

Our decided cases do not appear to be entirely harmonious as to what is required for a proper verification. In one of the earliest cases on the subject, Spangler v. District Court of Salt Lake County, 104 Utah 584, 140 P.2d 755 (1943), we stated that evidence that the affiant was conscious he was taking an oath cannot be inferred from his signature on a printed form; therefore, his mere signature to a printed form was not sufficient to constitute an oath. We later relied on that language in Spangler to hold invalid an affidavit signed by a patrolman in the presence of a notary when the patrolman had not verbally sworn to its contents. Colman v. Schwendiman, 680 P.2d 29 (Utah 1984). Two justices dissented, stating that the majority holding was against the “clear weight of authority.” See also White v. Heber City, 82 Utah 547, 26 P.2d 333 (1933), where in dicta we seemed to require the administration of an oath to an affiant and an oral averment as to the truthfulness of the document.

Between our decisions in Spangler and Colman, we decided two cases in which the strict requirements of Spangler were not adhered to. In State v. Mathews, 13 Utah 2d 391, 375 P.2d 392 (1962), we held that no formal ritual with the raising of the right hand was necessary and that a deputy county recorder who only signed a printed oath before a notary was a de jure officer. We later held that the administration of the oath need not follow any certain pattern and that the ritual is of secondary importance. McKnight v. State Land Board, 14 Utah 2d 238, 381 P.2d 726 (1963). In that case, the affiant signed an application form in blank in the presence of a notary. Later, while out of the state, he conferred with the notary in Utah by phone. The notary then completed the application and affixed his jurat that the application had been “[subscribed and sworn to before me this 2nd day of February, 1962, at Salt Lake City, Utah,” although the affiant was out of the state on that date. We upheld the verification.

A survey of cases from other jurisdictions reveals that many of them do not require that the affiant raise his hand or speak any words in order to have a valid verification. Those cases hold that the signing of a form of affidavit in the presence of a notary or an official authorized to administer an oath is sufficient. Blackburn v. Motor Vehicles Division, 33 Or. App. 397, 576 P.2d 1267 (1978), and cases cited and discussed therein. In order to end the confusion in our case law, we join those jurisdictions and the dissenters on our own Court in Colman v. Schwendiman. We adopt as our rule that for a valid verification,

(1) there must be a correct written oath or affirmation, and (2) it must be signed by the affiant in the presence of a notary or other person authorized to take oaths, and (3) the latter must affix a proper jurat.

There is no minimum requirement that an oath must be administered to the affiant or that the affiant must speak an oral oath or affirmation or raise his or her hand. We overrule Colman v. Schwendiman and Spangler v. District Court of Salt Lake County to the extent that they conflict with this new rule. However, our decision today in no way disturbs First Security Mortgage Corp. v. Hansen, 631 P.2d 919 (Utah 1981), where the form of verification was deficient, and Graff v. Boise Cascade Corp., 660 P.2d 721 (Utah 1983), where the verification form, though proper, was not properly executed. Nor do we depart in any way from our case law requiring substantial compliance with the statutory requirements of the contents of a notice of mechanic’s lien. Roberts Investment v. Gibbons & Reed Concrete Products, 22 Utah 2d 105, 108, 449 P.2d 116, 118 (1969); Park City Meat Co. v. Comstock Silver King Mining Co., 36 Utah 145, 154, 103 P. 254, 257 (1909). Likewise, Helsten v. Schwendiman, 668 P.2d 509 (Utah 1983), where the affiant did not personally appear before the notary, and Baker v. Schwendiman, 714 P.2d 675 (Utah 1986), where the affiant was not formally put under oath by the notary, remain good law.

In the instant case, the form of verification on the notice of mechanic’s lien recorded by plaintiff was properly worded so that by signing it, plaintiff swore to the truthfulness of the contents of the notice of lien.² The verification was signed in the presence of a notary, and the notary affixed a proper jurat. We therefore find that the notice of lien was properly verified.

We note that in early 1988 after the instant case had been argued and submitted to this Court, the legislature amended our statutes governing notaries public and enacted the “Notaries Public Reform Act.” Utah Code Ann. § 46-1-1 through -17 (1988). Since that enactment came long after the rights of the parties to this action arose, we express no opinion as to whether any of the provisions of that Act impinge upon our decision here.

Defendant’s third ground for its motion for summary judgment was that the work which was done in the subdivision by plaintiff and other mechanics prior to the rec-ordation of defendant’s trust deed, the work relied on by plaintiff in bringing his claims of priority over the trust deed, was insufficient to satisfy the requirements of section 38-1-5. The trial court did not reach this issue. It involves factual determinations which must now be made. We therefore reverse the summary judgment and remand this case to the trial court for that determination and any others necessary for final disposition.

STEWART, J., concurs.

1 . The legislature amended this statute in 1985 to delete the requirement of verification. See Utah Code Ann. § 38-1-7 (1988).

2 . The verification on the notice of lien form states: "[ ] being first duly sworn, says that he is claimant in the foregoing Notice of Lien; that he has heard/read said notice and knows the contents thereof, and that the same is true of his own knowledge. [Signed,] subscribed and sworn to before me this_day of-, 19_[notary’s signature and seal].”